Project Costs Simultaneously with the execution of this Agreement, the Company shall disclose to the Department all of the Project Costs which the Company seeks to include for purposes of determining the limitation of the amount of the Credit pursuant to Section 5-30 of the Act and provide to the Department a Schedule of Project Costs in the form as attached hereto as Exhibit C.
Project Cost Overruns In the event that the Recipient determines that the moneys granted pursuant to Section II hereof, together with the Local Subdivision Contribution, are insufficient to pay in full the costs of the Project, the Recipient may make a request for supplemental assistance to its District Committee. The Recipient must demonstrate that such funding is necessary for the completion of the Project and the cost overrun was the result of circumstances beyond the Recipient's control, that it could not have been avoided with the exercise of due care, and that such circumstances could not have been anticipated at the time of the Recipient's initial application. Should the District Committee approve such request the action shall be recorded in the District Committee's official meeting minutes and provided to the OPWC Director for the execution of an amendment to this Agreement.
Construction Contract; Cost Budget Prior to execution of a construction contract, Tenant shall submit a copy of the proposed contract with the Contractor for the construction of the Tenant Improvements, including the general conditions with Contractor (the “Contract”) to Landlord for its approval, which approval shall not be unreasonably withheld, conditioned or delayed. Following execution of the Contract and prior to commencement of construction, Tenant shall provide Landlord with a fully executed copy of the Contract for Landlord’s records. Prior to the commencement of the construction of the Tenant Improvements, and after Tenant has accepted all bids and proposals for the Tenant Improvements, Tenant shall provide Landlord with a detailed breakdown, by trade, for all of Tenant’s Agents, of the final estimated costs to be incurred or which have been incurred in connection with the design and construction of the Tenant Improvements to be performed by or at the direction of Tenant or the Contractor (the “Construction Budget”), which costs shall include, but not be limited to, the costs of the Architect’s and Engineers’ fees and the Landlord Coordination Fee. The amount, if any, by which the total costs set forth in the Construction Budget exceed the amount of the Tenant Improvement Allowance is referred to herein as the “Over Allowance Amount”. In the event that an Over-Allowance Amount exists, then prior to the commencement of construction of the Tenant Improvements, Tenant shall supply Landlord with cash in an amount equal to the Over-Allowance Amount. The Over-Allowance Amount shall be disbursed by Landlord prior to the disbursement of any of the then remaining portion of the Tenant Improvement Allowance, and such disbursement shall be pursuant to the same procedure as the Tenant Improvement Allowance. In the event that, after the total costs set forth in the Construction Budget have been delivered by Tenant to Landlord, the costs relating to the design and construction of the Tenant Improvements shall change, any additional costs for such design and construction in excess of the total costs set forth in the Construction Budget shall be added to the Over-Allowance Amount and the total costs set forth in the Construction Budget, and such additional costs shall be paid by Tenant to Landlord immediately as an addition to the Over-Allowance Amount or at Landlord’s option, Tenant shall make payments for such additional costs out of its own funds, but Tenant shall continue to provide Landlord with the documents described in items (i), (ii), (iii) and (iv) of Section 2.2.2.1 of this Tenant Work Letter, above, for Landlord’s approval, prior to Tenant paying such costs. All Tenant Improvements paid for by the Over-Allowance Amount shall be deemed Landlord’s property under the terms of the Lease.
Initial Contribution of Trust Property; Organizational Expenses The Property Trustee acknowledges receipt in trust from the Depositor in connection with the Original Trust Agreement of the sum of $10, which constituted the initial Trust Property. The Depositor shall pay organizational expenses of the Trust as they arise or shall, upon request of any Trustee, promptly reimburse such Trustee for any such expenses paid by such Trustee. The Depositor shall make no claim upon the Trust Property for the payment of such expenses.
Construction Administration Phase Delete the following paragraph if Submittal Exchange isn’t going to be used: 2.
Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE
1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State.
1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent.
1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State.
1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress.
1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER.
1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period.
1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State.
1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work.
1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon.
1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval.
1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6.
1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover.
1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions.
1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment.
1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.
Disbursement of the Tenant Improvement Allowance Except as otherwise set forth in this Work Letter, the Tenant Improvement Allowance shall be disbursed by Landlord (each of which disbursements shall be made pursuant to Landlord’s disbursement process, which disbursement process shall require the Architect to make field verifications and written certifications as required by Landlord in connection with Landlord’s disbursements to Contractor (as defined below)) only for the following items and costs (collectively the “Tenant Improvement Allowance Items”):
(a) Payment of (i) the fees of the Architect and the Engineers (as defined below), (ii) charges for Landlord’s construction consultant and Building engineer, and (iii) the fees incurred by, and the cost of documents and materials supplied by, Landlord and Landlord’s consultants in connection with the preparation and review of the Construction Drawings (as defined below);
(b) The payment of plan check, permit and license fees relating to construction of the Tenant Improvements;
(c) The cost of construction of the Tenant Improvements, including, without limitation, any cost of after-hours freight elevator usage;
(d) The cost of any changes in the Base, Shell, and Core when such changes are required by the Construction Drawings, such cost to include all direct architectural and/or engineering fees and expenses incurred in connection therewith;
(e) The cost of any changes to the Construction Drawings or Tenant Improvements required by applicable laws and building codes (collectively, “Code”);
(f) Sales and use taxes; and
(g) All other costs to be expended by Landlord in connection with the construction of the Tenant Improvements. In no event shall the Tenant Improvement Allowance Items include any costs of procuring or installing in the Premises any trade fixtures, equipment, furniture, furniture partitions or systems, furnishings, telephone, telecommunications, data and security wiring, cabling and equipment, or other personal property (“Personal Property”) to be used in the Premises by Tenant, and the cost of such Personal Property shall be paid by Tenant.
Construction Phase Fee Contractor’s Construction Phase Fee is the maximum amount payable to Contractor for any cost or profit expectation incurred in the performance of the Work that is not specifically identified as being eligible for reimbursement by Owner elsewhere in this Agreement. References in the UGSC to Contractor’s “overhead” and “profit” mean Contractor’s Construction Phase Fee. The Construction Phase Fee includes, but is not limited to, the following items:
9.1 All profit, profit expectations and costs associated with profit sharing plans such as personnel bonuses, incentives, and rewards; company stock options; or any other like expenses of Contractor.
Actions of Custodian Based on Proper Instructions and Special Instructions So long as and to the extent that the Custodian acts in accordance with (a) Proper Instructions or Special Instructions, as the case may be, and (b) the terms of this Agreement, the Custodian shall not be responsible for the title, validity or genuineness of any property, or evidence of title thereof, received by it or delivered by it pursuant to this Agreement.
Selection Under a Fixed Budget Services for assignments which the Association agrees meet the requirements of paragraph 3.5 of the Consultant Guidelines may be procured under contracts awarded on the basis of a Fixed Budget in accordance with the provisions of paragraphs 3.1 and 3.5 of the Consultant Guidelines.
