Infringement Indemnification If notified promptly in writing of any judicial action brought against City based on an allegation that City’s use of the Licensed Software infringes a patent, copyright, or any right of a third party or constitutes misuse or misappropriation of a trade secret or any other right in intellectual property (Infringement), Contractor will hold City harmless and defend such action at its own expense. Contractor will pay the costs and damages awarded in any such action or the cost of settling such action, provided that Contractor shall have sole control of the defense of any such action and all negotiations or its settlement or compromise. If notified promptly in writing of any informal claim (other than a judicial action) brought against City based on an allegation that City’s use of the Licensed Software constitutes Infringement, Contractor will pay the costs associated with resolving such claim and will pay the settlement amount (if any), provided that Contractor shall have sole control of the resolution of any such claim and all negotiations for its settlement. In the event a final injunction is obtained against City’s use of the Licensed Software by reason of Infringement, or in Contractor’s opinion City’s use of the Licensed Software is likely to become the subject of Infringement, Contractor may at its option and expense: (a) procure for City the right to continue to use the Licensed Software as contemplated hereunder, (b) replace the Licensed Software with a non-infringing, functionally equivalent substitute Licensed Software, or (c) suitably modify the Licensed Software to make its use hereunder non-infringing while retaining functional equivalency to the unmodified version of the Licensed Software. If none of these options is reasonably available to Contractor, then the Agreement may be terminated at the option of either Party hereto and Contractor shall refund to City all amounts paid under this Agreement for the license of such infringing Licensed Software. Any unauthorized modification or attempted modification of the Licensed Software by City or any failure by City to implement any improvements or updates to the Licensed Software, as supplied by Contractor, shall void this indemnity unless City has obtained prior written authorization from Contractor permitting such modification, attempted modification or failure to implement. Contractor shall have no liability for any claim of Infringement based on City’s use or combination of the Licensed Software with products or data of the type for which the Licensed Software was neither designed nor intended to be used.
Indemnification by Seller As an inducement to Buyer to enter into this Agreement and the Related Documents, and acknowledging that Buyer is relying on the indemnification provided in this Section 7 in entering into this Agreement and the Related Documents, Seller and Parent, jointly and severally, agree, to indemnify, defend and hold harmless Buyer and its affiliates, parent corporation and subsidiaries, and their respective employees, officers, directors, representatives, agents, counsel, successors and assigns (collectively, "Buyer Affiliates"), from and against any claims, losses, liability, obligations, lawsuits, judgments, settlements, governmental investigations, deficiencies, damages, costs or expenses of whatever nature, whether known or unknown, accrued, absolute, contingent or otherwise including, without limitation, interest, penalties, attorneys' fees, costs of investigation and all amounts paid in defense or settlement of the foregoing, reduced by and to the extent of any insurance proceeds received with respect to any of the foregoing (collectively "Claims and Losses"), suffered or incurred by Buyer or Buyer Affiliates as a result of or in connection with the following: (i) any and all debts, liabilities and obligations of Seller or related to the Assets (other than the Assumed Liabilities), whether known or unknown, accrued, absolute, contingent or otherwise, arising out of or relating to the business and operations of Seller or related to the Assets prior to or on the Closing Date or which arise after the Closing Date but which are based upon or arise out of any act, transaction, circumstance, state of facts or other condition which occurred or existed on or before the Closing Date, whether or not then known, accrued, due or payable; (ii) a breach of any obligation, representation, warranty, covenant or agreement of Seller or Parent in this Agreement or any Related Document, or because any representation or warranty by Seller and Parent contained in this Agreement or any Related Document, in any document furnished or required to be furnished pursuant to this Agreement by Seller or Parent to Buyer or any of its representatives, or any documents furnished to Buyer in connection with the Closing hereunder, shall be false; (iii) any litigation arising out of or based upon events or operative facts occurring prior to or on the Closing Date, in connection with the Seller or the Assets, whether or not disclosed on the Disclosure Schedule, including claims, without limitation, made by employees or former employees of Seller or Parent; (iv) any and all claims, including legal, administrative or creditor claims or actions, in connection with the Seller or the Assets or the transfer of Assets hereunder, if any fact material to any such claim or cause of action pleaded or stated there occurred prior to or on the Closing Date; and (v) costs and expenses (including reasonable attorneys' fees) incurred by Buyer in connection with any demand, action, suit, proceeding, demand, assessment or judgment incident to any of the foregoing (collectively, "Buyer's Damages").
Intellectual Property Infringement Indemnification 1.1 We will defend you against any third party claim(s) that the Tyler Software or Documentation infringes that third party’s patent, copyright, or trademark, or misappropriates its trade secrets, and will pay the amount of any resulting adverse final judgment (or settlement to which we consent). You must notify us promptly in writing of the claim and give us sole control over its defense or settlement. You agree to provide us with reasonable assistance, cooperation, and information in defending the claim at our expense.
1.2 Our obligations under this Section G(1) will not apply to the extent the claim or adverse final judgment is based on your use of the Tyler Software in contradiction of this Agreement, including with non-licensed third parties, or your willful infringement.
1.3 If we receive information concerning an infringement or misappropriation claim related to the Tyler Software, we may, at our expense and without obligation to do so, either: (a) procure for you the right to continue its use; (b) modify it to make it non-infringing; or (c) replace it with a functional equivalent, in which case you will stop running the allegedly infringing Tyler Software immediately. Alternatively, we may decide to litigate the claim to judgment, in which case you may continue to use the Tyler Software consistent with the terms of this Agreement.
1.4 If an infringement or misappropriation claim is fully litigated and your use of the Tyler Software is enjoined by a court of competent jurisdiction, in addition to paying any adverse final judgment (or settlement to which we consent), we will, at our option, either: (a) procure the right to continue its use; (b) modify it to make it non-infringing; or (c) replace it with a functional equivalent. This section provides your exclusive remedy for third party copyright, patent, or trademark infringement and trade secret misappropriation claims.
Intellectual Property Indemnification by Vendor Procedures Related to Indemnification. In the event that an indemnity obligation arises, Vendor shall pay all amounts set forth in Section 14 and 15 above (including any settlements) and – if it has accepted its indemnity obligation without qualification – control the legal defense to such claim or cause of action, including without limitation attorney selection, strategy, discovery, trial, appeal, and settlement, and TIPS shall, at Vendor’s cost and expense (with respect to reasonable out of pocket costs and expenses incurred by TIPS which shall be reimbursed to TIPS by Vendor), provide all commercially reasonable assistance requested by Vendor. In controlling any defense, Vendor shall ensure that all assertions of governmental immunity and all applicable pleas and defenses shall be promptly asserted.
Infringement Indemnity Except as specifically provided below, Ricoh will indemnify, defend and hold Subscriber harmless from and against any and all liabilities, damages, costs and expenses (including reasonable attorneys fees) incurred by Subscriber arising from a third party claim that the Services or Application, as delivered by Ricoh and used within the scope of this Agreement, infringe any existing domestic patent, copyright or trademark, but only if, (i) Subscriber notifies Ricoh in writing within thirty (30) days of any such claim, (ii) Ricoh shall have full control of the defense and all related settlement negotiations, and (iii) Subscriber shall provide Ricoh with assistance, information and authority necessary to perform the above. Notwithstanding the foregoing, Ricoh shall have no indemnity obligation for any claim relating to (i) any software of third parties, including without limitation, any embedded open source or similar software, (ii) any modifications to the Services or Application made by any entity other than Ricoh, (iii) combination or use of the Services or Application with other products, (iv) use of an outdated version of the Ancillary Software when Ricoh has made available an updated version that does not infringe, or (v) any addition, change or modification of the functionality of the Services or Application made at Subscriber’s request, if such claim would not have arisen but for such functionality. In the event of an infringement claim, if it is commercially reasonable to do so, and at its option, Ricoh will either obtain the right for Subscriber to use the Services or will modify the Services to make them non-infringing, and failing these options, Ricoh may terminate the license and Subscriber will return any Ancillary Software. THE REMEDIES ABOVE ARE THE SOLE AND EXCLUSIVE REMEDIES FOR RICOH’S BREACH OF ANY INTELLECTUAL PROPERTY WARRANTY CONTAINED IN THIS AGREEMENT OR IMPOSED OR IMPLIED BY LAW.
Indemnification by Sellers Subject to the other terms and conditions of this ARTICLE 10 and the terms and conditions set forth in ARTICLE 13, Sellers, severally and not jointly (pro rata in accordance with the portion of the Purchase Price received by each Seller), shall indemnify, defend, reimburse and hold harmless Buyer, its Affiliates, successors and assigns and the respective officers, directors, employees, attorneys, agents and stockholders of the foregoing (the “Buyer Indemnified Parties”) from and against any and all Losses incurred or sustained by, or imposed upon, such Buyer Indemnified Party based upon, arising out of, with respect to, relating to or by reason of:
(a) any inaccuracy in or breach of any of the representations or warranties of Sellers contained in ARTICLE 2 hereunder or the Company in ARTICLE 3, provided that no Seller shall have any obligation hereunder with respect to any inaccuracy in or breach of any of the representations and warranties of any other Seller;
(b) any breach or non-fulfillment of any covenant, agreement or obligation to be performed by Sellers pursuant to this Agreement;
(c) any Company Transaction Expenses or Indebtedness outstanding as of the Closing to the extent not paid or satisfied by the Company or Sellers at or prior to the Closing;
(d) any Taxes for the Pre-Closing Tax Period (including the pre-Closing portion of any Straddle Period) to the extent not included in the computation of Company Transaction Expenses or Closing Net Working Capital (collectively, “Pre-Closing Taxes”), to the extent that such Taxes have not been reimbursed under a claim made under the R&W Insurance Policy; or
(e) any of the matters set forth on Section 10.1(e) of the Buyer Disclosure Schedule. Any claims arising out of clauses (b), (c), (d), or (e) of this Section 10.1 are referred to herein as “Excluded Claims.”
PATENT INDEMNIFICATION The Contractor agrees to assume the defense of and shall indemnify and save harmless the Owner and all persons acting for or on behalf of it from all suits and claims against them, or any of them, arising from or occasioned by the use of any material, Equipment or apparatus, or any part thereof which infringes or is alleged to infringe on any patent rights. In case such material, equipment or apparatus, or any part thereof, in any such suit is held to constitute infringement, the Contractor, within a reasonable time, shall at its own expense, and as the Owner may elect, replace such material, Equipment or apparatus with non-infringing material, Equipment or apparatus, or remove the material, equipment, or apparatus and refund the sums paid therefor.
Indemnification by Supplier Supplier covenants and agrees to indemnify, defend and hold harmless Eargo, its Affiliate(s), Approved Buyer(s), and their respective agents, contractors, officers, directors, employees and Representatives (including any combination of the Eargo, its Affiliate(s), Approved Buyer(s) or their respective agents, contractors, officers, directors, employees and Representatives) (collectively, the “Indemnified Parties”) from and against any and all claims, allegations, losses, damages, settlements, governmental fines and penalties, and all other liabilities, including attorneys’ and other professional fees and court costs, and all costs and expenses, arising out of or related to: (a) the Units, or any portion thereof, on their own or in combination with any other goods and services, infringe any rights or IPR of a third party (collectively, “Third Party IPR”) where such Third Party IPR relates to Supplier’s Manufacturing Process, or manufacturing, packaging, testing, or other Services provided under this Agreement, excluding Product design and materials or equipment consigned to Supplier by Eargo; (b) personal injury or property damage resulting, directly or indirectly from the Units or Services (including any Hazard), the performance of Supplier’s obligations hereunder, or the fault or negligence of Supplier or the Supplier Parties; (c) negligent, willful or reckless acts or omissions, dishonesty or fraud of or by Supplier or any Supplier Parties; (d) a breach or alleged breach by Supplier or any Supplier Parties of any provision or clause (e.g., Supplier or Supplier Parties act in contravention of any clause or perform acts contrary to the terms specified in this Agreement) of this Agreement; (e) any claim or cause of action anywhere in the world asserted against Eargo or any of the Indemnified Parties alleging or in connection with alleged defects in the assembly or manufacturing of the Product(s); or (f) violations of law in the manufacture of the Products; (each a “Claim” and collectively, “Claims”).
Indemnification by Buyer (a) Buyer shall indemnify, defend and hold harmless Seller and its Affiliates and its and their respective officers, directors, employees, agents and representatives (the “Seller Indemnitees”) from and against any and all Adverse Consequences suffered or incurred by any Seller Indemnitee resulting from, arising out of, relating to or caused by (i) any breach or inaccuracy of any representation or warranty made in Article 2 or any representation or warranty made by Buyer or an Affiliate of Buyer in any certificate delivered in connection with this Agreement, (ii) any breach of any Pre-Closing Covenant by Buyer or (iii) any breach of any covenant or agreement of Buyer contained in this Agreement (other than the Pre-Closing Covenants).
(b) Buyer shall indemnify, defend and hold harmless the Seller Indemnitees from and against any and all Adverse Consequences suffered or incurred by any Seller Indemnitee resulting from, arising out of, relating to or caused by any Assumed Liability or any Acquired Asset or, subject to Seller’s obligations under this Article 7, any Liability of any Acquired Company (other than any Acquired Company Retained Liability) to the extent that such Adverse Consequences do not result from, arise out of or relate to, and are not caused by, a breach of this Agreement or any Ancillary Agreement by Seller or any Seller Entity or a matter set forth on Schedule 7.2(c) and do not constitute a Retained Liability or an Acquired Company Retained Liability.
(c) Subject to Seller’s obligations under this Article 7, Buyer shall indemnify, defend and hold harmless the Seller Indemnitees from and against any and all Adverse Consequences suffered or incurred by any Seller Indemnitee resulting from, arising out of, relating to or caused by any Third Party Claims to the extent resulting from, arising out of, relating to or caused by the operation of the Business after the Closing to the extent that such Adverse Consequences do not result from, arise out of or relate to, and are not caused by, a breach of this Agreement or any Ancillary Agreement by Seller or any Seller Entity or a matter set forth in Schedule 7.2(c) and do not constitute a Retained Liability or an Acquired Company Retained Liability.
Indemnification by Licensor Licensor shall defend, indemnify and hold harmless Licensee and its Affiliates, and their respective officers, directors, employees, agents, shareholders, successors and assigns, (collectively, the “Licensee Parties”) from and against any claim, suit, demand or action (“Action”), and any and all direct losses suffered or incurred by Licensee in connection with any third party claims (a) arising out of or resulting from any breach by Licensor of any provision of this Agreement or (b) that use of the Licensed Marks by Licensee in accordance with the terms and conditions of this Agreement infringes or otherwise violates a third party’s Trademarks. Licensor’s obligation to indemnify Licensee shall be conditioned on (a) Licensee’s provision to Licensor of prompt notice of such an Action (except where any delay does not materially prejudice Licensor); (b) Licensee’s reasonable cooperation with Licensor in the defense and settlement of such an Action at Licensor’s cost; and (c) Licensor having exclusive control of the defense, settlement and/or compromise of such an Action (provided that Licensor may not settle any Action in a manner that adversely affects Licensee without Licensee’s prior written consent, not to be unreasonably withheld or delayed).
