Addressing Objections Raised During Public Comment Period The Parties agree that the procedure contemplated for public review of this Stipulated Order and the Regional Water Board’s or its delegate’s adoption of this Stipulated Order is lawful and adequate. The Parties understand that the Regional Water Board or its delegate has the authority to require a public hearing on this Stipulated Order. If procedural objections are raised or the Regional Water Board requires a public hearing prior to the Stipulated Order becoming effective, the Parties agree to meet and confer concerning any such objections, and may agree to revise or adjust the procedure and/or this Stipulated Order as necessary or advisable under the circumstances.
Preliminary Approval Order “Preliminary Approval Order” means the order of the Court preliminarily approving this Settlement Agreement.
Enhanced Optional Daily Usage File (EODUF 13.1 The EODUF service Agreement with terms and conditions is included in this Attachment as Exhibit C. Rates for EODUF are as set forth in Exhibit D.
Free Look Period The free look period shall be applicable at the inception of the policy and:
Effective Date of the Contract The date indicated on the Contract or as otherwise specified therein.
Final Approval Order 62. The Parties shall jointly seek entry of a Final Approval Order, the text of which the Parties shall agree upon. The dismissal orders, motions or stipulation to implement this Section shall, among other things, seek or provide for a dismissal with prejudice and waiving any rights of appeal.
Recovery of Schedule Delays During Last Sixty Days of Contract Time At any time during the last sixty days of the Contract Time that the Design Professional finds that the Contractor is behind schedule per the Contract Time, as amended, the Design Professional shall notify the Contractor in writing. Within seven days of the date of the Design Professional's notice, the Contractor shall prepare and deliver to the Design Professional and Owner a written plan explaining how the Contractor intends to bring the Project back on schedule. The Contractor's plan must provide sufficient detail to allow the Design Professional and Owner to determine the proposal's feasibility.
Effective Date; Duration This Agreement shall become effective when signed by both parties and approved by the City’s legal counsel. Unless sooner terminated, this Agreement shall expire on June 30, 2019. Termination or expiration shall not extinguish or prejudice the City’s right to enforce this Agreement with respect to any default or defect in performance that has not been cured.
Carry Forward to a Subsequent Year If you do not withdraw the excess contribution, you may carry forward the contribution for a subsequent tax year. To do so, you under-contribute for that tax year and carry the excess contribution amount forward to that year on your tax return. The six percent excess contribution penalty tax will be imposed on the excess amount for each year that it remains as an excess contribution at the end of the year. You must file IRS Form 5329 along with your income tax return to report and remit any additional taxes to the IRS.
Effective Date of Settlements Settlements reached at any step of the grievance procedure in this article, other than Clause 8.11, shall be applied retroactively to the date of the occurrence of the action or situation which gave rise to the grievance, but not prior to the effective date of the agreement in effect at the time of the occurrence or the date set by a board of arbitration.
