Tenant Delays A "Tenant Delay” shall be defined as any delay in the design, permitting or performance of the Base Building Work to the extent that such delay is actually caused by any act or, where there is a duty to act under this Lease, any failure to act by Tenant or Tenant's contractors, architects, engineers, or anyone else engaged by or on behalf of Tenant in connection with the construction of the Tenant Improvement Work as set forth in this Article III (including, without limitation, any delays resulting from the Approved Tenant Finishes under Section 3.l(C) above) and disclosed to Tenant as hereinafter provided. Notwithstanding the foregoing, in no event shall any delays in the completion of the Base Building Work caused by Tenant’s use of non-union labor constitute a Tenant Delay hereunder. Notwithstanding the foregoing, no event shall be deemed a Tenant Delay unless and until Landlord has given Tenant written notice (the "Tenant Delay Notice") advising Tenant: (x) that a Tenant Delay is occurring and setting forth Landlord's good faith estimate as to the likely length of such Tenant Delay; (y) of the basis on which Landlord has determined that a Tenant Delay is occurring; and (z) the actions which Landlord believes that Tenant must take to eliminate such Tenant Delay. No event shall be deemed to be a Tenant Delay unless and until Tenant has failed to rectify the situation causing the Tenant Delay within forty-eight (48) hours after Tenant's receipt of the Tenant Delay Notice (which for the purposes of determining receipt may be delivered by hand to Tenant's Construction Representative, with copies to follow to Tenant at the notice address set forth in Section 1.2 of this Lease within five (5) days thereafter); provided, however, that if Tenant shall fail to eliminate the delay within the aforesaid 48-hour period, then the 48-hour cure period shall be included in the period of time charged to Tenant pursuant to such Tenant Delay Notice (it being understood and agreed that if Tenant shall in fact eliminate the Tenant Delay within the 48-hour cure period, no Tenant Delay shall be deemed to have occurred for the purposes of this Article III). In addition, any delay to the extent caused by (i) Landlord Delay or (ii) subject to the limitations of subsection (D) below, Tenant's Force Majeure (as defined in said subsection (D)) shall not constitute Tenant Delay. Tenant covenants that no Tenant Delay shall delay commencement of the Term or the obligation to pay Annual Fixed Rent or Additional Rent. The Delivery Dates and/or the date of substantial completion of the Base Building Work, as applicable, shall be deemed to have occurred as of the date when such Delivery Dates and/or date of substantial completion of the Base Building Work, as applicable, would have occurred but for any Tenant Delays, as determined by Landlord in the exercise of its good faith business judgment (it being understood and agreed that the foregoing shall not be construed so as to relieve Landlord of its obligation to actually complete the Base Building Work, notwithstanding the fact that substantial completion may have been deemed to have occurred prior to actual completion as the result of Tenant Delays).
Tenant Delay Except as otherwise provided in the Lease, Delivery of the Premises shall occur when Landlord’s Work has been Substantially Completed, except to the extent that completion of Landlord’s Work shall have been actually delayed by any one or more of the following causes (“Tenant Delay”):
(i) Tenant’s Representative was not available to give or receive any Communication or to take any other action required to be taken by Tenant hereunder within a reasonable period of time (not to exceed 2 business days) after written request from Landlord;
(ii) Tenant’s request for changes to the Building Shell, whether or not such changes are actually performed;
(iii) The construction of any changes to the Building Shell requested by Tenant and agreed upon by Landlord;
(iv) Tenant’s request for Change Requests (as defined in Section 4(a) below) whether or not any such Change Requests are actually performed;
(v) Construction of any Change Requests;
(vi) Tenant’s request for materials, finishes or installations requiring unusually long lead times (provided Landlord will request that the General Contractor inform Tenant of any long lead time items and identify substitutes for such items as soon as reasonably possible);
(vii) Tenant’s delay in reviewing, revising or approving plans and specifications beyond the periods set forth herein;
(viii) Tenant’s delay in providing any information that is reasonably required to come from Tenant which is critical to the normal progression of the Project within a reasonable period of time after request. Tenant shall provide such information as soon as reasonably possible, but in no event longer than one week after receipt of any request for such information from Landlord;
(ix) Tenant’s delay in making payments to Landlord for Excess TI Costs (as defined in Section 5(d) below) for more than 10 business days after such Excess TI Costs are required to be paid to Landlord; or
(x) Any other act or omission by Tenant or any Tenant Party (as defined in the Lease), or persons employed by any of such persons that continues for more than 1 business day after Landlord’s notice thereof to Tenant. If Delivery is delayed for any of the foregoing reasons, then Landlord shall cause the TI Architect to certify the date on which the Tenant Improvements would have been Substantially Completed but for such Tenant Delay and such certified date shall be deemed to be the Commencement Date for purposes of Tenant’s obligation to pay Base Rent, Operating Expenses, Excess TI Costs and TI Rent; however, Tenant will not have any obligation to pay any amounts to third parties pursuant to the Lease (and will not occupy the Premises) until the date upon which the Premises is Delivered to Tenant with the Landlord’s Work Substantially Complete. Upon request, Landlord shall advise Tenant of any materials, finishes or installations which are required as part of any Change Request that will result in unusually long lead times.
Force Majeure Delays In any case where either party hereto is required to do any act (other than the payment of money), delays caused by or resulting from Acts of God or Nature, war, civil commotion, fire, flood or other casualty, labor difficulties, shortages of labor or materials or equipment, government regulations, delay by government or regulatory agencies with respect to approval or permit process, unusually severe weather, or other causes beyond such party’s reasonable control the time during which act shall be completed, shall be deemed to be extended by the period of such delay, whether such time be designated by a fixed date, a fixed time or “a reasonable time.”
Total Operating Expenses All costs and expenses paid or incurred by the Company, as determined under GAAP, that are in any way related to the operation of the Company or its business, including the Advisory Fee, but excluding (i) the expenses of raising capital such as Organization and Offering Expenses, legal, audit, accounting, underwriting, brokerage, listing, registration, and other fees, printing and other such expenses and taxes incurred in connection with the issuance, distribution, transfer and registration of securities, (ii) interest payments, (iii) taxes, (iv) non-cash expenditures such as depreciation, amortization and bad debt reserves, (v) incentive fees paid in compliance with the NASAA REIT Guidelines; (vi) acquisition fees and Acquisition Expenses, (vii) real estate commissions on the sale of Real Property, and (viii) other fees and expenses connected with the acquisition, disposition, management and ownership of real estate interests, mortgages or other property (including the costs of foreclosure, insurance premiums, legal services, maintenance, repair, and improvement of property). The definition of “Total Operating Expenses” set forth above is intended to encompass only those expenses which are required to be treated as Total Operating Expenses under the NASAA REIT Guidelines. As a result, and notwithstanding the definition set forth above, any expense of the Company which is not part of Total Operating Expenses under the NASAA REIT Guidelines shall not be treated as part of Total Operating Expenses for purposes hereof. 2%/25% Guidelines. 2%/25% Guidelines shall have the meaning set forth in Section 14.
Longer Delays May Apply We may delay your ability to withdraw funds deposited by check into your account an additional number of days for these reasons: • We believe a check you deposit will not be paid. • You deposit checks totaling more than $5,525 on any one day. • You re-deposit a check that has been returned unpaid. • You have overdrawn your account repeatedly in the last six (6) months. • There is an emergency, such as failure of communications or computer equipment. We will notify you if we delay your ability to withdraw funds for any of these reasons, and we will tell you when the funds will be available. They will generally be available no later than the seventh business day after the day of your deposit.
Inability to Determine Eurodollar Rate In the event, prior to the commencement of any Interest Period relating to any Eurodollar Rate Loan, the Administrative Agent shall determine or be notified by the Required Lenders that adequate and reasonable methods do not exist for ascertaining the Eurodollar Rate that would otherwise determine the rate of interest to be applicable to any Eurodollar Rate Loan during any Interest Period, the Administrative Agent shall forthwith give notice of such determination (which shall be conclusive and binding on the Borrower and the Lenders) to the Borrower and the Lenders. In such event (a) any Loan Request or Conversion Request with respect to Eurodollar Rate Loans shall be automatically withdrawn and shall be deemed a request for Base Rate Loans, (b) each Eurodollar Rate Loan will automatically, on the last day of the then current Interest Period relating thereto, become a Base Rate Loan, and (c) the obligations of the Lenders to make Eurodollar Rate Loans shall be suspended until the Administrative Agent or the Required Lenders determine that the circumstances giving rise to such suspension no longer exist, whereupon the Administrative Agent or, as the case may be, the Administrative Agent upon the instruction of the Required Lenders, shall so notify the Borrower and the Lenders.
Act of God Days Act of God" days beyond the allowance by Michigan Law and the Department of Education regulations will be made up by the students and assistants at the end of the school year or at other times as specified by the calendar. Assistants will only receive compensation for the "Act of God" days allowed. When a scheduled day of schoolwork is delayed, association members shall report as near as possible to their regular starting times. Assistants will receive their full day's pay when the school day is shortened due to weather or mechanical problems.
RENTAL AMOUNT The Owner hereby grants the Agent power to create rental agreements related to the Property for: (check one)
Computation of Interest and Fees; Retroactive Adjustments of Applicable Rate (a) All computations of interest for Base Rate Loans (including Base Rate Loans determined by reference to LIBOR) shall be made on the basis of a year of 365 or 366 days, as the case may be, and actual days elapsed. All other computations of fees and interest shall be made on the basis of a 360-day year and actual days elapsed (which results in more fees or interest, as applicable, being paid than if computed on the basis of a 365-day year). Interest shall accrue on each Loan for the day on which the Loan is made, and shall not accrue on a Loan, or any portion thereof, for the day on which the Loan or such portion is paid; provided that any Loan that is repaid on the same day on which it is made shall, subject to Section 2.12(a), bear interest for one (1) day. Each determination by the Administrative Agent of an interest rate or fee hereunder shall be conclusive and binding for all purposes, absent manifest error.
(b) If, as a result of any restatement of or other adjustment to the financial statements of the Parent or for any other reason, then the Parent, the Borrower, the Administrative Agent, or the Lenders determine that (i) the Consolidated Leverage Ratio as calculated by the Parent and the Borrower as of any applicable date was inaccurate and (ii) a proper calculation of the Consolidated Leverage Ratio would have resulted in higher pricing for such period, then the Borrower shall immediately and retroactively be obligated to pay to the Administrative Agent for the account of the applicable Lenders, within three (3) Business Days after demand by the Administrative Agent (or, after the occurrence of an actual or deemed entry of an order for relief with respect to any Loan Party under the Bankruptcy Code of the United States, automatically and without further action by the Administrative Agent or any Lender), an amount equal to the excess of the amount of interest and fees that should have been paid for such period over the amount of interest and fees actually paid for such period. This paragraph shall not limit the rights of the Administrative Agent or any Lender, under Section 2.08(b) or under Article IX.
Increased Cost and Reduced Return; Capital Adequacy; Reserves on Eurodollar Rate Loans (a) If any Lender determines that as a result of the introduction of or any change in or in the interpretation of any Law, or such Lender’s compliance therewith, there shall be any increase in the cost to such Lender of agreeing to make or making, funding or maintaining Eurodollar Rate Loans or (as the case may be) issuing or participating in Letters of Credit, or a reduction in the amount received or receivable by such Lender in connection with any of the foregoing (excluding for purposes of this subsection (a) any such increased costs or reduction in amount resulting from (i) Taxes or Other Taxes (as to which Section 3.01 shall govern), (ii) changes in the basis of taxation of overall net income or overall gross income by the United States or any foreign jurisdiction or any political subdivision of either thereof under the Laws of which such Lender is organized or has its Lending Office, and (iii) reserve requirements contemplated by Section 3.04(c)), then from time to time upon demand of such Lender (with a copy of such demand to the Administrative Agent), the Borrower shall pay to such Lender such additional amounts as will compensate such Lender for such increased cost or reduction.
(b) If any Lender determines that the introduction of any Law regarding capital adequacy or any change therein or in the interpretation thereof, or compliance by such Lender (or its Lending Office) therewith, has the effect of reducing the rate of return on the capital of such Lender or any corporation controlling such Lender as a consequence of such Lender’s obligations hereunder (taking into consideration its policies with respect to capital adequacy and such Lender’s desired return on capital), then from time to time upon demand of such Lender (with a copy of such demand to the Administrative Agent), the Borrower shall pay to such Lender such additional amounts as will compensate such Lender for such reduction.
(c) The Borrower shall pay to each Lender, as long as such Lender shall be required to maintain reserves with respect to liabilities or assets consisting of or including Eurocurrency funds or deposits (currently known as “Eurocurrency liabilities”), additional interest on the unpaid principal amount of each Eurodollar Rate Loan equal to the actual costs of such reserves allocated to such Loan by such Lender (as determined by such Lender in good faith, which determination shall be conclusive), which shall be due and payable on each date on which interest is payable on such Loan, provided the Borrower shall have received at least 15 days’ prior notice (with a copy to the Administrative Agent) of such additional interest from such Lender. If a Lender fails to give notice 15 days prior to the relevant Interest Payment Date, such additional interest shall be due and payable 15 days from receipt of such notice.
