Documents, Records and Funds in Possession of the Servicer to be Held for the Trustee The Servicer shall transmit to the Trustee or, at the direction of the Trustee, the Custodian as required by this Agreement all documents and instruments in respect of a Mortgage Loan coming into the possession of the Servicer from time to time and shall account fully to the Trustee for any funds received by the Servicer or which otherwise are collected by the Servicer as Liquidation Proceeds or Insurance Proceeds in respect of any Mortgage Loan. The documents constituting the Servicing File shall be held by the Servicer as custodian and bailee for the Trustee. All Mortgage Files and funds collected or held by, or under the control of, the Servicer in respect of any Mortgage Loans, whether from the collection of principal and interest payments or from Liquidation Proceeds, including but not limited to, any funds on deposit in the Servicer Custodial Account, shall be held by the Servicer for and on behalf of the Trustee and shall be and remain the sole and exclusive property of the Trustee, subject to the applicable provisions of this Agreement. The Servicer also agrees that it shall not knowingly create, incur or subject any Mortgage File or any funds that are deposited in the Servicer Custodial Account, Certificate Account or any Escrow Account, or any funds that otherwise are or may become due or payable to the Trustee for the benefit of the Certificateholders, to any claim, lien, security interest, judgment, levy, writ of attachment or other encumbrance created by the Servicer, or assert by legal action or otherwise any claim or right of setoff against any Mortgage File or any funds collected on, or in connection with, a Mortgage Loan, except, however, that the Servicer shall be entitled to set off against and deduct from any such funds any amounts that are properly due and payable to the Servicer under this Agreement.
Transfer or Deletion of Student Data The Provider shall review, on an annual basis, whether the Student Data it has received pursuant to the DPA continues to be needed for the purpose(s) of the Service Agreement and this DPA. If any of the Student Data is no longer needed for purposes of the Service Agreement and this DPA, the Provider will provide written notice to the LEA as to what Student Data is no longer needed. The Provider will delete or transfer Student Data in readable form to the LEA, as directed by the LEA (which may be effectuated through Exhibit D of the DPA), within 30 calendar days if the LEA requests deletion or transfer of the Student Data and shall provide written confirmation to the LEA of such deletion or transfer. Upon termination of the Service Agreement between the Provider and LEA, Provider shall conduct a final review of Student Data within 60 calendar days. If the LEA receives a request from a parent, as that term is defined in 105 ILCS 10/2(g), that Student Data being held by the Provider be deleted, the LEA shall determine whether the requested deletion would violate State and/or federal records laws. In the event such deletion would not violate State or federal records laws, the LEA shall forward the request for deletion to the Provider. The Provider shall comply with the request and delete the Student Data within a reasonable time period after receiving the request. Any provision of Student Data to the LEA from the Provider shall be transmitted in a format readable by the LEA.
Suspension of unsafe Construction Works (i) Upon recommendation of the Authority’s Engineer to this effect, the Authority may by notice require the Contractor to suspend forthwith the whole or any part of the Works if, in the reasonable opinion of the Authority’s Engineer, such work threatens the safety of the Users and pedestrians.
(ii) The Contractor shall, pursuant to the notice under Clause 11.17 (i), suspend the Works or any part thereof for such time and in such manner as may be specified by the Authority and thereupon carry out remedial measures to secure the safety of suspended works, the Users and pedestrians. The Contractor may by notice require the Authority’s Engineer to inspect such remedial measures forthwith and make a report to the Authority recommending whether or not the suspension hereunder may be revoked. Upon receiving the recommendations of the Authority’s Engineer, the Authority shall either revoke such suspension or instruct the Contractor to carry out such other and further remedial measures as may be necessary in the reasonable opinion of the Authority, and the procedure set forth in this Clause 11.17 shall be repeated until the suspension hereunder is revoked.
(iii) Subject to the provisions of Clause 21.6, all reasonable costs incurred for maintaining and protecting the Works or part thereof during the period of suspension (the “Preservation Costs”), shall be borne by the Contractor; provided that if the suspension has occurred as a result of any breach of this Agreement by the Authority, the Preservation Costs shall be borne by the Authority.
(iv) If suspension of Works is for reasons not attributable to the Contractor, the Authority’s Engineer shall determine any Time Extension to which the Contractor is reasonably entitled.
Documents Records and Funds in Possession of Master Servicer to be Held for the Trustee Notwithstanding any other provisions of this Agreement, the Master Servicer shall transmit to the Trustee as required by this Agreement all documents and instruments in respect of a Mortgage Loan coming into the possession of the Master Servicer from time to time and shall account fully to the Trustee for any funds received by the Master Servicer or which otherwise are collected by the Master Servicer as Liquidation Proceeds or Insurance Proceeds in respect of any Mortgage Loan. All Mortgage Files and funds collected or held by, or under the control of, the Master Servicer in respect of any Mortgage Loans, whether from the collection of principal and interest payments or from Liquidation Proceeds, including but not limited to, any funds on deposit in the Certificate Account, shall be held by the Master Servicer for and on behalf of the Trustee and shall be and remain the sole and exclusive property of the Trustee, subject to the applicable provisions of this Agreement. The Master Servicer also agrees that it shall not create, incur or subject any Mortgage File or any funds that are deposited in the Certificate Account, Distribution Account or any Escrow Account, or any funds that otherwise are or may become due or payable to the Trustee for the benefit of the Certificateholders, to any claim, lien, security interest, judgment, levy, writ of attachment or other encumbrance, or assert by legal action or otherwise any claim or right of setoff against any Mortgage File or any funds collected on, or in connection with, a Mortgage Loan, except, however, that the Master Servicer shall be entitled to set off against and deduct from any such funds any amounts that are properly due and payable to the Master Servicer under this Agreement.
Payment for Improvements If payment is made directly to contractors, Tenant shall (i) comply with Landlord's requirements for final lien releases and waivers in connection with Tenant's payment for work to contractors, and (ii) sign Landlord's standard contractor's rules and regulations. If Tenant orders any work directly from Landlord, Tenant shall pay to Landlord an amount equal to five percent of the cost of such work to compensate Landlord for all overhead, general conditions, fees and other costs and expenses arising from Landlord's involvement with such work. If Tenant does not order any work directly from Landlord, Tenant shall reimburse Landlord for Landlord's reasonable, actual, out-of-pocket costs and expenses actually incurred in connection with Landlord's review of such work.
Access to Records; Contractor Financial Records Contractor agrees that District and its authorized representatives are entitled to review all Contractor books, documents, papers, plans, and records, electronic or otherwise (“Records”), directly pertinent to this Contract for the purpose of making audit, examination, excerpts, and transcripts.
Access to List of Holders (a) If the Trustee is not acting as Certificate Registrar, the Certificate Registrar will furnish or cause to be furnished to the Trustee, within fifteen days after receipt by the Certificate Registrar of a request by the Trustee in writing, a list, in such form as the Trustee may reasonably require, of the names and addresses of the Certificateholders of each Class as of the most recent Record Date.
(b) If three or more Holders or Certificate Owners (hereinafter referred to as “Applicants”) apply in writing to the Certificate Registrar, and such application states that the Applicants desire to communicate with other Holders with respect to their rights under this Agreement or under the Certificates and is accompanied by a copy of the communication which such Applicants propose to transmit, then the Certificate Registrar shall, within five Business Days after the receipt of such application, afford such Applicants reasonable access during the normal business hours of the Certificate Registrar to the most recent list of Certificateholders held by the Certificate Registrar or shall, as an alternative, send, at the Applicants’ expense, the written communication proffered by the Applicants to all Certificateholders at their addresses as they appear in the Certificate Register.
(c) Every Holder or Certificate Owner, if the Holder is a Clearing Agency, by receiving and holding a Certificate, agrees with the Depositor, the Master Servicer, the Securities Administrator, the Certificate Registrar and the Trustee that neither the Depositor, the Master Servicer, the Securities Administrator, the Certificate Registrar nor the Trustee shall be held accountable by reason of the disclosure of any such information as to the names and addresses of the Certificateholders hereunder, regardless of the source from which such information was derived.
Software Transfer You may permanently transfer all of your rights under this XXXX, provided you (a) retain no copies, (b) transfer all of the SOFTWARE PRODUCT (including all component parts, the media and printed materials, any upgrades, this XXXX, and, if applicable, the Certificate of Authenticity), and (c) the recipient agrees to abide by all of the terms of this XXXX. If the SOFTWARE PRODUCT is an upgrade, any transfer must include all prior versions of the SOFTWARE PRODUCT and all of your rights therein, if any.
REMOVAL OF RECORDS FROM PREMISES Where performance of the Contract involves use by the Contractor (or the Contractor’s subsidiaries, affiliates, partners, agents or subcontractors) of Authorized User owned or licensed papers, files, computer disks or other electronic storage devices, data or records at Authorized User facilities or offices, or via remote access, the Contractor (or the Contractor’s subsidiaries, affiliates, partners, agents or subcontractors) shall not remotely access, modify, delete, copy or remove such Records without the prior written approval of the Authorized User. In no case, with or without the written approval of the Authorized User, can the Authorized User data be accessed, moved or sent outside the continental United States.
Documents, Records and Funds in Possession of Master Servicer To Be Held for Trustee (a) The Master Servicer shall transmit and each Servicer (to the extent required by the related Servicing Agreement) shall transmit to the Trustee or Custodian such documents and instruments coming into the possession of the Master Servicer or such Servicer from time to time as are required by the terms hereof, or in the case of the Servicers, the applicable Servicing Agreement, to be delivered to the Trustee or Custodian. Any funds received by the Master Servicer or by a Servicer in respect of any Mortgage Loan or which otherwise are collected by the Master Servicer or by a Servicer as Liquidation Proceeds or Insurance Proceeds in respect of any Mortgage Loan shall be held for the benefit of the Trustee and the Certificateholders subject to the Master Servicer's right to retain or withdraw from the Master Servicer Collection Account the Master Servicing Compensation and other amounts provided in this Agreement, and to the right of each Servicer to retain its Servicing Fee and other amounts as provided in the applicable Servicing Agreement. The Master Servicer shall, and (to the extent provided in the applicable Servicing Agreement) shall cause each Servicer to, provide access to information and documentation regarding the Mortgage Loans to the Trustee, its agents and accountants at any time upon reasonable request and during normal business hours, and to Certificateholders that are savings and loan associations, banks or insurance companies, the Office of Thrift Supervision, the FDIC and the supervisory agents and examiners of such Office and Corporation or examiners of any other federal or state banking or insurance regulatory authority if so required by applicable regulations of the Office of Thrift Supervision or other regulatory authority, such access to be afforded without charge but only upon reasonable request in writing and during normal business hours at the offices of the Master Servicer designated by it. In fulfilling such a request the Master Servicer shall not be responsible for determining the sufficiency of such information.
(b) All Mortgage Files and funds collected or held by, or under the control of, the Master Servicer, in respect of any Mortgage Loans, whether from the collection of principal and interest payments or from Liquidation Proceeds or Insurance Proceeds, shall be held by the Master Servicer for and on behalf of the Trustee and the Certificateholders and shall be and remain the sole and exclusive property of the Trustee; provided, however, that the Master Servicer and each Servicer shall be entitled to setoff against, and deduct from, any such funds any amounts that are properly due and payable to the Master Servicer or such Servicer under this Agreement or the applicable Servicing Agreement.
