Lease of Aircraft Lessor agrees to lease the Aircraft to Lessee pursuant to the provisions of FAR Section 91.501(b)(6) and Section 91.501(c)(1) and this Agreement, and to provide a fully-qualified and credentialed flight crew for all flights to be conducted hereunder during the Term (as defined in Section 13) hereof. The parties acknowledge and agree that this Agreement did not result in any way from any direct or indirect advertising, holding out or soliciting on the part of Lessor or any person purportedly acting on behalf of Lessor. Lessor and Lessee intend that the lease of the Aircraft effected by this Agreement shall be treated as a “wet lease” pursuant to which Lessor provides transportation services to Lessee in accordance with FAR Section 91.501(b)(6) and Section 91.501(c)(1).
Lease of Equipment Lessor leases to Lessee, and Lessee leases from Lessor, all the property described in the Lease Schedules which are signed from time to time by Lessor and Lessee.
Use of Partially Constructed Roads Unless Contracting Officer determines that there is justification under existing conditions and ground conditions permit hauling without undue damage, portions of Specified Roads shall be Substantially Completed prior to their use for hauling timber. When necessary to facilitate construction and protect bridges and roads from damage, timber felled in construction and timber logged directly to the road from areas immediately adjacent thereto may be hauled before road construction is Substantially Completed. Such hauling shall be confined to periods when abnormal soil erosion and damage to National Forest lands will not result.
Use of the Equipment 9.1 The Equipment shall be used by Hospital only at the Site and shall not be removed therefrom. Hospital shall use the Equipment only in the regular and ordinary course of Hospital's business operations and only within the capacity of the Equipment as determined by Elekta's specifications. Hospital shall not use nor permit the Equipment to be used in any manner nor for any purpose which, in the opinion of Elekta or GKF, the Equipment is not designed or reasonably suitable.
9.2 This is an agreement of lease only. Nothing herein shall be construed as conveying to Hospital any right, title or interest in or to the Equipment, except for the express leasehold interest granted to Hospital for the Term. All Equipment shall remain personal property (even though said Equipment may hereafter become attached or affixed to real property) and the title thereto shall at all times remain exclusively in GKF.
9.3 During the Term, upon the request of GKF, Hospital shall promptly affix to the Equipment in a prominent place, or as otherwise directed by GKF, labels, plates, insignia, lettering or other markings supplied by GKF indicating GKF's ownership of the Equipment, and shall keep the same affixed for the entire Term. Hospital hereby authorizes GKF to cause this Lease or any statement or other instrument showing the interest of GKF in the Equipment to be filed or recorded, or refiled or re-recorded, with all governmental agencies considered appropriate by GKF, at Hospital's cost and expense. Hospital also shall promptly execute and deliver, or cause to be executed and delivered, to GKF any statement or instrument requested by GKF for the purpose of evidencing GKF's interest in the Equipment, including financing statements and waivers with respect to rights in the Equipment from any owners or mortgagees of any real estate where the Equipment may be located.
9.4 At Hospital's cost and expense, Hospital shall (a) protect and defend GKF's ownership of and title to the Equipment from and against all persons claiming against or through Hospital, (b) at all times keep the Equipment free from any and all liens, encumbrances, attachments, levies, executions, burdens, charges or legal processes imposed against Hospital, (c) give GKF immediate written notice of any matter described in clause (b), and (d) in the manner described in Section 22 below indemnify GKF harmless from and against any loss, cost or expense (including reasonable attorneys' fees) with respect to any of the foregoing.
Lease of Premises Landlord hereby demises and leases to Tenant for the Term of this Lease and upon the terms and conditions hereinafter set forth, and Tenant hereby accepts from Landlord, the Premises.
Use of Words and Phrases Herein," "hereby," "hereunder," "hereof," "hereinbefore," "hereinafter" and other equivalent words refer to the Pooling and Servicing Agreement as a whole. All references herein to Articles, Sections or Subsections shall mean the corresponding Articles, Sections and Subsections in the Pooling and Servicing Agreement. The definitions set forth herein include both the singular and the plural.
Early Construction of Base Case Facilities Developer may request Connecting Transmission Owner to construct, and Connecting Transmission Owner shall construct, subject to a binding cost allocation agreement reached in accordance with Attachment S to the ISO OATT, including Section 25.8.7 thereof, using Reasonable Efforts to accommodate Developer’s In-Service Date, all or any portion of any System Upgrade Facilities or System Deliverability Upgrades required for Developer to be interconnected to the New York State Transmission System which are included in the Base Case of the Class Year Study for the Developer, and which also are required to be constructed for another Developer, but where such construction is not scheduled to be completed in time to achieve Developer’s In-Service Date.
Suspension of unsafe Construction Works (i) Upon recommendation of the Authority’s Engineer to this effect, the Authority may by notice require the Contractor to suspend forthwith the whole or any part of the Works if, in the reasonable opinion of the Authority’s Engineer, such work threatens the safety of the Users and pedestrians.
(ii) The Contractor shall, pursuant to the notice under Clause 11.17 (i), suspend the Works or any part thereof for such time and in such manner as may be specified by the Authority and thereupon carry out remedial measures to secure the safety of suspended works, the Users and pedestrians. The Contractor may by notice require the Authority’s Engineer to inspect such remedial measures forthwith and make a report to the Authority recommending whether or not the suspension hereunder may be revoked. Upon receiving the recommendations of the Authority’s Engineer, the Authority shall either revoke such suspension or instruct the Contractor to carry out such other and further remedial measures as may be necessary in the reasonable opinion of the Authority, and the procedure set forth in this Clause 11.17 shall be repeated until the suspension hereunder is revoked.
(iii) Subject to the provisions of Clause 21.6, all reasonable costs incurred for maintaining and protecting the Works or part thereof during the period of suspension (the “Preservation Costs”), shall be borne by the Contractor; provided that if the suspension has occurred as a result of any breach of this Agreement by the Authority, the Preservation Costs shall be borne by the Authority.
(iv) If suspension of Works is for reasons not attributable to the Contractor, the Authority’s Engineer shall determine any Time Extension to which the Contractor is reasonably entitled.
Use of Premises Tenant shall not use the premises or any part thereof, or permit the premises or any part thereof to be used, for any purpose other than the use hereinabove specifically mentioned, subject, however, to all the covenants, agreements, terms, provisions and conditions of this Lease. Those portions, if any, of the premises which on the plan(s) attached hereto are shown as toilets and utility areas shall be used by Tenant only for the purposes for which they are designed. Tenant will not at any time use or occupy the premises or any part thereof, or permit the premises or any part thereof to be used or occupied, in violation of the certificate of occupancy (temporary or final) issued for the Building and/or the premises. Tenant shall not xxx or permit the use of the premises or any part thereof in any way which would violate any of the covenants, agreements, terms, provisions and conditions of this Lease or for any unlawful purposes or in any unlawful manner and Tenant shall not suffer or permit the premises or any part thereof to be used in any manner or anything to be done therein or suffer or permit anything to be brought into or kept in the premises which, in the judgment of Landlord, shall in any way impair or tend to impair the character, reputation or appearance of the Building as a first-class office building, impair or interfere with or tend to impair or interfere with any of the Building services or the proper and economic heating, cleaning, air conditioning or other servicing of the Building or the premises, or impair or interfere with or tend to impair or interfere with the use of any of the other areas of the Building by, or occasion discomfort, inconvenience or annoyance to, any of the other tenants or occupants of the Building. Tenant shall not install any electrical or other equipment of any kind which, in the judgment of Landlord, might cause any such impairment, interference, discomfort, inconvenience or annoyance. Except as set forth in Article 1 hereof, Tenant will not, and will not permit anyone to, sell or traffic in any spirituous liquors, wine, ale or beer in or from the premises or carry on any manufacturing in the premises. If any governmental license or permit shall be required for the proper and lawful conduct of Tenant's business or other activity carried on it the premises, Tenant, at Tenant's expense, shall duly procure and thereafter maintain such license or permit and submit the same to inspection by Landlord. Tenant, at Tenant's expense, shall, at all times, comply with the terms and conditions of each license or permit.
Use of Aircraft Employees shall not be required to use an aircraft in the course of their duties other than those of regular commercial airlines, licensed charters, or government aircraft.
