Indemnification and Defense 16.1 To the fullest extent permitted by California law, Developer shall indemnify, keep and hold harmless the District, the Architect(s) and Construction Manager(s), their respective consultants, separate contractors, board members, officers, representatives, agents, and employees, in both individual and official capacities (“Indemnitees”), against all suits, claims, injury, damages, losses, and expenses (“Claims”), including but not limited to attorney’s fees and costs, caused by, arising out of, resulting from, or incidental to, in whole or in part, the performance of the Work under this Contract by Developer or its Subcontractors, vendors and/or suppliers. However, Developer’s indemnification and hold harmless obligation shall be reduced by the proportion of the Indemnitees’ and/or Architect’s liability to the extent the Claim(s) is/are caused wholly by the active negligence or willful misconduct of the Indemnitees, and/or defects in design furnished by the Architect, as found by a court or arbitrator of competent jurisdiction. This indemnification and hold harmless obligation of Developer shall not be construed to negate, abridge, or otherwise reduce any right or obligation of indemnity that would otherwise exist or arise as to any Indemnitee or other person described herein. This indemnification and hold harmless obligation includes, but is not limited to, any failure or alleged failure by Developer to comply with any law and/or provision of the Contract Documents in strict accordance with their terms, and without limitation, any failure or alleged failure of Developers obligations regarding any stop payment notice actions or liens, including Civil Wage and Penalty Assessments and/or Orders by the DIR.
16.2 To the furthest extent permitted by California law, Developer shall also defend Indemnitees, at its own expense, including but not limited to attorneys’ fees and costs, against all Claims caused by, arising out of, resulting from, or incidental to, in whole or in part, the performance of the Work under this Facilities Lease by Developer, its Subcontractors, vendors, or suppliers. However, without impacting Developer’s obligation to provide an immediate and ongoing defense of Indemnitees, Developer’s defense obligation shall be reduced by the proportion of the Indemnitees’ and/or Architect’s liability to the extent caused by the sole negligence, active negligence, or willful misconduct of the Indemnitees, and/or defects in design furnished by the Architect, as found by a court or arbitrator of competent jurisdiction. The District shall have the right to accept or reject any legal representation that Xxxxxxxxx proposes to defend the Indemnitees. If any Indemnitee provides its own defense due to failure to timely respond to tender of defense, rejection of tender of defense, or conflict of interest of proposed counsel, Developer shall reimburse such Indemnitee for any expenditures. Developer’s defense obligation shall not be construed to negate, abridge, or otherwise reduce any right or obligation of defense that would otherwise exist as to any Indemnitee or other person described herein. Developer’s defense obligation includes, but is not limited to, any failure or alleged failure by Developer to comply with any provision of law, any failure or alleged failure to timely and properly fulfill all of its obligations under the Contract Documents in strict accordance with their terms, and without limitation, any failure or alleged failure of Developer’s obligations regarding any stop payment notice actions or liens, including Civil Wage and Penalty Assessments and/or Orders by the DIR. Developer shall give prompt notice to the District in the event of any Claim(s).
16.3 Without limitation of the provisions herein, if Xxxxxxxxx’s obligation to indemnify and hold harmless the Indemnitees or its obligation to defend Indemnitees as provided herein shall be determined to be void or unenforceable, in whole or in part, it is the intention of the Parties that these circumstances shall not otherwise affect the validity or enforceability of Developer’s agreement to indemnify, defend, and hold harmless the rest of the Indemnitees, as provided herein. Further, Developer shall be and remain fully liable on its agreements and obligations herein to the fullest extent permitted by law.
Defense and Indemnification 12.1 Consultant agrees to indemnify, defend (with attorneys approved by City), and hold harmless the City, and its officers, officials, agents and employees (the “Indemnified Parties”) from any and all claims, demands, costs or liability that arise out of, or pertain to, or relate to the Consultant, its employees, agents, and subcontractors performance of services under this Agreement. Consultant’s duty to indemnify under this section shall not include liability for damages for death or bodily injury to persons, injury to property, or other loss, damage or expense arising from the sole negligence or willful misconduct by the City or its elected officials, officers, agents, and employees. Consultant's indemnification obligations shall not be limited by the insurance provisions of this Agreement. The Parties expressly agree that any payment, attorney's fees, costs or expense City incurs or makes to or on behalf of an injured employee under the City's self-administered workers' compensation is included as a loss, expense, or cost for the purposes of this section, and that this section will survive the expiration or early termination of this Agreement.
12.2 This indemnity is in addition to any other rights or remedies which City may have under the law or this Agreement. In the event of any claim or demand made against any party which is entitled to be indemnified hereunder, City may, at its sole discretion, reserve, retain or apply any monies due to Consultant under this Agreement for the purpose of resolving such claims; provided however, that City may release such funds if Consultant provides City with reasonable assurances of protection of the City's interest. The City shall, in its sole discretion determine whether such assurances are reasonable.
12.3 Consultant agrees that its duty to defend arises upon an allegation of liability based upon the performance of services under this Agreement by Consultant, its officers, agents, representatives, employees, sub-consultants, or anyone for whom Consultant is liable and that an adjudication of Consultant’s liability is not a condition precedent to Consultant's duty to defend.
Indemnification Claims An Indemnified Party shall give written notification to the Indemnifying Party of the commencement of any Third Party Action. Such notification shall be given within 20 days after receipt by the Indemnified Party of notice of such Third Party Action, and shall describe in reasonable detail (to the extent known by the Indemnified Party) the facts constituting the basis for such Third Party Action and the amount of the claimed damages; provided, however, that no delay or failure on the part of the Indemnified Party in so notifying the Indemnifying Party shall relieve the Indemnifying Party of any liability or obligation hereunder except to the extent of any damage or liability caused by or arising out of such failure. Within 20 days after delivery of such notification, the Indemnifying Party may, upon written notice thereof to the Indemnified Party, assume control of the defense of such Third Party Action with counsel reasonably satisfactory to the Indemnified Party; provided that the Indemnifying Party may not assume control of the defense of Third Party Action involving criminal liability or in which equitable relief is sought against the Indemnified Party. If the Indemnifying Party does not, or is not permitted under the terms hereof to, so assume control of the defense of a Third Party Action, the Indemnified Party shall control such defense. The Non-controlling Party may participate in such defense at its own expense. The Controlling Party shall keep the Non-controlling Party advised of the status of such Third Party Action and the defense thereof and shall consider in good faith recommendations made by the Non-controlling Party with respect thereto. The Non-controlling Party shall promptly furnish the Controlling Party with such information as it may have or receive with respect to such Third Party Action (including copies of any summons, complaint or other pleading which may have been served on such party and any written claim, demand, invoice, billing or other document evidencing or asserting the same) and shall otherwise cooperate with and assist the Controlling Party in the defense of such Third Party Action. The fees and expenses of counsel to the Indemnified Party with respect to a Third Party Action shall be considered Damages for purposes of this Agreement if (x) the Indemnified Party controls the defense of such Third Party Action pursuant to the terms of this Section 5.3 or (y) the Indemnifying Party assumes control of such defense and the Indemnified Party reasonably concludes that the Indemnifying Party and the Indemnified Party have conflicting interests with respect to such Third Party Action. The Indemnifying Party shall not agree to any settlement of, or the entry of any judgment arising from, any Third Party Action without the prior written consent of the Indemnified Party, which shall not be unreasonably withheld, conditioned or delayed. The Indemnified Party shall not agree to any settlement of, or the entry of any judgment arising from, any such Third Party Action without the prior written consent of the Indemnifying Party, which shall not be unreasonably withheld, conditioned or delayed.
Indemnity Obligations (a) Parent shall indemnify and hold harmless SpinCo from and against, and will reimburse SpinCo for, (i) all liability for Taxes allocated to Parent pursuant to Article II, (ii) all Tax Related Costs and Expenses allocated to Parent pursuant to Section 6.7, (iii) all Taxes, Tax Related Costs and Expenses and Tax Related Losses (without duplication) to the extent arising out of, based upon, or relating or attributable to any breach of or inaccuracy in, or failure to perform, as applicable, any representation, covenant or obligation of any member of the Parent Group pursuant to this Agreement and (iv) the amount of any Refund received by any member of the Parent Group that is allocated to SpinCo pursuant to Section 2.5(a).
(b) Without regard to whether a Post-Distribution Ruling or an Unqualified Tax Opinion may have been provided or whether any action is permitted or consented to hereunder and notwithstanding anything to the contrary in this Agreement, SpinCo shall indemnify and hold harmless Parent from and against, and will reimburse Parent for, (i) all liability for Taxes allocated to SpinCo pursuant to Article II, (ii) all Tax Related Costs and Expenses allocated to SpinCo pursuant to Section 6.7, (iii) all liability for Taxes, Tax Related Costs and Expenses and Tax Related Losses (without duplication) arising out of, based upon, or relating or attributable to any breach of or inaccuracy in, or failure to perform, as applicable, any representation, covenant or obligation of any member of the SpinCo Group pursuant to this Agreement, (iv) the amount of any Refund received by any member of the SpinCo Group that is allocated to Parent pursuant to Section 2.5(a) and (v) any Distribution Taxes and Tax Related Losses attributable to a Prohibited Act, or otherwise attributable to a SpinCo Disqualifying Action (regardless of whether the conditions set forth in Section 4.2(c) are satisfied). To the extent that any Tax, Tax Related Costs and Expenses or Tax Related Loss is subject to indemnity pursuant to both Section 5.1(a) and Section 5.1(b), responsibility for such Tax, Tax Related Costs and Expenses or Tax Related Loss shall be shared by Parent and SpinCo according to relative fault as determined by Parent in its sole and absolute discretion. The amount of any liability for Taxes which are indemnifiable pursuant to this Section 5.1(b)(iii) and (v) shall be determined, in Parent’s sole and absolute discretion, without regard to any Tax Attributes of the Parent Group or the Parent Business.
Survival of Indemnification Obligations The provisions of this Article 13 shall survive the expiration or termination of this Agreement.
Indemnification Obligations Subject to the limitations set forth in this Agreement, each Fund severally and not jointly agrees to indemnify and hold harmless the Custodian and its nominees from all loss, damage and expense (including reasonable attorneys' fees) suffered or incurred by the Custodian or its nominee caused by or arising from actions taken by the Custodian on behalf of such Fund in the performance of its duties and obligations under this Agreement; provided however, that such indemnity shall not apply to loss, damage and expense occasioned by or resulting from the negligence, misfeasance or misconduct of the Custodian or its nominee. In addition, each Fund agrees severally and not jointly to indemnify any Person against any liability incurred by reason of taxes assessed to such Person, or other loss, damage or expenses incurred by such Person, resulting from the fact that securities and other property of such Fund's Portfolios are registered in the name of such Person; provided however, that in no event shall such indemnification be applicable to income, franchise or similar taxes which may be imposed or assessed against any Person.
Review of Indemnification Obligations (i) Notwithstanding the foregoing, in the event any Reviewing Party shall have determined (in a written opinion, in any case in which Independent Legal Counsel is the Reviewing Party) that Indemnitee is not entitled to be indemnified, exonerated or held harmless hereunder under applicable law, (A) the Company shall have no further obligation under Section 2(a) to make any payments to Indemnitee not made prior to such determination by such Reviewing Party and (B) the Company shall be entitled to be reimbursed by Indemnitee (who hereby agrees to reimburse the Company) for all Expenses theretofore paid in indemnifying, exonerating or holding harmless Indemnitee (within thirty (30) days after such determination); provided, however, that if Indemnitee has commenced or thereafter commences legal proceedings in a court of competent jurisdiction to secure a determination that Indemnitee is entitled to be indemnified, exonerated or held harmless hereunder under applicable law, any determination made by any Reviewing Party that Indemnitee is not entitled to be indemnified hereunder under applicable law shall not be binding and Indemnitee shall not be required to reimburse the Company for any Expenses theretofore paid in indemnifying, exonerating or holding harmless Indemnitee until a final judicial determination is made with respect thereto (as to which all rights of appeal therefrom have been exhausted or lapsed). Indemnitee’s obligation to reimburse the Company for any Expenses shall be unsecured and no interest shall be charged thereon.
(ii) Subject to Section 2(b)(iii) below, if the Reviewing Party shall not have made a determination within forty-five (45) days after receipt by the Company of the request therefor, the requisite determination of entitlement to indemnification shall, to the fullest extent not prohibited by law, be deemed to have been made and Indemnitee shall be entitled to such indemnification, absent (A) a misstatement by Indemnitee of a material fact, or an omission of a material fact necessary to make Indemnitee’s statement not materially misleading, in connection with the request for indemnification or (B) a prohibition of such indemnification under applicable law; provided, however, that such 45-day period may be extended for a reasonable time, not to exceed an additional thirty (30) days, if the person, persons or entity making the determination with respect to entitlement to indemnification in good faith requires such additional time for the obtaining or evaluating of documentation and/or information relating thereto.
(iii) Notwithstanding anything in this Agreement to the contrary, no determination as to entitlement of Indemnitee to indemnification under this Agreement shall be required to be made prior to the final disposition of the Claim.
Limitations on Indemnification Obligations The rights of the Indemnified Parties to indemnification pursuant to the provisions of Section 7.2(a) and Section 7.2(b) are subject to the following provisions:
(a) None of the Indemnified Parties shall be entitled to recover for any particular Loss pursuant to Section 7.2(a)(i) or Section 7.2(b)(i) (except in the case of Fraud) unless such Loss equals or exceeds $10,000 (and no such Loss less than $10,000 shall be applied against the Deductible).
(b) The Indemnified Parties shall not be entitled to recover Losses pursuant to Section 7.2(a)(i) or Section 7.2(b)(i) (except in the case of Fraud) until the total amount which the Indemnified Parties would recover under Section 7.2(a)(i) or Section 7.2(b)(i), as applicable, in the aggregate (as limited by the other provisions hereof), but for this Section 7.4(b), exceeds $1,192,500 (the “Deductible”), in which case the applicable Indemnified Parties shall only be entitled to recover Losses in excess of such amount, subject to the other limitations herein.
(c) Except, in each case, in the case of Fraud, (i) the maximum liability of Seller to the Purchaser Indemnitees with respect to any Losses of the Purchaser Indemnitees indemnifiable pursuant to Section 7.2(a)(i) shall not exceed $1,192,500 and (ii) the maximum liability of Seller or Purchaser, as applicable, for indemnifiable Losses pursuant to this Article VII shall not exceed the Aggregate Purchase Price.
(d) The amount of any and all Losses indemnifiable hereunder shall be determined net of any amounts actually recovered by the Indemnified Parties under insurance policies (excluding, in the case of the Purchaser Indemnitees, the Representation and Warranty Insurance Policy) or other collateral sources (such as contractual indemnities of any Person which are contained outside of this Agreement) with respect to such Losses (which amounts actually recovered by the Indemnified Parties shall be calculated, in each case, net of any reasonable out-of-pocket costs and any Taxes incurred in connection with such recovery). In any case where a Purchaser Indemnitee actually recovers, under insurance policies (excluding, in the case of the Purchaser Indemnitees, the Representation and Warranty Insurance Policy) or from other collateral sources, any amount in respect of a matter for which such Indemnified Party was previously indemnified hereunder, such Indemnified Party shall promptly pay over to the Responsible Party a refund equal to the amount so recovered (after deducting therefrom the amount of the reasonable out-of-pocket costs and expenses and any Taxes incurred in connection with such recovery), if and solely to the extent that such amount of recovery would have reduced the amount to which the Indemnified Party would have been entitled pursuant to the first sentence of this Section 7.4(d), but not in excess of the aggregate amount previously paid to the Indemnified Parties hereunder in respect of such matter.
(e) The Purchaser Indemnitees shall use commercially reasonable efforts to recover under the Representation and Warranty Insurance Policy, to the extent available and subject to applicable retention and other coverage limitations thereunder, for any Losses for Indemnified Taxes pursuant to Section 7.2(a)(iv) or for any Losses pursuant to Section 7.2(a)(ii) prior to seeking indemnification from Seller under this Agreement; provided that nothing in this Section 7.4(e) shall limit the Purchaser Indemnitees’ rights to indemnification pursuant to Section 7.2(a)(iv) or pursuant to Section 7.2(a)(ii) to the extent that recovery is not available under the Representation and Warranty Insurance Policy for any reason with respect to all or any portion of such Losses. The amount of any and all indemnifiable Losses for Indemnified Taxes pursuant to Section 7.2(a)(iv) or for any indemnifiable Losses pursuant to Section 7.2(a)(ii) shall be determined net of any amounts actually recovered by the Indemnified Parties under the Representation and Warranty Insurance Policy with respect to such Losses (which amounts actually recovered by the Indemnified Parties shall be calculated, in each case, net of any reasonable out-of-pocket costs and any Taxes incurred in connection with such recovery). In any case where a Purchaser Indemnitee actually recovers under the Representation and Warranty Insurance Policy any amount in respect of a matter for which such Indemnified Party was previously indemnified hereunder, such Indemnified Party shall promptly pay over to the Responsible Party a refund equal to the amount so recovered (after deducting therefrom the amount of the reasonable out-of-pocket costs and expenses and any Taxes incurred in connection with such recovery), if and solely to the extent that such amount of recovery would have reduced the amount to which the Indemnified Party would have been entitled pursuant to the first sentence of this Section 7.4(e), but not in excess of the aggregate amount previously paid to the Indemnified Parties hereunder in respect of such matter; provided that for the avoidance of doubt, Purchaser shall not be required to repay to Seller any amounts recovered under the Representation and Warranty Insurance Policy to the extent such repayment would, after taking into account the deductible and other limitations under the Representation and Warranty Insurance Policy, have the effect of reducing the amount of indemnifiable Losses actually recovered by Purchaser with respect to such claim below the amount of indemnified Losses to which Purchaser would otherwise be entitled to recover from Seller pursuant to this Article VII, but for this Section 7.4(e). Purchaser covenants and agrees that the Representation and Warranty Insurance Policy will expressly exclude any right of subrogation against the Seller Group (other than with respect to Fraud).
(f) The Indemnified Parties shall be entitled to recover for a Loss only once under Article VII even if a claim or claims for indemnification in respect of such Loss has been made as a result of a breach of more than one representation, warranty, covenant or agreement contained in this Agreement.
(g) The Indemnified Parties shall not be entitled to recover any Loss to the extent such Loss was included in or otherwise expressly taken into account in the determination of the Aggregate Purchase Price.
(h) The rights to indemnification of the Indemnified Parties under this Article VII shall not be affected or deemed waived by reason of any investigation made by or on behalf of any party hereto (including by any of such party’s advisors or representatives) or by reason of the fact that such party or any of such advisors or representatives knew or should have known that any representation or warranty is, was or might be inaccurate.
(i) For purposes of determining the breach or inaccuracy of any representation or warranty of the Company set forth in Article III or the Seller set forth in Article IV and in calculating the amount of any Losses attributable thereto, any “materiality,” “Material Adverse Effect,” or similar qualifications in such representations and warranties shall be disregarded, except that the foregoing shall not apply to (i) the use of the term “Material Contract” in any representation or warranty or (ii) any representation or warranty set forth in Section 3.4(a) or Section 3.6(a).
(j) The Purchaser Indemnitees shall only be entitled to recover under this Article VII for any breach of any representations and warranties regarding Losses for Taxes with respect to taxable periods, or portions thereof, that end on or before the Closing Date, except to the extent such Losses arise from or are attributable to a breach of the representations or warranties contained in Sections 3.15(e), 3.15(k) or 3.15(l).
Seller’s Indemnification Obligations Seller shall, on the date of Closing, agree (and, upon delivery to Purchaser of the Assignments, shall be deemed to have agreed), subject to the limitations and procedures contained in this Article 9, following the Closing, to indemnify and hold Purchaser, its Affiliates and its and their respective successors and permitted assigns and all of their respective stockholders, partners, members, managers, directors, officer, employees, agents and representatives (collectively, the “Purchaser Indemnitees”) harmless from and against any and all claims, obligations, actions, liabilities, damages or expenses (collectively, “Purchaser’s Losses”) incurred, suffered, paid by or resulting to any of the Purchaser Indemnitees and which results from, arises out of or in connection with, is based upon, or exists by reason of: (a) any breach of any representation, warranty, covenant or agreement of Seller contained in this Agreement (in each case without regard to materiality or any qualification as to Material Adverse Effect), (b) Seller’s non-compliance with Applicable Laws or agreements in respect of the Properties prior to the Closing, (c) all Property Costs incurred prior to the Effective Date (including with regard to joint interest xxxxxxxx by Seller and any participating party’s payments in respect thereof), (d) all costs and expenses incurred by Purchaser associated with the plugging and abandoning of each Abandoned Well pursuant to Section 7.13 or (e) the Excluded Assets; REGARDLESS OF THE NEGLIGENCE, STRICT LIABILITY OR OTHER FAULT OR RESPONSIBILITY OF PURCHASER, ANY OTHER PURCHASER INDEMNITEE, SELLER OR ANY OTHER PERSON. Notwithstanding any other provision of this Agreement, (i) the maximum liability of Seller under the indemnity provisions of Article 9 or under any other provisions of this Agreement, in either case for a breach of any representation or warranty other than the Seller Transaction Representations and Section 4.1(i), shall not exceed ten percent (10%) of the Purchase Price and (ii) Seller shall have no liability under the indemnity provisions of this Section 9.5 by reason of any breach of any representation or warranty (other than the Seller Transaction Representations and Section 4.1(i)) until and unless the aggregate amount of the liability for all Purchaser Losses associated therewith exceeds ONE MILLION Dollars ($1,000,000), in which event Seller shall be liable for the amount of all Purchaser Losses, but in no event to exceed ten percent (10%) of the Purchase Price. Seller agrees that any amounts owing to Purchaser under this Agreement may be set off against and withheld from any amounts owing to Seller in respect of its interest under the Farmout Agreement.
Liability Exculpation and Indemnification Liability. Except as otherwise provided by the Act, all debts, obligations and liabilities of the Company (including, without limitation, under a judgment, decree or order of a court), whether arising in contract, tort or otherwise, shall be solely the debts, obligations and liabilities of the Company, and no Covered Person shall be obligated personally for any such debt, obligation or liability of the Company solely by reason of being a Covered Person. Exculpation. No Covered Person shall be liable to the Company or any other Covered Person for any loss, damage or claim incurred by reason of any act or omission performed or omitted by such Covered Person in good faith on behalf of the Company and in a manner believed to be within the scope of authority conferred on such Covered Person by this Agreement, except that a Covered Person shall be liable for any such loss, damage or claim incurred by reason of such Covered Person’s gross negligence, willful misconduct or willful breach of this Agreement.
