Jurisdictional Disputes 17.01 A xxxx-up meeting will be held with each Contractor not later than the commencement of the Contractor's work on all projects and no assignments shall be made before this xxxx- up. Xxxx-up assignments shall also apply to all sub-contractors. If a jurisdictional dispute arises once the work has commenced, assignments will be made in accordance with procedures, rules and regulations of the National Joint Board Building Trades Department, A.F.L. & C.I.O. The work assignment shall not be completed until a meeting on site has been convened with all Parties involved and until a subsequent meeting (not later than twenty-four (24) hours) has taken place, at which the Contractor shall present the work assignment on paper to all Parties.
17.02 In the event such jurisdictional dispute cannot be settled on a Local basis by the Unions involved, such dispute shall be submitted to the International Unions involved for settlement without permitting it to interfere in any way with the progress of the work at any time. In the event the dispute is not settled by the International Unions involved, it shall then be submitted to the National Joint Board for resolution. It is understood and agreed, however, that if the dispute causes any delay in the progress of the work or gives rise to an apprehended delay, any of the Parties hereto may apply to the Labour Relations Board (Nova Scotia) Construction Panel for an Interim Order under Section 50 of the Trade Union Act, Chapter 311, R.S.N.S. 1967, amended.
Non-Jurisdictional Entities LIPA and NYPA do not waive their exemptions, pursuant to Section 201(f) of the FPA, from Commission jurisdiction with respect to the Commission’s exercise of the FPA’s general ratemaking authority.
Additional Actions If, at any time after the Effective Time, the Surviving Corporation shall consider or be advised that any deeds, bills of sale, assignments, assurances or any other actions or things are necessary or desirable to vest, perfect or confirm of record or otherwise in the Surviving Corporation its right, title or interest in, to or under any of the rights, properties or assets of Merger Sub or the Company or otherwise carry out this Agreement, the officers and directors of the Surviving Corporation shall be authorized to execute and deliver, in the name and on behalf of Merger Sub or the Company, all such deeds, bills of sale, assignments and assurances and to take and do, in the name and on behalf of Merger Sub or the Company, all such other actions and things as may be necessary or desirable to vest, perfect or confirm any and all right, title and interest in, to and under such rights, properties or assets in the Surviving Corporation or otherwise to carry out this Agreement.
Jurisdiction, Etc (a) Each party hereto hereby irrevocably and unconditionally agrees that it will not commence any action, litigation or proceeding of any kind or description, whether in law or equity, whether in contract or in tort or otherwise, against the Administrative Agent, any Lender, any LC Issuing Bank, or any Related Party of the foregoing in any way relating to this Agreement or any other Loan Document or the transactions relating hereto or thereto, in any forum other than the courts of the State of New York sitting in the Borough of Manhattan in New York City, and of the United States District Court of the Southern District of New York sitting in the Borough of Manhattan in New York City, and any appellate court from any thereof, and each of the parties hereto irrevocably and unconditionally submits to the jurisdiction of such courts and agrees that all claims in respect of any such action, litigation or proceeding may be heard and determined in such New York State court or, to the fullest extent permitted by applicable law, in such federal court. Each party hereto agrees that a final judgment in any such action, litigation or proceeding shall be conclusive and may be enforced in other jurisdictions by suit on the judgment or in any other manner provided by law.
(b) The Borrower irrevocably and unconditionally waives, to the fullest extent permitted by Applicable Law, any objection that it may now or hereafter have to the laying of venue of any action or proceeding arising out of or relating to this Agreement or any other Loan Document in any court referred to in paragraph (a) of this Section. Each of the parties hereto hereby irrevocably waives, to the fullest extent permitted by applicable law, the defense of an inconvenient forum to the maintenance of such action or proceeding in any such court.
(c) Each party hereto irrevocably consents to service of process in the manner provided for notices in Section 8.02. Nothing in this Agreement will affect the right of any party hereto to serve process in any other manner permitted by Applicable Law.
Jurisdiction and Process (a) Each Credit Party irrevocably submits to the non-exclusive jurisdiction of any New York State or federal court sitting in the Borough of Manhattan, The City of New York, over any suit, action or proceeding arising out of or relating to this Agreement (including the Multiparty Guaranty) or the Notes. To the fullest extent permitted by applicable law, each Credit Party irrevocably waives and agrees not to assert, by way of motion, as a defense or otherwise, any claim that it is not subject to the jurisdiction of any such court, any objection that it may now or hereafter have to the laying of the venue of any such suit, action or proceeding brought in any such court and any claim that any such suit, action or proceeding brought in any such court has been brought in an inconvenient forum.
(b) Each Credit Party consents to process being served by or on behalf of any holder of Notes in any suit, action or proceeding of the nature referred to in Section 22.8(a) by mailing a copy thereof by registered or certified mail (or any substantially similar form of mail), postage prepaid, return receipt requested, to it at its address specified in Section 18 or at such other address of which such holder shall then have been notified pursuant to said Section. Each Credit Party agrees that such service upon receipt (i) shall be deemed in every respect effective service of process upon it in any such suit, action or proceeding, and (ii) shall, to the fullest extent permitted by applicable law, be taken and held to be valid personal service upon and personal delivery to it. Notices hereunder shall be conclusively presumed received as evidenced by a delivery receipt furnished by the United States Postal Service or any reputable commercial delivery service.
(c) Nothing in this Section 22.8 shall affect the right of any holder of a Note to serve process in any manner permitted by law, or limit any right that the holders of any of the Notes may have to bring proceedings against any Credit Party in the courts of any appropriate jurisdiction or to enforce in any lawful manner a judgment obtained in one jurisdiction in any other jurisdiction.
Additional Action 10.1 Each Party to this Agreement shall execute and deliver such other documents and do such other acts and things as may be reasonably necessary or desirable to give effect to the provisions of this Agreement.
10.2 Nothing contained in the Agreement shall be construed as creating an obligation on the part of either Party to refrain from entering into a business relationship with any third party. Nothing contained in the Agreement shall be construed as creating a joint venture, partnership or employment relationship between the Parties. Except as specified herein, neither Party shall have the right, power or implied authority to create any obligation or duty (express, implied or otherwise) on behalf of the other Party. For the avoidance of doubt, nothing in this Agreement shall oblige either of the Parties to enter into any agreements or transactions whatsoever.
Criminal Actions Where an employee is charged with an offence resulting directly from the proper performance of his/her duties and is subsequently found not guilty, the employee shall be reimbursed for reasonable legal fees.
Certain Additional Actions Regarding Intellectual Property If any Event of Default shall have occurred and be continuing, upon the written demand of the Collateral Agent, each Pledgor shall execute and deliver to the Collateral Agent an assignment or assignments of the registered Patents, Trademarks and/or Copyrights and Goodwill and such other documents as are necessary or appropriate to carry out the intent and purposes hereof. Within five (5) Business Days of written notice thereafter from the Collateral Agent, each Pledgor shall make available to the Collateral Agent, to the extent within such Pledgor’s power and authority, such personnel in such Pledgor’s employ on the date of the Event of Default as the Collateral Agent may reasonably designate to permit such Pledgor to continue, directly or indirectly, to produce, advertise and sell the products and services sold by such Pledgor under the registered Patents, Trademarks and/or Copyrights, and such persons shall be available to perform their prior functions on the Collateral Agent’s behalf.
Jurisdiction of Organization During the term of the Receivables, CNHICA will maintain its “location” (as defined in Section 9-307 of the UCC) in one of the States.
Jurisdiction of Courts Québec hereby appoints the person from time to time who holds the position of Delegate General of Québec in New York, Xxx Xxxxxxxxxxx Xxxxx, 00xx xxxxx, Xxx Xxxx, Xxx Xxxx 00000-0000, as its authorized agent (the “Authorized Agent”) upon whom process may be served in any action by any Underwriter, or by any person controlling such Underwriter, and based upon this Agreement which may be instituted in any State or Federal court in The City of New York, and expressly accepts the non-exclusive jurisdiction of any such court in respect of such action. Québec hereby irrevocably waives any immunity to service of process in respect of any such action to which the Authorized Agent might otherwise be entitled. Such appointment shall be irrevocable as long as any of the Securities remain outstanding, except that, if for any reason the Authorized Agent ceases to be able to act as agent or no longer has an address in The City of New York, Québec will appoint another person or persons in The City of New York, selected in its discretion, as Authorized Agent(s). Québec will take any and all action, including the filing of any and all documents and instruments that may be necessary to continue such appointment or appointments in full force and effect as aforesaid. Service of process upon the Authorized Agent together with written notice of such service mailed or delivered to Québec at its address set forth in Section 11, shall be deemed in every respect effective service of process upon Québec. Notwithstanding the foregoing, any action by an Underwriter, or by any person controlling such Underwriter, and based upon this Agreement may be instituted in any competent court in Québec. Québec hereby waives, to the fullest extent permitted by applicable law, any immunity to jurisdiction to which it might otherwise be entitled in any action based on this Agreement which may be instituted as provided in this Section in any State or Federal court in The City of New York or in any competent court in Québec.
