Inspection of Services. Subcontractor shall make the Services accessible at all reasonable times for inspection by the Contractor. Subcontractor shall, at the first opportunity, inspect all material and equipment delivered to the job site by others to be used or incorporated in the Subcontractor’s Services and give prompt notice of any defect therein. Subcontractor assumes full responsibility to protect the work done hereunder until final acceptance by the Contractor or any authorized third (3rd) party.
Inspection of Services. Any Compensation shall be subject to the Client inspecting the completed Services of the Service Provider. If any of the Services performed by the Service Provider pursuant to this Agreement are defective or incomplete, the Client shall have the right to notify the Service Provider, at which time the Service Provider shall promptly correct such work within a reasonable time.
Inspection of Services a. The Contractor shall maintain an inspection system acceptable to WMATA covering the services under this Contract. The Contractor shall maintain complete records of all inspection work it performs and make them available to WMATA during Contract performance in the manner and in accordance with the time periods set forth in the "Audit and Inspection of Records" clause of this Contract.
b. WMATA has the right to inspect and test all services provided under this Contract, at all times and places reasonably practicable during the term of this Contract. WMATA shall perform inspections and tests in a manner that will not unduly delay the Contract.
c. If WMATA performs inspections or tests on the Contractor's or subcontractor's premises, the Contractor shall furnish, and shall require subcontractors to furnish, without cost, all reasonable facilities and assistance for the safe and convenient performance of such inspections or tests.
d. If any of the services performed do not conform to the Contract's requirements, WMATA may require the Contractor to perform them again in conformity with the Contract's requirements, without additional cost. When the defects in performance cannot reasonably be corrected by such further performance, WMATA may:
i. Direct the Contractor to take necessary action to ensure that future performance conforms to this Contract's requirements; and/or
ii. Reduce the Contract price to reflect the reduced value of the services performed.
e. If the Contractor fails to comply with the provisions of paragraph (d), WMATA may:
i. By contract or otherwise, perform the services and charge to the Contractor any cost incurred by WMATA; and/ or
ii. In the event that the Contracting Officer deems such failure to comply a material breach, terminate the Contract for default.
f. Nothing contained herein shall be deemed to preclude the Contracting Officer from reducing the Contract price due to the reduced value of nonconforming services provided to WMATA.
Inspection of Services. (a) The Contractor shall provide and maintain a system, acceptable to the City, for inspecting all Services it provides under the Contract. Complete records of all inspection work performed by the Contractor shall be maintained and made available to the City during Contract performance and for as long afterwards as the Contract requires.
(b) The City has the right to inspect and test all Services called for by the Contract, to the extent practicable at all times and places during the term of the Contract. The City shall perform inspections and tests in a manner that will not unduly delay the work.
(c) If the City performs inspections or tests on the premises of the Contractor or a subcontractor, the Contractor shall furnish, and shall require subcontractors to furnish, at no increase in Contract price, all reasonable facilities and assistance for the safe and convenient performance of these duties.
(1) If any of the Services do not conform to Contract requirements or industry standards, the City may require the Contractor to perform the Services again in conformity with Contract requirements, at no increase in Contract amount. When the defects in Services cannot be corrected by re-performance, the City may:
(i) Require the Contractor to take necessary action to ensure that future performance conforms to Contract requirements; and
(ii) Reduce the Contract price to reflect the reduced value of the Services performed.
(2) If the Contractor subsequently fails again to take the necessary action to ensure future performance in conformity with Contract requirements, the City may:
(i) By contract or otherwise, perform the Services and charge to the Contractor any cost incurred by the City that is directly related to the performance of such Services; or
(ii) Terminate the Contract for default by procedures set forth in Section I.6, Default.
Inspection of Services. A. The Department and other government regulatory agencies have the right to inspect and test all Services called for by this Contract, to the extent practicable at all times and places during the Contract Term. The Department shall perform inspections in a manner that will not unduly interfere with the Contractor’s performance of Services. The Contractor shall furnish, and shall require Subcontractors to furnish, at no increase in the Contract price, all reasonable assistance for the safe and convenient performance of these duties.
Inspection of Services. The Contractor is responsible for performing or having performed all inspections and tests necessary to substantiate that the services furnished under this Contract conform to Contract requirements, including any applicable technical requirements for specified manufacturers’ parts. This clause takes precedence over any City inspection and testing required in the Contract’s specifications, except for specialized inspections or tests specified to be performed solely by the City.
A. Definition of “services”, as used in this clause, includes services performed, workmanship, and material furnished or utilized in the performance of services.
B. The Contractor shall provide and maintain an inspection system acceptable to the City covering the services under this Contract. Complete records of all inspection work performed by the Contractor shall be maintained and made available to the City during Contract performance and for as long afterwards as the Contract requires.
C. The City has the right to inspect and test all services called for by the Contract, to the extent practicable at all times and places during the term of the Contract. The City will perform inspections and tests in a manner that will not unduly delay the work.
D. If the City performs inspections or test on the premises of the Contractor or a subcontractor, the Contractor shall furnish, and shall require subcontractors to furnish, at no increase in Contract price, all reasonable facilities and assistance for the safe and convenient performance of these duties.
Inspection of Services. Services performed by Contractor under this Contract shall be subject to inspection by the CCHCS at any and all times during the performance thereof. If the CCHCS official conducting the inspection determines that the services performed are not in accordance with the specification, CCHCS may, at its option, have the work performed by an alternate provider, charging the Contractor with any excess cost occasioned thereof.
Inspection of Services. 6.4.1 The Contractor shall provide and maintain an inspection system acceptable to County covering the services under this Contract. Complete records of all inspection work performed by the Contractor shall be maintained and made available to County during contract performance and for as long afterwards as the Contract requires.
6.4.2 County has the right to inspect and test all services called for by the Contract, to the extent practicable at all times and places during the term of the Contract. County shall perform inspections and tests in a manner that will not unduly delay the work.
6.4.3 If any of the services do not conform with Contract requirements, County may require the Contractor to perform the services again in conformity with Contract requirements, at on increase in Contract amount. When the defects in services cannot be corrected by re- performance, County may:
6.4.3.1 Require the Contractor to take necessary action to ensure that future performance conforms to Contract requirements; and
6.4.3.2 Reduce the Contract price to reflect the reduced value of the services performed.
6.4.4 If the Contractor fails to promptly perform the services again or to take the necessary action to ensure future performance in conformity with Contract requirements, County may:
6.4.4.1 By Contract or otherwise, perform the services and charge to the Contractor any cost incurred by County that is directly related to the performance of such service; or
6.4.4.2 Terminate the Contract for default.
Inspection of Services. The services performed by Contractor under this Agreement shall be subject to inspection by the Comal County Sheriff or his designated representative to insure strict compliance with the terms of this Agreement.
Inspection of Services a. The Contractor shall maintain an inspection system acceptable to WMATA covering the services under this Contract. The Contractor shall maintain complete records of all inspection work it performs and make them available to WMATA during Contract performance in the manner and in accordance with the time periods set forth in the "Audit and Inspection of Records" clause of this Contract.
b. WMATA has the right to inspect and test all services provided under this Contract, at all times and places reasonably practicable during the term of this Contract. WMATA shall perform inspections and tests in a manner that will not unduly delay the Contract.
c. If WMATA performs inspections or tests on the Contractor's or subcontractor's premises, the Contractor shall furnish, and shall require subcontractors to furnish, without cost, all reasonable facilities and assistance for the safe and convenient performance of such inspections or tests.
d. If any of the services performed do not conform to the Contract's requirements, WMATA may require the Contractor to perform them again in conformity with the
i. Direct the Contractor to take necessary action to ensure that future performance conforms to this Contract's requirements; and/or
ii. Reduce the Contract price to reflect the reduced value of the services performed.
e. If the Contractor fails to comply with the provisions of paragraph (d), WMATA may:
i. By contract or otherwise, perform the services and charge to the Contractor any cost incurred by WMATA; and/ or
ii. In the event that the Contracting Officer deems such failure to comply a material breach, terminate the Contract for default.
f. Nothing contained herein shall be deemed to preclude the Contracting Officer from reducing the Contract price due to the reduced value of nonconforming services provided to WMATA.
