Certificate of Substantial Completion The Date of Substantial Completion of the Work or designated portion thereof is the Date certified by the City when construction is sufficiently complete, in accordance with the Contract Documents, so the City of Roanoke, Virginia (City or Owner) can occupy or utilize the Work or designated portion thereof for the use for which it is intended, as expressed in the Contract Documents. ITB NO.: PROJECT: CONTRACTOR: PROJECT OR DESIGNATED PORTION SHALL INCLUDE: The Work or portion thereof designated above performed under this Contract has been reviewed and found to be substantially complete. The Date of Substantial Completion of the Project or portion thereof designated above is hereby established as . The City will assume possession thereof at a.m./p.m. on that date. A list of items ("punch list"), prepared by the A/E and/or Director, Department of Public Works, to be completed or corrected by the Contractor, is attached hereto. The failure to include any items on such list does not alter the responsibility of the Contractor to complete all Work in accordance with the Contract Documents. The Contractor will complete any portion of the Work that is not substantially complete and will complete or correct the work on the punch list in accordance with the Contract Documents. The establishment of a date of substantial completion and/or the acceptance of the Work or designated portion thereof does not relieve the Contractor of any responsibility for any faulty materials or workmanship or operate to relieve the Contractor or its Surety from any obligation under the Contract with the City or the Performance Bond or Labor and Material Payment Bond. This Certificate is subject to the terms and conditions of the Contract Documents, including but not limited to Section 20.8 of the General Conditions. Contractor By Date City of Roanoke, Virginia City By Date CITY OF ROANOKE, VIRGINIA AFFIDAVIT OF PAYMENT OF CLAIMS By: This day personally appeared before me, , and, being by me first duly sworn states that all subcontractors and suppliers of labor and materials have been paid all sums due them for work performed or materials furnished in the performance of the Contract between the City of Roanoke, Virginia, and ,Contractor, dated , 20 , for or arrangements have been made by the Contractor satisfactory to such subcontractors and suppliers with respect to the payment of such sums as may be due from the Contractor to the subcontractors and suppliers. COMMONWEALTH OF VIRGINIA CITY/COUNTY OF I, , a Notary Public in and for the Commonwealth of Virginia, do hereby certify that , whose name is signed to the foregoing, has subscribed, sworn to and acknowledged the same before me this day of , 20 . Seal: Notary Public Registration #: My Commission Expires:
Step Four If the decision of the President/Superintendent is not satisfactory to the grievant or no decision is rendered, CRFO may, within fifteen days of receipt of the notification of the decision, submit a request for arbitration. The grievance, including but not limited to disputes over procedural or substantive arbitrability, shall then be submitted to an arbitrator for advisory determination.
9.4.4.1 Within five days of receiving the request for arbitration, CRFO and the District will first attempt to agree upon an arbitrator. If no agreement is reached, the parties shall request the State Conciliation Service to supply a panel of seven names of persons experienced in hearing grievances in public education. Each party will alternately strike a name until only one name remains. That person will be the arbitrator. The order of striking will be by lot. Upon mutual agreement, the list of arbitrators may be obtained from the American Arbitration Association.
9.4.4.2 CRFO and the District shall each bear their own costs associated with representation at any step in the grievance procedure, except for the costs of the arbitrator. CRFO and the District shall share equally the costs of the arbitrator’s fees and expenses and any costs for a court reporter and transcript.
9.4.4.3 As soon as possible after the arbitrator’s selection, the arbitrator shall conduct a hearing into the matter and render written findings of fact and conclusions on all the issues submitted. If the parties cannot agree upon a submission agreement, the arbitrator shall determine the issues by referring to the written grievance and the answers at each step. After the hearing both parties will have an opportunity to submit written briefs.
9.4.4.4 The arbitrator will have no power to alter, amend, add to, subtract from, or disregard any of the terms of this agreement but will recommend only if there has been a violation of this agreement. The arbitrator will be without power or authority to make any recommendation that requires the commission of an act prohibited by law or that violates the terms of this agreement.
9.4.4.5 The findings of fact and the recommendation of the arbitrator will be advisory to the Board of Trustees, which will make the final determination. Upon review of the record, if the Board of Trustees is unable to render a final determination on the record, the Board may reopen the record for the taking of additional evidence and may adopt its own written findings of fact and conclusions.
Substantial Completion 9.8.1 When the Contractor considers that the Work, or a designated portion thereof which has been accepted in writing to by the State, is substantially complete as defined in Subparagraph
Certificate of Completion The Interconnection Customer shall provide the EDC with a completed copy of the Interconnection Agreement Certificate of Completion, including evidence of the electrical inspection performed by the local authority having jurisdiction. The evidence of completion of the electrical inspection may be provided on inspection forms used by local inspecting authorities. The Interconnection request shall not be finally approved until the EDC’s representative signs the Interconnection Agreement Certificate of Completion.
Partial Destruction If the Premises or the Building are damaged by fire or other casualty to an extent not exceeding twenty-five percent (25%) of the full replacement cost thereof, and Landlord’s contractor reasonably estimates in a writing delivered to Landlord and Tenant that the damage thereto may be repaired, reconstructed or restored to substantially its condition immediately prior to such damage within one hundred eighty (180) days from the date of such casualty, and Landlord will receive insurance proceeds sufficient to cover the costs of such repairs, reconstruction and restoration (including proceeds from Tenant and/or Tenant’s insurance which Tenant is required to deliver to Landlord pursuant to Subparagraph 20(d) below to cover Tenant’s obligation for the costs of repair, reconstruction and restoration of any portion of the tenant improvements and any alterations for which Tenant is responsible under this Lease), then Landlord agrees to commence and proceed diligently with the work of repair, reconstruction and restoration and this Lease will continue in full force and effect.
Construction Completion The related Construction shall have been completed substantially in accordance with the related Plans and Specifications, the related Deed and all Applicable Laws, and such Leased Property shall be ready for occupancy and operation. All fixtures, equipment and other property contemplated under the Plans and Specifications to be incorporated into or installed in such Leased Property shall have been substantially incorporated or installed, free and clear of all Liens except for Permitted Liens.
EFFECTIVE DATE OF CONTRACT This contract shall not become effective until and unless approved by the City of Nashua.
Level Four A. If within ten (10) school days following the formal third step the Association submits a request to the Superintendent to enter into arbitration, the Superintendent and the Association shall attempt to agree upon a mutually acceptable arbitrator and shall obtain a commitment from said arbitrator to serve. If the parties are unable to agree upon an arbitrator or to obtain such a commitment within ten (10) school days, a written request for a list of arbitrators shall be made to the Public Employment Relations Board (PERB) by either party. The list shall consist of seven (7) potential arbitrators and the parties shall determine by lot which party shall have the right to remove the first name from the list. The party having the right to remove the first name shall do so within two (2) school days. Then the parties shall have one (1) school day alternately to remove until one (1) name remains. The person whose name remains shall be the arbitrator.
B. The arbitrator so selected shall confer with the Superintendent and the Association and hold hearings promptly and shall issue his/her decision not later than fifteen (15) school days from the date of the close of the hearings, or, if oral hearings have been waived, then from the date the final statements and proofs on the issues are submitted to him/her. The arbitrator's decision shall be in writing and shall set forth his/her findings of fact, reasoning, and conclusions of the issues submitted. The arbitrator's decision shall have no power to alter, add to, or detract from the specific provisions of the Agreement. No decision of the arbitrator shall in any way be derogation of the powers, duties, and rights established in the Board by constitutional provisions, statue, ordinance, or special legislative acts. The decision of the arbitrator shall be submitted to the Superintendent and the Association and shall be final and binding on the parties.
C. The costs of the services of the arbitrator will be borne equally by the Board and the Association.
D. If the grievant files any claim or complaint in any forum other than under the grievance procedure of this Master Contract Agreement, then the school district shall not be required to process the same claim or set of facts through this grievance procedure.
On Completion the Seller shall deliver to the Buyer:
(a) a completed and signed transfer of the Sale Shares to the Buyer or as it directs and the related share certificate;
(b) a power of attorney in agreed form appointing the Buyer as attorney pending the Buyer’s registration as a member of the Company with power on the Seller’s behalf to execute and deliver all deeds and documents and to do all acts and things and exercise all rights which the Buyer would be entitled to execute, deliver and do and exercise if the Buyer was registered as the holder of the Sale Shares with power to sub-delegate this power and power to appoint a substitute attorney in addition to the Buyer;
(c) the statutory books of each Group Company (including any separate sheet minutes in respect of the Subsidiary, if applicable) complete and accurate up to Completion and any company seal(s), certificates of incorporation, certificates of incorporation on change of name and all share certificates of each Group Company;
(d) a signed deed addressed by the Seller to the Buyer and to the Company and all Group Companies acknowledging that there is no outstanding indebtedness owing at Completion from any Group Company to the Seller or to any Seller’s Associate or vice versa;
(e) letters of resignation in agreed form from each director of each Group Company and the secretary of each Group Company (if any);
(f) a letter, in agreed form, from the Seller confirming that upon Completion it has ceased to be a registrable relevant legal entity (within the meaning of section 790C of the Companies Act 2006) in relation to the Company;
(g) the Disclosure Letter;
(h) the consultancy agreement in the agreed form between the Company and Xxxxxxx Xxxxxxx signed by the parties;
(i) deeds of release in the agreed form between each of the employees of the Group Companies previously granted share awards by the Seller and the Seller in relation to the provision of such share awards in the Seller;
(j) earn-in letter agreements in the agreed form executed by certain of the employees of the Group Companies (as determined by the Buyer) in relation to the potential issue of additional shares in Xxxxxxxx.xxx Limited to such persons;
(k) an intellectual property assignment in the agreed form from the Seller in favour of the Company;
(l) an intellectual property assignment in the agreed from XXXX00.Xxx Limited (UK) in favour of the Company; and
(m) a settlement agreement in the agreed form duly executed by Xxxxxx Xxxxxx (together with the associated advisers certificate) dated at least one Business Day prior to the date of the assignments referred to at clauses 6.2(k) and (I) above.
Effective Date of this Section Notwithstanding any other provision of this Agreement, the Proprietary Information provisions of this Agreement shall apply to all information furnished by either Party to the other in furtherance of the purpose of this Agreement, even if furnished before the Effective Date.
