Payment of Checks, Drafts and Orders Subject to Section 9.5, the Assuming Institution agrees to pay all properly drawn checks, drafts and withdrawal orders of depositors of the Failed Bank presented for payment, whether drawn on the check or draft forms provided by the Failed Bank or by the Assuming Institution, to the extent that the Deposit balances to the credit of the respective makers or drawers assumed by the Assuming Institution under this Agreement are sufficient to permit the payment thereof, and in all other respects to discharge, in the usual course of conducting a banking business, the duties and obligations of the Failed Bank with respect to the Deposit balances due and owing to the depositors of the Failed Bank assumed by the Assuming Institution under this Agreement.
Inspection of Agreement A copy of this Agreement shall be available at all reasonable times at the principal corporate trust office of the Warrant Agent for inspection by the holder of any Warrant Certificate. The Warrant Agent may require such holder to submit his Warrant Certificate for inspection by it.
Construction of Agreement The parties mutually acknowledge that they and their attorneys have participated in the preparation and negotiation of this Agreement. In cases of uncertainty this Agreement shall be construed without regard to which of the parties caused the uncertainty to exist.
Performance and Compliance with Contracts and Credit and Collection Policy The Seller shall (and shall cause the Servicer to), at its expense, timely and fully perform and comply with all material provisions, covenants and other promises required to be observed by it under the Contracts related to the Receivables, and timely and fully comply in all material respects with the applicable Credit and Collection Policies with regard to each Receivable and the related Contract.
Selection of Subcontractors, Procurement of Materials and Leasing of Equipment The contractor shall not discriminate on the grounds of race, color, religion, sex, national origin, age or disability in the selection and retention of subcontractors, including procurement of materials and leases of equipment. The contractor shall take all necessary and reasonable steps to ensure nondiscrimination in the administration of this contract.
a. The contractor shall notify all potential subcontractors and suppliers and lessors of their EEO obligations under this contract.
b. The contractor will use good faith efforts to ensure subcontractor compliance with their EEO obligations.
Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE
1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State.
1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent.
1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State.
1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress.
1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER.
1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period.
1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State.
1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work.
1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon.
1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval.
1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6.
1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover.
1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions.
1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment.
1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.
CERTIFICATION OF AGREEMENT In accordance with section 170LT of the Workplace Relations Act 1996, I now certify the attached written agreement. This agreement shall come into force from 16 February 2004 and shall remain in force until 31 October 2005. BY THE COMMISSION: Printed by authority of the Commonwealth Government Printer <Price code 70> TABLE OF CONTENTS Subject Matter Clause No. Page No. Accident Pay 29 32 All-In Payments 34 34 Alpine Areas 14.1.(b) 15 Altona Area Allowance 14.2.(a) 16 Amenities 37 35 Apprentices 22.(a) 23 Australian Materials 41 37 Casual Labour 12.2 13 Classification Structure & Rates of Pay, Allowances 13 14 Clothing Issue & Safety Footwear 40 36 Co-Invest (Long Service Leave) 27 31 Commitments 3 5 Consultation 8 7 Demolition Work 14.1.(d) 16 Dispute Settlement Procedure 9 8 Drugs & Alcohol 38 35 Employment & Termination 12 12 Fares & Travel Allowance 15 17 Fast Food Allowance 14.1.(a) 15 Further Flexibilities 23 24 Geelong, Altona, Portland, etc Metals Agreements 14.3 16 Geographic Area, and Sector Specific Allowances, Conditions and Exceptions 14 15 Hearing Tests 11.(2) 10 Heavy Blocks 11.(9) 12 Hours Of work, Rostered Days Off, and Protection of Leisure Time 17 17 Inclement Weather 24 24 Income Protection 28.1 31 Income Protection & Trauma Insurance 28 31 Induction Procedures 11.(4) 11 Job Stewards/Delegates 36 34 Job Xxxxxxx/Delegate Facilities 36.2 35 Journey Accidents 30 32 Latrobe Valley Allowance 14.2.(b) 16 Leisure Time Protected 17.3 18 Living Away from Home Allowance 16 17 Major Events 14.1.(c) 15 Metal Trades Labour Hire Agreement 14.4 16 Negotiation of a Subsequent Agreement 43 37 No Extra Claims 44 38 Objectives of the Agreement 2 5 Overtime 17.2 18 Parties and Persons Bound 4 6 Payment of Wages 19 21 Period of Operation 6 6 Picnic Day 31 33 Project Agreements 5.2 6 Project Pre-Commencement Conference 18 21 Protective Clothing & Equipment 11.(3) 10 Pyramid Subcontracting 35 34 Redundancy 25 30 Rehabilitation Program 39 35 Relationship to Parent Award and Victorian Building Industry Agreement 7 6 Right of Entry & Representation 33 33 Rostered Days Off 17.4 19 Safety Dispute Resolution 10 8 Scope & Application 5 6 Security & Continuity of Employment 32 33 Service Core Allowance 14.2.(c) 16 Signatories 45 39 Superannuation 26 30 Termination of Employment 12.3 13 Time & Wages Records 19.1 21 Title 1 5 Tool Storage 20 22 Toxic Substances 11(8) 11 Training & Related Matters 22 23 Trauma Insurance 28.2 32 Waste Minimisation, Recycling and Environmental Issues 42 37 Workplace Safety 11 10 Appendix A – Classification Structure 40 Appendix B – Rates of Pay 1. From 1 December 2002 2. From 1 March 2003 3. From 1 March 2004 4. From 1 March 2005 41 Appendix C – Site Allowances 51 Appendix D – Drugs & Alcohol Policy 54 Appendix E – Passenger and Material Lifts 61 Appendix F – Amenities 63 Appendix G – Shopping Centres 66 Appendix H – Trade Union Training Leave 67 Appendix I – Sector Appendix 70
Incorporation of Terms in Subcontracts a. Grantee will include in all its contracts with subrecipient subcontractors and solicitations for subrecipient subcontracts, without modification (except as required to make applicable to the subcontract):
1. Statement of Work
2. Uniform Terms and Conditions
3. Special Conditions
4. Federal Assurances and Certifications
5. Non-Exclusive List of Applicable Laws
6. A provision granting to the System Agency, State Auditor's Office (SAO), Office of Inspector General (OIG), and the Comptroller General of the United States, and any of their representatives, the right of access to inspect the work and the premises on which any work is performed, and the right to audit the subcontractor.
b. Grantee will ensure that all written agreements with subcontractors incorporate the terms of this Contract so that all terms, conditions, provisions, requirements, duties and liabilities under this Contract applicable to the services provided or activities conducted by a subcontractor are passed down to that subcontractor.
c. No provision of this Contract creates privity of contract between the System Agency and any subcontractor of Grantee.
Copies of Contract Documents to Contractor Without charge to the Contractor the Design Professional shall furnish to the Contractor up to five sets of completed Contract Documents in hardcopy, one set of reproducible and electronic background floor and reflected ceiling plan drawings and, if requested, one copy in read-only electronic format. The Contractor may obtain such additional sets of Contract Documents, as the Contractor deems necessary and shall pay the cost of reproduction of such additional sets to the Design Professional.
Operation of Agreement This Agreement will be effective and binding immediately upon its execution, but, anything in this Agreement to the contrary notwithstanding, this Agreement will not be operative unless and until a Change in Control occurs. Upon the occurrence of a Change in Control at any time during the Term, without further action, this Agreement shall become immediately operative.
