Common use of Inspection of Services Clause in Contracts

Inspection of Services. a. The Contractor shall maintain an inspection system acceptable to WMATA covering the services under this Contract. The Contractor shall maintain complete records of all inspection work it performs and make them available to WMATA during Contract performance in the manner and in accordance with the time periods set forth in the "Audit and Inspection of Records" clause of this Contract. b. WMATA has the right to inspect and test all services provided under this Contract, at all times and places reasonably practicable during the term of this Contract. WMATA shall perform inspections and tests in a manner that will not unduly delay the Contract. c. If WMATA performs inspections or tests on the Contractor's or subcontractor's premises, the Contractor shall furnish, and shall require subcontractors to furnish, without cost, all reasonable facilities and assistance for the safe and convenient performance of such inspections or tests. d. If any of the services performed do not conform to the Contract's requirements, WMATA may require the Contractor to perform them again in conformity with the i. Direct the Contractor to take necessary action to ensure that future performance conforms to this Contract's requirements; and/or ii. Reduce the Contract price to reflect the reduced value of the services performed. e. If the Contractor fails to comply with the provisions of paragraph (d), WMATA may: i. By contract or otherwise, perform the services and charge to the Contractor any cost incurred by WMATA; and/ or ii. In the event that the Contracting Officer deems such failure to comply a material breach, terminate the Contract for default. f. Nothing contained herein shall be deemed to preclude the Contracting Officer from reducing the Contract price due to the reduced value of nonconforming services provided to WMATA.

Inspection of Services. ‌ a. The Contractor shall provide and maintain an inspection system acceptable to WMATA covering the services under this Contract. The Contractor shall maintain complete records of all inspection work it performs and make them available to WMATA during Contract performance in the manner and in accordance with the time periods set forth in the "Audit and Inspection of Records" clause of this Contract.to b. WMATA has the right to inspect and test all services provided under called for by this Contract, at all times and places reasonably practicable during the term of this Contract. WMATA shall perform inspections inspection and tests in a manner that will not unduly delay the Contract. c. If WMATA performs inspections or tests on the Contractor's or subcontractor's premises, the Contractor shall furnish, and shall require subcontractors to furnish, without cost, all reasonable facilities and assistance for the safe and convenient performance of such inspections or tests.tests.‌ d. If any of the services performed do not conform to the Contract's requirements, WMATA may require the Contractor to perform them again in conformity with thethe Contract's requirements, without additional cost. When the defects in performance cannot reasonably be corrected by such further performance, WMATA may: i. Direct the Contractor to take necessary action to ensure that future performance conforms to this Contract's requirements; and/orand/or‌ ii. Reduce the Contract price to reflect the reduced value of the services performed. e. If the Contractor fails to comply with the provisions of paragraph (d), WMATA may: i. By contract or otherwise, perform the services and charge to the Contractor any cost thereby incurred by WMATA; and/ oror‌ ii. In the event that the Contracting Officer deems such failure to comply a material breach, terminate the Contract for default. f. Nothing contained herein shall be deemed to preclude the Contracting Officer from reducing the Contract price due to the reduced value of nonconforming services provided to WMATA.

Inspection of Services. a. The Contractor shall provide and maintain an inspection system acceptable to WMATA covering the services under this Contract. The Contractor shall maintain complete records of all inspection work it performs and make them available to WMATA during Contract performance in the manner and in accordance with the time periods set forth in the "Audit and Inspection of Records" clause article of this Contract. b. WMATA has the right to inspect and test all services provided under called for by this Contract, at all times and places reasonably practicable during the term of this Contract. WMATA shall perform inspections inspection and tests in a manner that will not unduly delay the Contract. c. If WMATA performs inspections or tests on the Contractor's or subcontractor's premises, the Contractor shall furnish, and shall require subcontractors to furnish, without cost, all reasonable facilities and assistance for the safe and convenient performance of such inspections or tests. d. If any of the services performed do not conform to the Contract's requirements, WMATA may require the Contractor to perform them again in conformity with thethe Contract's requirements, without additional cost. When the defects in performance cannot reasonably be corrected by such further performance, WMATA may:‌ i. Direct the Contractor to take necessary action to ensure that future performance conforms to this Contract's requirements; and/or ii. Reduce the Contract price to reflect the reduced value of the services performed.performed.‌ e. If the Contractor fails to comply with the provisions of paragraph (d), WMATA may: i. By contract or otherwise, perform the services and charge to the Contractor any cost thereby incurred by WMATA; and/ oror‌ ii. In the event that the Contracting Officer deems such failure to comply a material breach, terminate the Contract for default. f. Nothing contained herein shall be deemed to preclude the Contracting Officer from reducing the Contract price due to the reduced value of nonconforming services provided to WMATA.

Inspection of Services. ‌ a. The Contractor shall maintain an inspection system acceptable to WMATA covering the services under this Contract. The Contractor shall maintain complete records of all inspection work it performs and make them available to WMATA during Contract performance in the manner and in accordance with the time periods set forth in the "Audit and Inspection of Records" clause of this Contract. b. WMATA has the right to inspect and test all services provided under this Contract, at all times and places reasonably practicable during the term of this Contract. WMATA shall perform inspections and tests in a manner that will not unduly delay the Contract. c. If WMATA performs inspections or tests on the Contractor's or subcontractor's premises, the Contractor shall furnish, and shall require subcontractors to furnish, without cost, all reasonable facilities and assistance for the safe and convenient performance of such inspections or tests. d. If any of the services performed do not conform to the Contract's requirements, WMATA may require the Contractor to perform them again in conformity with thethe Contract's requirements, without additional cost. When the defects in performance cannot reasonably be corrected by such further performance, WMATA may: i. Direct the Contractor to take necessary action to ensure that future performance conforms to this Contract's requirements; and/or ii. Reduce the Contract price to reflect the reduced value of the services performed. e. If the Contractor fails to comply with the provisions of paragraph (d), WMATA may: i. By contract or otherwise, perform the services and charge to the Contractor any cost incurred by WMATA; and/ or ii. In the event that the Contracting Officer deems such failure to comply a material breach, terminate the Contract for default.default.‌ f. Nothing contained herein shall be deemed to preclude the Contracting Officer from reducing the Contract price due to the reduced value of nonconforming services provided to WMATA.