Instructions of the Company The Company shall have the right, by one or more instruments in writing executed and delivered to the Collateral Agent, the Custodial Agent or the Securities Intermediary, as the case may be, to direct the time, method and place of conducting any proceeding for the realization of any right or remedy available to the Collateral Agent, or of exercising any power conferred on the Collateral Agent, the Custodial Agent or the Securities Intermediary, as the case may be, or to direct the taking or refraining from taking of any action authorized by this Agreement; provided, however, that (i) such direction shall not conflict with the provisions of any law or of this Agreement and (ii) the Collateral Agent, the Custodial Agent and the Securities Intermediary shall be adequately indemnified as provided herein. Nothing in this Section 8.2 shall impair the right of the Collateral Agent in its discretion to take any action or omit to take any action which it deems proper and which is not inconsistent with such direction.
Obligations of the Authority (i) The Authority shall, at its own cost and expense, undertake, comply with and perform all its obligations set out in this Agreement or arising hereunder.
(ii) The Authority shall be responsible for the correctness of the Scope of the Project, Project Facilities, Specifications and Standards and the criteria for testing of the completed Works.
(iii) The Authority shall, upon submission of the Performance Security as per the RFP by the Contractor, shall provide to the Contractor:
(a) No less than 90% (ninety per cent) of the required Right of Way of the Construction Zone of total length of the Project Highway within a period of 30 (thirty) days from the date of this Agreement, which shall be in contiguous stretches of length not less than 1( One) kilometre.
(b) approval of the general arrangement drawings (the “GAD”) from railway authorities to enable the Contractor to construct road over- bridges/ under- bridges at level crossings on the Project Highway in accordance with the Specifications and Standards, and subject to the terms and conditions specified in such approval, within a period of 60 (sixty) days from the Appointed Date, and reimbursement of all the costs and expenses paid by the Contractor to the railway authorities for and in respect of the road over- bridges/ under bridges; and7
(c) all environmental clearances as required under Clause 4.3.8
(iv) Delay in providing the Right of Way or approval of GAD by railway authorities, as the case may be, in accordance with the provisions of Clause 3.1 (iii) shall entitle the Contractor to Damages in a sum calculated in accordance with the provisions of Clause 8.3 of this Agreement and Time Extension in accordance with the provisions of Clause 10.5 of this Agreement. For the avoidance of doubt, the Parties agree that the Damages for delay in approval of GAD by the railway authorities for a particular road over-bridge/ under-bridge shall be deemed to be equal to the Damages payable under the provisions of Clause 8.3 for delay in providing Right of Way for a length of 2 (two) kilometre for each such road over-bridge/ under-bridge.
Representations of the Adviser The Adviser represents, warrants and further covenants as follows:
Actions of Custodian Based on Proper Instructions and Special Instructions So long as and to the extent that the Custodian acts in accordance with (a) Proper Instructions or Special Instructions, as the case may be, and (b) the terms of this Agreement, the Custodian shall not be responsible for the title, validity or genuineness of any property, or evidence of title thereof, received by it or delivered by it pursuant to this Agreement.
Obligations of the Academy Trust The Academy Trust must keep the Land clean and tidy and make good any damage or deterioration to the Land. The Academy Trust must not do anything to lessen the value or marketability of the Land without the Secretary of State’s consent.
Representations of the Manager The Manager represents, warrants and agrees that:
(i) Manager is a Delaware limited liability company established pursuant to the laws of the State of Delaware;
(ii) Manager is duly registered as an “investment adviser” under the Investment Advisers Act of 1940 (“Advisers Act”);
(iii) Manager has been duly appointed by the Trustees and Shareholders of the Fund to provide investment services to the Fund as contemplated by the Management Contract.
(iv) the execution, delivery and performance of this Agreement are within Manager’s powers, have been and remain duly authorized by all necessary corporate action and will not violate or constitute a default under any applicable law or regulation or of any decree, order, judgment, agreement or instrument binding on Manager;
(v) no consent (including, but not limited to, exchange control consents) of any applicable governmental authority or body is necessary, except for such consents as have been obtained and are in full force and effect, and all conditions of which have been duly complied with; and
(vi) this Agreement constitutes a legal, valid and binding obligation enforceable against Manager.
REPRESENTATIONS OF THE ADVISOR (a) The Advisor shall use its best judgment and efforts in rendering the advice and services to the Fund as contemplated by this Agreement.
(b) The Advisor shall maintain all licenses and registrations necessary to perform its duties hereunder in good order.
(c) The Advisor shall conduct its operations at all times in conformance with the Advisers Act, the Investment Company Act, and any other applicable state and/or self-regulatory organization regulations.
(d) The Advisor shall maintain errors and omissions insurance in an amount at least equal to that disclosed to the Board of Trustees in connection with their approval of this Agreement.
Obligations of the Adviser (a) The Adviser shall provide (or cause the Fund’s Custodian (as defined in Section 5 hereof, the Fund’s accountant and the Fund’s distributor) to provide) timely information to the Sub-Adviser regarding such matters as the composition of the Sub-Advised Assets, cash requirements and cash available for investment in the Sub-Advised Assets, and all other information as may be reasonably necessary for the Sub-Adviser to perform its responsibilities hereunder.
(b) The Adviser has furnished the Sub-Adviser with a copy of the prospectus and statement of additional information of the Fund and it agrees during the continuance of this Agreement to furnish the Sub-Adviser copies of any revisions or supplements thereto at, or, if practicable, before the time the revisions or supplements become effective. The Adviser agrees to furnish the Sub-Adviser with copies of any financial statements or reports made by the Fund to its shareholders, and any further materials or information that the Sub-Adviser may reasonably request to enable it to perform its functions under this Agreement.
Outage Authority and Coordination Developer and Connecting Transmission Owner may each, in accordance with NYISO procedures and Good Utility Practice and in coordination with the other Party, remove from service any of its respective Attachment Facilities or System Upgrade Facilities and System Deliverability Upgrades that may impact the other Party’s facilities as necessary to perform maintenance or testing or to install or replace equipment. Absent an Emergency State, the Party scheduling a removal of such facility(ies) from service will use Reasonable Efforts to schedule such removal on a date and time mutually acceptable to both the Developer and the Connecting Transmission Owner. In all circumstances either Party planning to remove such facility(ies) from service shall use Reasonable Efforts to minimize the effect on the other Party of such removal.
Conditions of Eft Services (a.) Ownership of Card(s). Any Card we supply to you is our property and must be returned to us, or to any person whom we authorize to act as our agent, or to any person who is authorized to honor the Card, immediately according to instructions. The Card may be reclaimed at any time at our sole discretion without demand or notice. You cannot transfer your Card to another person.
