Operations and Maintenance Notice Each Party shall notify the other Parties in writing of the identity of the person(s) that it designates as the point(s) of contact with respect to the implementation of Articles 9 and 10.
Operation and Maintenance 17.1 O&M obligations of the Concessionaire
17.1.1 During the Operation Period, the Concessionaire shall operate and maintain the Bus Terminal in accordance with this Agreement either by itself, or through the O&M Contractor and if required, modify, repair or otherwise make improvements to the Bus Terminal to comply with the provisions of this Agreement, Applicable Laws and Applicable Permits, and conform to Specifications and Standards and Good Industry Practice. The obligations of the Concessionaire hereunder shall include:
(a) permitting safe, smooth and uninterrupted flow of traffic on the Bus Terminal during normal operating conditions. Buses of other state road transport corporations shall be parked inside the Bus Terminal for which no charges shall be payable to the Concessionaire and if any charges are applicable for such parking then it shall be realized by Authority only;
(b) minimising incidents affecting the safety and use of the Bus Terminal by providing a rapid and effective response and maintaining liaison with emergency services of the State;
(c) carrying out periodic preventive maintenance of the Bus Terminal;
(d) undertaking routine maintenance including prompt repairs of ticket counters, Workshops, Authority's Office and other infrastructure as mentioned in the Operation and Maintenance Schedule;
(e) undertaking major maintenance such as per the Maintenance Schedule of the major infrastructure in the Bus Terminal;
(f) preventing, with the assistance of the concerned law enforcement agencies, any encroachments on the Bus Terminal;
(g) protection of the environment and provision of equipment and materials therefor;
(h) operation and maintenance of all communication, control and administrative systems necessary for the efficient operation of the Bus Terminal;
(i) maintaining a public relations unit to interface with and attend to suggestions from the Users, passengers, government agencies, media and other agencies;
(j) complying with Safety Requirements in accordance with Article 18;
(k) operation and maintenance of all Project Assets diligently and efficiently and in accordance with Good Industry Practice;
(l) maintaining punctuality and reliability in operating the Bus Terminal; and
(m) maintaining a high standard of cleanliness and hygiene in the Bus Terminal.
17.1.2 The Concessionaire shall remove promptly from the Bus Terminal all surplus construction machinery and materials, waste materials (including hazardous materials and waste water), rubbish and other debris (including, without limitation, accident debris) and keep the Bus Terminal in a clean, tidy and orderly condition,
Operation of Agreement This Agreement will be effective and binding immediately upon its execution, but, anything in this Agreement to the contrary notwithstanding, this Agreement will not be operative unless and until a Change in Control occurs. Upon the occurrence of a Change in Control at any time during the Term, without further action, this Agreement shall become immediately operative.
Notifications of Outages and Maintenance In the event that a Registry Operator plans maintenance, it will provide notice to the ICANN emergency operations department, at least, twenty-‐four (24) hours ahead of that maintenance. ICANN’s emergency operations department will note planned maintenance times, and suspend Emergency Escalation services for the monitored services during the expected maintenance outage period. If Registry Operator declares an outage, as per its contractual obligations with ICANN, on services under a service level agreement and performance requirements, it will notify the ICANN emergency operations department. During that declared outage, ICANN’s emergency operations department will note and suspend emergency escalation services for the monitored services involved.
Application and Operation of Agreement Table Of Contents
Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE
1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State.
1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent.
1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State.
1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress.
1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER.
1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period.
1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State.
1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work.
1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon.
1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval.
1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6.
1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover.
1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions.
1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment.
1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.
Account Maintenance Trade Allocations Trade Reporting; (Futures) Daily Trade Checkout Daily Statement Reconciliation
Operation and Maintenance of Properties The Borrower will, and will cause each of its Subsidiaries to:
(a) operate its Oil and Gas Properties and other material Properties or cause such Oil and Gas Properties and other material Properties to be operated in a careful and efficient manner in accordance with the practices of the industry and in compliance with all applicable contracts and agreements and in compliance with all Governmental Requirements, including, without limitation, applicable proration requirements and Environmental Laws, and all applicable laws, rules and regulations of every other Governmental Authority from time to time constituted to regulate the development and operation of its Oil and Gas Properties and the production and sale of Hydrocarbons and other minerals therefrom, except, in each case, where the failure to comply could not reasonably be expected to have a Material Adverse Effect.
(b) keep and maintain all Property material to the conduct of its business in good working order and condition, ordinary wear and tear excepted preserve, maintain and keep in good repair, working order and efficiency (ordinary wear and tear excepted) all of its material Oil and Gas Properties and other material Properties, including, without limitation, all material equipment, machinery and facilities.
(c) promptly pay and discharge, or make reasonable and customary efforts to cause to be paid and discharged, all delay rentals, royalties, expenses and indebtedness accruing under the leases or other agreements affecting or pertaining to its Oil and Gas Properties and will do all other things necessary to keep unimpaired their rights with respect thereto and prevent any forfeiture thereof or default thereunder.
(d) promptly perform or make reasonable and customary efforts to cause to be performed, in accordance with industry standards and in all material respects, the obligations required by each and all of the assignments, deeds, leases, sub-leases, contracts and agreements affecting its interests in its Oil and Gas Properties and other material Properties.
(e) to the extent the Borrower or one of its Subsidiaries is not the operator of any Property, the Borrower shall use reasonable efforts to cause the operator to comply with this Section 8.06.
Operations and Maintenance Seller shall not during the months of June through September inclusive schedule any non-emergency maintenance that reduces the energy generating capability of the Facility by more than ten percent (10%), unless (i) such outage is required to avoid damage to the Facility, (ii) such maintenance is necessary to maintain equipment warranties and cannot be scheduled outside the months of June through September, (iii) such outage is required in accordance with prudent electrical practices, or (iv) the Parties agree otherwise in writing.
Discretion in relation to card/facilities Notwithstanding and without prejudice to the other provisions of this agreement, we are entitled to, at any time in our reasonable discretion with reasonable notice and without giving any reason:-
(a) increase or decrease the combined credit limit; and/or
(b) refuse to re-issue, renew or replace the card; and/or
(c) introduce, amend, vary, terminate or withdraw all or any of the benefits, services, facilities and privileges in respect of or in connection with your card account and your being a cardmember (e.g. preferential interest rate balance transfer programs, instalment plans, exclusive invitations to events, access to health, travel, credit balance repayment insurance offered in collaboration with key insurance companies) whether specifically relating to you or generally to all cardmembers. Updated information on the benefits, services, facilities and privileges will be provided by us via such means as we deem appropriate including via our online portal xxx.xxxxxxxx.xxx.xx.
