OWNER’S RIGHT TO PERFORM CONSTRUCTION AND TO AWARD SEPARATE CONTRACTS § 7.4.1 The Owner reserves the right to perform construction or operations related to the Project with the Owner’s own forces, and to award separate contracts in connection with other portions of the Project.
Contractor Obligations The Contractor is responsible for fully meeting all Contract obligations set forth in the OGS Centralized Contract and for providing services in accordance with the Contract and any Authorized User Agreement, Statement of Work or Purchase Order.
LIMITATION OF CONTRACTOR’S LIABILITY Except as specified in any separate writing between the Contractor and an END USER, Contractor’s total liability under this Agreement, whether for breach of contract, warranty, negligence, strict liability, in tort or otherwise, but excluding its obligation to indemnify H-GAC, is limited to the price of the particular products/services sold hereunder, and Contractor agrees either to refund the purchase price or to repair or replace product(s) that are not as warranted. In no event will Contractor be liable for any loss of use, loss of time, inconvenience, commercial loss, loss of profits or savings or other incidental, special or consequential damages to the full extent such use may be disclaimed by law. Contractor understands and agrees that it shall be liable to repay and shall repay upon demand to END USER any amounts determined by H-GAC, its independent auditors, or any agency of State or Federal government to have been paid in violation of the terms of this Agreement.
DESCRIPTION OF CONTRACT MODIFICATION This contract modification is made in accordance with Exhibit E-Revised-1, Contractual Terms and Conditions, Section 22. CHANGES, to be made part hereof for all pertinent purposes. The changes are as follows:
CONTRACTOR OBLIGATION Contractor shall identify and mark the precise portion(s) of the relevant page(s) of any records provided to Enterprise Services that Contractor believes are statutorily exempt from disclosure and identify the precise statutory basis for exemption from disclosure. In addition, if, in Contractor’s judgment, certain portions of such records are not statutorily exempt from disclosure but are sensitive because particular portions of Contractor’s records (NOT including pricing) include highly confidential, proprietary, or trade secret information (or the equivalent) that Contractor protects through the regular use of confidentiality or similar agreements and routine enforcements through court enforcement actions, Contractor shall identify and mark the precise portion(s) of the relevant page(s) of any records that include such sensitive information.
Application of Contract Provisions The parties agree that the following contract provisions shall not apply to these employees:
General Contract Provisions Any and all Schedules to this Agreement form a part hereof. No amendment, waiver, discharge or release of this Agreement shall be binding or enforceable unless made in writing signed by all of the parties hereto. Time is and shall remain of the essence under and pursuant to this Agreement; provided that the time for performing or completing any matter under or pursuant to this Agreement may be extended or abridged by an agreement in writing by the parties or their respective solicitors. Failure by any party to strictly enforce any provisions hereof shall not operate as a waiver or limitation of such party's rights hereunder in respect of any subsequent default. If any provision of this Agreement or the application thereof to any person or circumstance is to any extent held or rendered invalid, unenforceable or illegal, same shall be considered separate and severable herefrom and all other provisions of this Agreement shall remain in full force and effect and be binding upon the parties hereof. The headings set forth in this Agreement are inserted for convenience and reference only and shall in no way define or limit the intent or interpretation of any of the provisions hereof. Wherever in this Agreement any subject matter is described as including specifically described persons, things, events or other items, unless expressly stated to the contrary, the word “including” or any other derivation or variation of that word means, as the case may be, “including, without limitation,” or “including, without limiting the generality of the foregoing,” or such derivation or variation thereof as required by the context. This Agreement shall be read and construed with all changes of gender and number of the party or parties referred to in each case as required by the context, and the covenants and agreements of each party shall be deemed to be joint and several where such party is more than one person, firm or corporation. With respect to each party which is a partnership, each person who is presently a partner of such partnership and each person who becomes a partner of such partnership shall be and continue to be jointly and severally liable for all covenants and agreements of such party notwithstanding that any such person subsequently ceases to be a partner of such partnership, subject to and only to the extent of the limited liability of any such person that is a limited partner of such partnership.
Limitation of Vendor Indemnification and Similar Clauses This is a requirement of the TIPS Contract and is non-negotiable TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, is prohibited from indemnifying third-parties (pursuant to the Article 3, Section 52 of the Texas Constitution) except as otherwise specifically provided for by law or as ordered by a court of competent jurisdiction. Article 3, Section 52 of the Texas Constitution states that "no debt shall be created by or on behalf of the State … " and the Texas Attorney General has opined that a contractually imposed obligation of indemnity creates a "debt" in the constitutional sense. Tex. Att'y Gen. Op. No. MW-475 (1982). Thus, contract clauses which require TIPS to indemnify Vendor, pay liquidated damages, pay attorney's fees, waive Vendor's liability, or waive any applicable statute of limitations must be deleted or qualified with ''to the extent permitted by the Constitution and Laws of the State of Texas." Does Vendor agree? Yes, I Agree Alternative Dispute Resolution Limitations This is a requirement of the TIPS Contract and is non-negotiable. TIPS, a department of Region 8 Education Service Center, a political subdivision, and local government entity of the State of Texas, does not agree to binding arbitration as a remedy to dispute and no such provision shall be permitted in this Agreement with TIPS. Vendor agrees that any claim arising out of or related to this Agreement, except those specifically and expressly waived or negotiated within this Agreement, may be subject to non-binding mediation at the request of either party to be conducted by a mutually agreed upon mediator as prerequisite to the filing of any lawsuit arising out of or related to this Agreement. Mediation shall be held in either Camp or Titus County, Texas. Agreements reached in mediation will be subject to the approval by the Region 8 ESC's Board of Directors, authorized signature of the Parties if approved by the Board of Directors, and, once approved by the Board of Directors and properly signed, shall thereafter be enforceable as provided by the laws of the State of Texas. Does Vendor agree? Yes, Vendor agrees Does Vendor agree? Yes, Vendor agrees No Waiver of TIPS Immunity This is a requirement of the TIPS Contract and is non-negotiable. Vendor agrees that nothing in this Agreement shall be construed as a waiver of sovereign or government immunity; nor constitute or be construed as a waiver of any of the privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department. The failure to enforce, or any delay in the enforcement, of any privileges, rights, defenses, remedies, or immunities available to Region 8 Education Service Center or its TIPS Department under this Agreement or under applicable law shall not constitute a waiver of such privileges, rights, defenses, remedies, or immunities or be considered as a basis for estoppel. 5 Does Vendor agree? Yes, Vendor agrees Payment Terms and Funding Out Clause This is a requirement of the TIPS Contract and is non-negotiable. Vendor agrees that TIPS and TIPS Members shall not be liable for interest or late-payment fees on past-due balances at a rate higher than permitted by the laws or regulations of the jurisdiction of the TIPS Member. Funding-Out Clause: Vendor agrees to abide by the applicable laws and regulations, including but not limited to Texas Local Government Code § 271.903, or any other statutory or regulatory limitation of the jurisdiction of any TIPS Member, which requires that contracts approved by TIPS or a TIPS Member are subject to the budgeting and appropriation of currently available funds by the entity or its governing body. 2
Contractor Guaranties Contractor shall:
GENERAL CONDITIONS OF CONTRACT 1. Definitions 1.1 In this Contract, the following terms shall be interpreted as indicated:
