Dangerous Goods You warrant that the Goods do not include any firearms or goods which are or may become of a dangerous, corrosive, highly combustible, explosive, damaging or noxious nature nor likely to encourage any vermin or pest unless You have disclosed to Us in writing the presence and nature of any such items prior to them being made available to Us for loading or storage. We may refuse to remove or store such items. If We discover any article or substance of this nature after the Goods have been received by Us, We may take any reasonable action, including destruction or disposal, as We may think fit without incurring any liability to You.
Indemnification Procedures for Non-Third Party Claims In the event any Indemnified Party should have an indemnification claim against the Shareholder under this Agreement that does not involve a claim by a third party, the Indemnified Party shall promptly deliver notice of such claim to the Shareholder in writing and in reasonable detail. The failure by any Indemnified Party to so notify the Shareholder shall not relieve the Shareholder from any liability that it may have to such Indemnified Party, except to the extent that the Shareholder has been actually prejudiced by such failure. If the Shareholder does not notify the Indemnified Party within fifteen (15) Business Days following its receipt of such notice that the Shareholder disputes such claim, such claim specified by the Shareholder in such notice shall be conclusively deemed a liability of the Shareholder under this Article VII and the Shareholder shall pay the amount of such liability to the Indemnified Party on demand, or in the case of any notice in which the amount of the claim is estimated, on such later date when the amount of such claim is finally determined. If the Shareholder disputes its liability with respect to such claim in a timely manner, Shareholder and the Indemnified Party shall proceed in good faith to negotiate a resolution of such dispute and, if not resolved through negotiations, such dispute shall be submitted to arbitration pursuant to Section 9.9.
Standard of Care; Indemnification; Limitation of Liability A. USBFS shall exercise reasonable care in the performance of its duties under this Agreement. Neither USBFS nor its suppliers shall be liable for any error of judgment or mistake of law or for any loss suffered by the Trust or any third party in connection with its duties under this Agreement, including losses resulting from mechanical breakdowns or the failure of communication or power supplies beyond USBFS’s control, except a loss arising out of or relating to USBFS’s refusal or failure to comply with the terms of this Agreement or from its bad faith, negligence, or willful misconduct in the performance of its duties under this Agreement. Notwithstanding any other provision of this Agreement, if USBFS has exercised reasonable care in the performance of its duties under this Agreement, the Trust shall indemnify and hold harmless USBFS and its suppliers from and against any and all claims, demands, losses, expenses, and liabilities of any and every nature (including reasonable attorneys’ fees) that USBFS or its suppliers may sustain or incur or that may be asserted against USBFS or its suppliers by any person arising out of or related to (X) any action taken or omitted to be taken by it in performing the services hereunder (i) in accordance with the foregoing standards, or (ii) in reliance upon any written or oral instruction provided to USBFS by any duly authorized officer of the Trust, as approved by the Board of Trustees of the Trust, or (Y) the Data, or any information, service, report, analysis or publication derived therefrom, except for any and all claims, demands, losses, expenses, and liabilities arising out of or relating to USBFS’s refusal or failure to comply with the terms of this Agreement or from its bad faith, negligence or willful misconduct in the performance of its duties under this Agreement. This indemnity shall be a continuing obligation of the Trust, its successors and assigns, notwithstanding the termination of this Agreement. As used in this paragraph, the term “USBFS” shall include USBFS’s directors, officers and employees. The Trust acknowledges that the Data are intended for use as an aid to institutional investors, registered brokers or professionals of similar sophistication in making informed judgments concerning securities. The Trust accepts responsibility for, and acknowledges it exercises its own independent judgment in, its selection of the Data, its selection of the use or intended use of such, and any results obtained. Nothing contained herein shall be deemed to be a waiver of any rights existing under applicable law for the protection of investors. USBFS shall indemnify and hold the Trust harmless from and against any and all claims, demands, losses, expenses, and liabilities of any and every nature (including reasonable attorneys' fees) that the Trust may sustain or incur or that may be asserted against the Trust by any person arising out of any action taken or omitted to be taken by USBFS as a result of USBFS’s refusal or failure to comply with the terms of this Agreement, or from its bad faith, negligence, or willful misconduct in the performance of its duties under this Agreement. This indemnity shall be a continuing obligation of USBFS, its successors and assigns, notwithstanding the termination of this Agreement. As used in this paragraph, the term “Trust” shall include the Trust’s directors, officers and employees. In the event of a mechanical breakdown or failure of communication or power supplies beyond its control, USBFS shall take all reasonable steps to minimize service interruptions for any period that such interruption continues. USBFS will make every reasonable effort to restore any lost or damaged data and correct any errors resulting from such a breakdown at the expense of USBFS. USBFS agrees that it shall, at all times, have reasonable contingency plans with appropriate parties, making reasonable provision for emergency use of electrical data processing equipment to the extent appropriate equipment is available. Representatives of the Trust shall be entitled to inspect USBFS’s premises and operating capabilities at any time during regular business hours of USBFS, upon reasonable notice to USBFS. Moreover, USBFS shall provide the Trust, at such times as the Trust may reasonably require, copies of reports rendered by independent accountants on the internal controls and procedures of USBFS relating to the services provided by USBFS under this Agreement. Notwithstanding the above, USBFS reserves the right to reprocess and correct administrative errors at its own expense. In no case shall either party be liable to the other for (i) any special, indirect or consequential damages, loss of profits or goodwill (even if advised of the possibility of such); (ii) any delay by reason of circumstances beyond its control, including acts of civil or military authority, national emergencies, labor difficulties, fire, mechanical breakdown, flood or catastrophe, acts of God, insurrection, war, riots, or failure beyond its control of transportation or power supply; or (iii) any claim that arose more than one year prior to the institution of suit therefor.
B. In order that the indemnification provisions contained in this section shall apply, it is understood that if in any case the indemnitor may be asked to indemnify or hold the indemnitee harmless, the indemnitor shall be fully and promptly advised of all pertinent facts concerning the situation in question, and it is further understood that the indemnitee will use all reasonable care to notify the indemnitor promptly concerning any situation that presents or appears likely to present the probability of a claim for indemnification. The indemnitor shall have the option to defend the indemnitee against any claim that may be the subject of this indemnification. In the event that the indemnitor so elects, it will so notify the indemnitee and thereupon the indemnitor shall take over complete defense of the claim, and the indemnitee shall in such situation initiate no further legal or other expenses for which it shall seek indemnification under this section. The indemnitee shall in no case confess any claim or make any compromise in any case in which the indemnitor will be asked to indemnify the indemnitee except with the indemnitor’s prior written consent.
C. The indemnity and defense provisions set forth in this Section 9 shall indefinitely survive the termination and/or assignment of this Agreement.
D. If USBFS is acting in another capacity for the Trust pursuant to a separate agreement, nothing herein shall be deemed to relieve USBFS of any of its obligations in such other capacity.
Contractor’s Pollution Liability insurance covering losses caused by pollution conditions that arise from the operations of the Contractor. Contractors Pollution Liability insurance shall be written in an amount of at least $1,000,000 per loss, with an annual aggregate of at least $1,000,000. Contractors Pollution Liability shall cover bodily injury, property damage, cleanup costs and defense including costs and expenses incurred in the investigation, defense, or settlement of claims. If the Contractors Pollution Liability insurance is written on a claims-made basis, the Contractor warrants that any retroactive date applicable to coverage under the policy precedes the effective date of this contract; and that continuous coverage will be maintained or an extended discovery period will be exercised for a period of three (3) years beginning from the time that work under the contract is completed. The City shall be named by endorsement as an additional insured on the Contractors Pollution Liability insurance policy. If the scope of services as defined in this contract includes the disposal of any hazardous materials from the job site, the Contractor must furnish to the City evidence of Pollution Liability insurance maintained by the disposal site operator for losses arising from the insured facility accepting waste under this contract. Coverage certified to the Public Entity under this paragraph must be maintained in minimum amounts of $1,000,000 per loss, with an annual aggregate of at least $1,000,000. Pollution Liability coverage at least as broad as that provided under ISO Pollution Liability- Broadened Coverage for Covered Autos Endorsement CA 99 48 shall be provided, and the Motor Carrier Act Endorsement (MCS 90) shall be attached.
Standard of Care; Limitation of Liability; Indemnification (a) ALPS shall be obligated to act in good faith and to exercise commercially reasonable care and diligence in the performance of its duties under this Agreement, including with regard to the processing of investments checks using mutually agreed upon procedures. The parties agree that any encoding or payment processing errors shall be governed by this standard of care and Section 4-209 of the Uniform Commercial Code is superseded by this Section 4 of this Agreement.
(b) In the absence of willful misfeasance, bad faith, negligence or reckless disregard by ALPS in the performance of its duties, obligations or responsibilities set forth in this Agreement, ALPS and its affiliates, including their respective officers, directors, agents and employees, shall not be liable for, and the Fund agrees to indemnify, defend and hold harmless such persons from, all taxes, charges, expenses, disbursements, assessments, claims, losses, damages, penalties, actions, suits, judgments and liabilities (including, without limitation, attorneys’ fees and disbursements and liabilities arising under applicable federal and state laws) arising directly or indirectly from the following:
(i) the inaccuracy of factual information furnished to ALPS by the Fund or the Fund’s investment adviser or custodian or any authorized third party on behalf of the Fund;
(ii) any reasonable error of judgment or mistake of law or for any loss suffered by the Fund in connection with the matters to which this Agreement relates;
(iii) ALPS’ reliance on any instruction, direction, notice, instrument or other information provided by the Fund or the Fund’s investment adviser or custodian or any authorized third party on behalf of the Fund that ALPS reasonably believes to be genuine;
(iv) failure to satisfy requests to cancel or amend payment orders, if ALPS receives such requests without reasonable time to comply with such requests;
(v) failure to detect any erroneous payment order, provided that ALPS complies with the payment order instructions as received and with the Security Procedure (as defined below);
(vi) lost interest with respect to the refundable amount of an unauthorized payment order, unless ALPS is notified of the unauthorized payment order within 30 days of notification by ALPS of the acceptance of such payment order; or
(vii) any other action or omission to act which ALPS properly takes in connection with the provision of services to the Fund pursuant to this Agreement.
(c) ALPS shall indemnify and hold harmless the Fund, the Fund’s investment adviser and their respective officers, directors, agents and employees from and against any and all taxes, charges, expenses, disbursements, assessments, claims, losses, damages, penalties, actions, suits, judgments and liabilities (including, without limitation, attorneys’ fees and disbursements and liabilities arising under applicable federal and state laws) arising directly or indirectly from ALPS’ willful misfeasance, bad faith, negligence or reckless disregard in the performance of its duties, obligations or responsibilities set forth in this Agreement.
(d) Notwithstanding anything in this Agreement to the contrary, neither party shall be liable under this Agreement to the other party hereto for any punitive, consequential, special or indirect losses or damages. Any indemnification payable by a party to this Agreement shall be net of insurance maintained by the indemnified party as of the time the claim giving rise to indemnity hereunder is alleged to have arisen to the extent it covers such claim.
(e) In any case in which either party (the “Indemnifying Party”) may be asked to indemnify or hold the other party (the “Indemnified Party”) harmless, the Indemnified Party will notify the Indemnifying Party promptly after identifying any situation which it believes presents or appears likely to present a claim for indemnification against the Indemnifying Party although the failure to do so shall not prevent recovery by the Indemnified Party and shall keep the Indemnifying Party advised with respect to all developments concerning such situation. The Indemnifying Party shall have the option to defend the Indemnified Party against any claim which may be the subject of this indemnification, and, in the event that the Indemnifying Party so elects, such defense shall be conducted by counsel chosen by the Indemnifying Party and reasonably satisfactory to the Indemnified Party, and thereupon the Indemnifying Party shall take over complete defense of the claim and the Indemnified Party shall sustain no further legal or other expenses in respect of such claim. The Indemnified Party will not confess any claim or make any compromise in any case in which the Indemnifying Party will be asked to provide indemnification, except with the Indemnifying Party’s prior written consent.
Indemnification of Third Party Claims The obligations and liabilities of any party to indemnify any other under this Article 6 with respect to Claims relating to third parties shall be subject to the following terms and conditions:
Indemnification Procedures for Third Party Claims If a claim by a third party (including claims for breaches of fiduciary duties) is made against an Indemnified Party and such Indemnified Party intends to seek indemnity with respect thereto from the Company (in the case of a Purchaser Indemnified Party seeking such indemnity) or the Purchaser (in the case of a Company Indemnified Party seeking indemnity) (each of the Company or the Purchaser, as the case may be, in such capacity, an “Indemnifying Party”), such Indemnified Party shall give notice in writing as promptly as reasonably practicable to such Indemnifying Party of any Proceeding commenced against or by it in respect of which indemnity may be sought hereunder, but failure to so notify such Indemnifying Party shall not relieve such Indemnifying Party from any liability that it may have on account of this Article VI, so long as such failure shall not have materially prejudiced the position of such Indemnifying Party. Upon such notification, the Indemnifying Party shall assume the defense of such Proceeding brought by a third party, and, after such assumption, the Indemnified Party shall not be entitled to reimbursement of any expenses thereafter incurred by it in connection with such Proceeding, except as described below. In any such Proceeding, any Indemnified Party shall have the right to retain its own counsel (including local counsel), but the fees and expenses of such counsel shall be at the expense of such Indemnified Party unless (i) the Indemnifying Party shall have failed to promptly assume and thereafter conduct such defense, (ii) the Indemnifying Party and the Indemnified Party shall have mutually agreed to the contrary, (iii) in the reasonable determination of counsel for the Indemnified Party, representation of such Indemnified Party by counsel obtained by the Indemnifying Party would be inappropriate due to actual or potential conflicting interests between such Indemnified Party and any other party represented by such counsel in such proceeding. No Indemnifying Party, in the defense of a third-party claim, shall, except with the consent of the Indemnified Party, consent to entry of any judgment or enter into any settlement that does not include as an unconditional term thereof the giving by the claimant or plaintiff to such Indemnified Party of a release from all liability in respect of such claim. The Indemnifying Party shall not be liable for any settlement of any Proceeding effected without its written consent (which shall not be unreasonably withheld, delayed or conditioned by such Indemnifying Party), but if settled with such consent or if there be final judgment for the plaintiff, the Indemnifying Party shall indemnify the Indemnified Party from and against any Loss by reason of such settlement or judgment. The Indemnifying Party will advance expenses to an Indemnified Party as reasonably incurred so long as such indemnified party shall have provided the indemnifying party with a written undertaking to reimburse the indemnifying party for all amounts so advanced if it is ultimately determined that the indemnified party is not entitled to indemnification hereunder (which shall include breaches of fiduciary duty if permitted above).
Indemnification; Third Party Claims The Master Servicer agrees to indemnify the Depositor, the Sponsor and the Trustee, and their respective officers, directors, agents and affiliates, and hold each of them harmless against any and all claims, losses, penalties, fines, forfeitures, reasonable legal fees and related costs, judgments, and any other costs, liability, fees and expenses that the Depositor, the Sponsor or the Trustee may sustain as a result of (a) any material breach by the Master Servicer of any if its obligations hereunder, including particularly its obligations to provide any reports under Section 9.25(a), Section 9.25(b), Section 9.26 or any information, data or materials required to be included in any Exchange Act report, (b) any material misstatement or omission in any information, data or materials provided by the Master Servicer, or (c) the negligence, bad faith or willful misconduct of the Master Servicer in connection with its performance hereunder, provided, however, that in no event shall the Master Servicer be liable for any special, consequential, indirect or punitive damages pursuant to this Section 9.31, even if advised of the possibility of such damages. The Depositor, the Sponsor and the Trustee shall immediately notify the Master Servicer if a claim is made by a third party with respect to this Agreement or the Mortgage Loans entitling the Depositor, the Sponsor or the Trustee to indemnification hereunder, whereupon the Master Servicer shall assume the defense of any such claim and pay all expenses in connection therewith, including counsel fees, and promptly pay, discharge and satisfy any judgment or decree which may be entered against it or them in respect of such claim. Notwithstanding anything to the contrary contained herein, the Master Servicer shall not settle any claim involving any of the other parties hereto without such party’s prior written consent unless such settlement involves a complete and absolute release of such party from any and all liability in connection with such claim. This indemnification shall survive the termination of this Agreement or the termination of the Master Servicer as a party to this Agreement.
Indemnification of TIPS XXXXXX AGREES TO INDEMNIFY, HOLD HARMLESS, AND DEFEND TIPS, TIPS MEMBERS, TIPS officers, TIPS Employees, TIPS Directors, and TIPS Trustees (the “TIPS Indemnitees”) from and against all claims and suits by third-parties for damages, injuries to persons (including death), property damages, losses, expenses, fees, including court costs, attorney’s fees, and expert fees, arising out of or relating to Vendor’s performance under this Agreement (including the performance of Vendor’s officers, employees, agents, Authorized Resellers, subcontractors, licensees, or invitees), regardless of the nature of the cause of action, including without limitation causes of action based upon common, constitutional, or statutory law or based in whole or in part upon allegations of negligent or intentional acts or omissions on the part of Vendor, its officers, employees, agents, Authorized Resellers, subcontractors, licensees, or invitees. NO LIMITATION OF LIABILITY FOR DAMAGES FOR PERSONAL INJURY OR PROPERTY DAMAGE ARE PERMITTED OR AGREED TO BY TIPS. Apart from this indemnification provision requiring indemnification of the TIPS Indemnitees’ attorney’s fees as set forth above, recovery of attorneys’ fees by the prevailing party is authorized only if authorized by Xxx. Educ. Code § 44.032(f).
Intellectual Property Warranty and Indemnification Contractor represents and warrants that any materials or deliverables, including all Deliverable Materials, provided under this Contract are either original, or not encumbered, and do not infringe upon the copyright, trademark, patent or other intellectual property rights of any third party, or are in the public domain. If Deliverable Materials provided hereunder become the subject of a claim, suit or allegation of copyright, trademark or patent infringement, City shall have the right, in its sole discretion, to require Contractor to produce, at Contractor’s own expense, new non-infringing materials, deliverables or works as a means of remedying any claim of infringement in addition to any other remedy available to the City under law or equity. Contractor further agrees to indemnify, defend, and hold harmless the City, its officers, employees and agents from and against any and all claims, actions, costs, judgments or damages, of any type, alleging or threatening that any Deliverable Materials, supplies, equipment, services or works provided under this contract infringe the copyright, trademark, patent or other intellectual property or proprietary rights of any third party (Third Party Claim of Infringement). If a Third Party Claim
