Payment of Liquidated Damages With respect to any Liquidated Damages that accrue, Owner shall invoice Contractor for such Liquidated Damages. Contractor shall pay such Liquidated Damages within ten (10) Days after Contractor’s receipt of such invoice. To the extent Contractor does not pay such Liquidated Damages within such ten (10) Day period, Owner may, at its option, do one or more of the following: (i) withhold from Contractor amounts that are otherwise due and payable to Contractor in the amount of such Liquidated Damages and/or (ii) collect on the Letter of Credit in the amount of such Liquidated Damages. For the avoidance of doubt, prior to exercising such right to withhold or collect on the Letter of Credit, Owner shall not be required to provide the notice as set forth in Section 7.8. As used in this Agreement, Liquidated Damages are “paid” if and to the extent Owner exercises option (i) or (ii) above for the collection of Liquidated Damages.
Waiver of Liquidated Damages If the Partnership is unable to cause a Registration Statement to become effective on or before the Target Effective Date, then the Partnership may request a waiver of the Liquidated Damages, which may be granted by the consent of the Holders of at least the Registrable Securities Required Voting Percentage, in their sole discretion, and which such waiver shall apply to all the Holders of Registrable Securities included on such Registration Statement.
Obligation Absolute; Partial Liquidated Damages The Company’s obligations to issue and deliver the Conversion Shares upon conversion of this Debenture in accordance with the terms hereof are absolute and unconditional, irrespective of any action or inaction by the Holder to enforce the same, any waiver or consent with respect to any provision hereof, the recovery of any judgment against any Person or any action to enforce the same, or any setoff, counterclaim, recoupment, limitation or termination, or any breach or alleged breach by the Holder or any other Person of any obligation to the Company or any violation or alleged violation of law by the Holder or any other Person, and irrespective of any other circumstance which might otherwise limit such obligation of the Company to the Holder in connection with the issuance of such Conversion Shares; provided, however, that such delivery shall not operate as a waiver by the Company of any such action the Company may have against the Holder. In the event the Holder of this Debenture shall elect to convert any or all of the outstanding principal amount hereof, the Company may not refuse conversion based on any claim that the Holder or anyone associated or affiliated with the Holder has been engaged in any violation of law, agreement or for any other reason, unless an injunction from a court, on notice to Holder, restraining and or enjoining conversion of all or part of this Debenture shall have been sought and obtained, and the Company posts a surety bond for the benefit of the Holder in the amount of 150% of the outstanding principal amount of this Debenture, which is subject to the injunction, which bond shall remain in effect until the completion of arbitration/litigation of the underlying dispute and the proceeds of which shall be payable to the Holder to the extent it obtains judgment. In the absence of such injunction, the Company shall issue Conversion Shares or, if applicable, cash, upon a properly noticed conversion. If the Company fails for any reason to deliver to the Holder such Conversion Shares pursuant to Section 4(c)(ii) by the Share Delivery Date, the Company shall pay to the Holder, in cash, as liquidated damages and not as a penalty, for each $1,000 of principal amount being converted, $10 per Trading Day (increasing to $20 per Trading Day on the fifth (5th) Trading Day after such liquidated damages begin to accrue) for each Trading Day after such Share Delivery Date until such Conversion Shares are delivered or Holder rescinds such conversion. Nothing herein shall limit a Hxxxxx’s right to pursue actual damages or declare an Event of Default pursuant to Section 8 hereof for the Company’s failure to deliver Conversion Shares within the period specified herein and the Holder shall have the right to pursue all remedies available to it hereunder, at law or in equity including, without limitation, a decree of specific performance and/or injunctive relief. The exercise of any such rights shall not prohibit the Holder from seeking to enforce damages pursuant to any other Section hereof or under applicable law.
Liquidated Damages The Company’s obligations to pay any partial liquidated damages or other amounts owing under the Transaction Documents is a continuing obligation of the Company and shall not terminate until all unpaid partial liquidated damages and other amounts have been paid notwithstanding the fact that the instrument or security pursuant to which such partial liquidated damages or other amounts are due and payable shall have been canceled.
Payment of accrued default interest Subject to the other provisions of this Agreement, any interest due under this Clause shall be paid on the last day of the period by reference to which it was determined; and the payment shall be made to the Agent for the account of the Creditor Party to which the overdue amount is due.
Default Payment Following the occurrence and during the continuance of an Event of Default, the Holder, at its option, may demand repayment in full of all obligations and liabilities owing by Company to the Holder under this Note, the Purchase Agreement and/or any other Related Agreement and/or may elect, in addition to all rights and remedies of the Holder under the Purchase Agreement and the other Related Agreements and all obligations and liabilities of the Company under the Purchase Agreement and the other Related Agreements, to require the Company to make a Default Payment (“Default Payment”). The Default Payment shall be 130% of the outstanding principal amount of the Note, plus accrued but unpaid interest, all other fees then remaining unpaid, and all other amounts payable hereunder. The Default Payment shall be applied first to any fees due and payable to the Holder pursuant to this Note, the Purchase Agreement, and/or the other Related Agreements, then to accrued and unpaid interest due on this Note and then to the outstanding principal balance of this Note. The Default Payment shall be due and payable immediately on the date that the Holder has exercised its rights pursuant to this Section 2.3.
Default Interest; Late Charge Following the occurrence and during the continuance of any Event of Default, and regardless of whether or not the Agent or the Lenders shall have accelerated the maturity of the Loans, all Loans shall bear interest payable on demand at a rate per annum equal to the sum of the Base Rate plus the Applicable Margin plus five percent (5.0%) (the “Default Rate”), until such amount shall be paid in full (after as well as before judgment), and the fee payable with respect to Letters of Credit shall be increased to a rate equal to five percent (5.0%) above the Letter of Credit fee that would otherwise be applicable to such time, or if any of such amounts shall exceed the maximum rate permitted by law, then at the maximum rate permitted by law. In addition, the Borrower shall pay a late charge equal to four percent (4.0%) of any amount of interest and/or principal payable on the Loans or any other amounts payable hereunder or under the other Loan Documents, which is not paid by the Borrower within ten (10) days of the date when due (or, in the case of amounts due at the Revolving Credit Maturity Date or Term Loan Maturity Date, as applicable, within fifteen (15) Business Days of such date).
Investor’s Rights and Remedies Cumulative; Liquidated Damages All rights, remedies, and powers conferred in this Agreement and the Transaction Documents are cumulative and not exclusive of any other rights or remedies, and shall be in addition to every other right, power, and remedy that Investor may have, whether specifically granted in this Agreement or any other Transaction Document, or existing at law, in equity, or by statute, and any and all such rights and remedies may be exercised from time to time and as often and in such order as Investor may deem expedient. The parties acknowledge and agree that upon Company’s failure to comply with the provisions of the Transaction Documents, Investor’s damages would be uncertain and difficult (if not impossible) to accurately estimate because of the parties’ inability to predict future interest rates and future share prices, Investor’s increased risk, and the uncertainty of the availability of a suitable substitute investment opportunity for Investor, among other reasons. Accordingly, any fees, charges, and default interest due under the Note and the other Transaction Documents are intended by the parties to be, and shall be deemed, liquidated damages (under Company’s and Investor’s expectations that any such liquidated damages will tack back to the Closing Date for purposes of determining the holding period under Rule 144 under the 1933 Act). The parties agree that such liquidated damages are a reasonable estimate of Investor’s actual damages and not a penalty, and shall not be deemed in any way to limit any other right or remedy Investor may have hereunder, at law or in equity. The parties acknowledge and agree that under the circumstances existing at the time this Agreement is entered into, such liquidated damages are fair and reasonable and are not penalties. All fees, charges, and default interest provided for in the Transaction Documents are agreed to by the parties to be based upon the obligations and the risks assumed by the parties as of the Closing Date and are consistent with investments of this type. The liquidated damages provisions of the Transaction Documents shall not limit or preclude a party from pursuing any other remedy available at law or in equity; provided, however, that the liquidated damages provided for in the Transaction Documents are intended to be in lieu of actual damages.
Amount and Payment of Special Interest Any Special Interest that accrues on a Note pursuant to Section 7.03(A) will be payable on the same dates and in the same manner as the Stated Interest on such Note and will accrue at a rate per annum equal to one quarter of one percent (0.25%) of the principal amount thereof for the first ninety (90) days on which Special Interest accrues and, thereafter, at a rate per annum equal to one half of one percent (0.50%) of the principal amount thereof; provided, however, that in no event will Special Interest, together with any Additional Interest, accrue on any day on a Note at a combined rate per annum that exceeds one half of one percent (0.50%). For the avoidance of doubt, any Special Interest that accrues on a Note will be in addition to the Stated Interest that accrues on such Note and, subject to the proviso of the immediately preceding sentence, in addition to any Additional Interest that accrues on such Note.
Default Rate and Payment Dates (a) If all or a portion of the principal amount of any Loan which is a LIBOR Rate Loan shall not be paid when due or continued as a LIBOR Rate Loan in accordance with the provisions of Section 2.9 (whether at the stated maturity, by acceleration or otherwise), such overdue principal amount of such Loan shall be converted to an Alternate Base Rate Loan at the end of the Interest Period applicable thereto.
