Liability to HCOL Sample Clauses

Liability to HCOL. (i) Without prejudice to Sub-clause 13(a) of Part II, the Technical Contractor shall be under no liability whatsoever to HCOL for any loss, damage, delay or expense of whatsoever nature, whether direct or indirect, (including but not limited to loss of profit arising out of or in connection with detention of or delay to the Vessel) and howsoever arising in the course of performance of the Technical Services pertaining to the Agreement UNLESS same is proved to have resulted solely from the negligence, gross negligence or wilful default of the Technical Contractor or its employees or agents, or subcontractors employed by them in connection with the Vessel, in which case (save where loss, damage, delay or expenses has resulted from the Technical Contractor's personal act or omission committed with the intent to cause same or recklessly and with knowledge that such acts would probably result in loss, damage, delay or expense) the Technical Contractor’s liability for each incident or series of incidents giving rise to a claim or claims shall never exceed a total of ten (10) times the Fee payable hereunder. (ii) Acts or omissions of the Crew; notwithstanding anything that may appear to the contrary in this Agreement, the Technical Contractor shall not be liable for any acts or omissions of the Crew, even if such acts or omissions are negligent, grossly negligent or wilful, except only to the extent that they are shown to have resulted from a direct instruction of the Technical Contractor, in which case the Crew’s liability shall be limited in accordance with the terms of this Clause 13 (Responsibilities).
Sample 1
AutoNDA by SimpleDocs

Related to Liability to HCOL

  • Your liability to us (alleged) illegal use, etc (a) This clause applies where: (i) your Service is actually or allegedly used in a way that breaches any law or infringes the rights of any third party; and (ii) we suffer loss or reasonably incur expense as a result. (b) You must make good our loss and reimburse our expenses on request.

  • Our Liability to You 8.1 We will not be liable to You in respect of any losses You or the Card User may suffer in connection with or arising from the Card, except where such losses are due to a breach by us of this Agreement or due to Our negligence. In addition, We will not be liable for disputes concerning the quality of goods or services purchased from any merchant that accepted a Card or for any additional fees charged by the operator of POS or ATM terminals (e.

  • Liability to Third Parties The Member shall not be liable for the debts, obligations or liabilities of the Company, including under a judgment, decree or order of a court.

  • Warranty of Ability to Perform The Contractor warrants that, to the best of its knowledge, there is no pending or threatened action, proceeding, or investigation, or any other legal or financial condition, that would in any way prohibit, restrain, or diminish the Contractor’s ability to satisfy its Contract obligations. The Contractor warrants that neither it nor any affiliate is currently on the convicted vendor list maintained pursuant to section 287.133 of the Florida Statutes, or on any similar list maintained by any other state or the federal government. The Contractor shall immediately notify the Customer in writing if its ability to perform is compromised in any manner during the term of the Contract.

  • Ability to Abandon CVR A Holder may at any time, at such Holder’s option, abandon all of such Holder’s remaining rights in a CVR by transferring such CVR to Parent without consideration therefor. Nothing in this Agreement is intended to prohibit Parent from offering to acquire CVRs for consideration in its sole discretion.

  • No Liability to Third Parties No person who is or has been a Trustee, officer, or employee of the Trust shall be subject to any personal liability whatsoever to any Person, other than the Trust or its Shareholders, in connection with the affairs of the Trust; and all Persons shall look solely to the Trust Property or Property of a Series for satisfaction of claims of any nature arising in connection with the affairs of the Trust or such Series. Every note, bond, contract, instrument, certificate, Share or undertaking and every other act or thing whatsoever executed or done by or on behalf of the Trust or the Trustees or any of them in connection with the Trust shall be conclusively deemed to have been executed or done only in or with respect to their or his capacity as Trustees or Trustee and neither such Trustees or Trustee nor the Shareholders shall be personally liable thereon. All Persons extending credit to, contracting with or having any claim against the Trust or a Series shall look only to the assets of the Trust Property or the Trust Property of such Series for payment under such credit, contract or claim; and neither the Trustees, nor any of the Trust's officers, employees or agents, whether past, present or future, shall be personally liable therefor.

  • Liability towards each other 5.1 No warranties

  • WAIVER OF SPECIAL DAMAGES THE BORROWER WAIVES, TO THE MAXIMUM EXTENT NOT PROHIBITED BY LAW, ANY RIGHT THE UNDERSIGNED MAY HAVE TO CLAIM OR RECOVER FROM THE BANK IN ANY LEGAL ACTION OR PROCEEDING ANY SPECIAL, EXEMPLARY, PUNITIVE OR CONSEQUENTIAL DAMAGES.

  • WARRANTY OF CONTRACTOR’S ABILITY TO PERFORM The Contractor warrants that, to the best of its knowledge, there is no pending or threatened action, proceeding, or investigation, or any other legal or financial condition, that would in any way prohibit, restrain, or diminish the Contractor’s ability to satisfy its Contract obligations. The Contractor warrants that neither it nor any affiliate is currently on the Suspended Vendor List, Convicted Vendor List, or the Discriminatory Vendor List, or on any similar list maintained by any other state or the federal government. The Contractor shall immediately notify the Department in writing if its ability to perform is compromised in any manner during the term of the Contract. Contractor’s candidates shall complete this Resume Self-Certification Form. Completed Resume Self-Certification Forms shall be submitted within the Contractor’s response to Customer’s requests for quote. “I the undersigned do hereby certify, under the penalty of perjury, that information in my resume submitted for consideration of the State of Florida contract position is true, correct, complete, and made in good faith to the best of my knowledge and belief. If an omission, falsification, misstatement, or misrepresentation has been made regarding my education, work ability, experience, employment history, and/or fitness for employment as a contractor, I may be disqualified as a contractor, and the matter will be reported to appropriate agency or law enforcement personnel. I understand that there may be civil and/or criminal penalties for misrepresenting pertinent information in connection with contract positions, including, but not limited to, penalties available under sections 287.133 or 817.566, Florida Statutes. I further understand that if I am not a United States citizen, violation cases may be reported to the US Department of Homeland Security for potential deportation.” “In addition, I the undersigned do hereby consent to the release of my information by employers, educational institutions, law enforcement agencies, and other individuals and organizations to investigators and other authorized agents of Florida for verification and investigation purposes. I understand that any documents submitted to procure a contract(s) with the State of Florida, including resumes, are public records.” Print Full Legal Name of Candidate Candidate’s Signature Date Candidate’s Form of Identification Presented Identification number Contractor’s Witness Signature One Date Contractor’s Witness Signature Two Date Print Name Contractor’s Witness One Print Name Contractor’s Witness Two Customers shall complete this Contractor Selection Justification Form for each candidate selected and attach all completed forms to the purchase order. Date: Contractor’s Name: Contractor’s Contact Information: Candidate’s Name: Address: _ Phone: _ Email: Date Candidate will be available: _ Hourly rate of candidate: $ Position candidate recommended for: _ Justification for selection of candidate: _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ Agency: Division/Section/Unit: _ Printed Name: _ Title: _ Signature _ Date: Contractor's Name: Quarter: Purchase Order (PO) Number: PO Total $ Amount: PO Starting Date Ending Date Please review the attached Rating Definitions and provide your opinion by rating the following: 1. Effectiveness performing tasks 2. Quality & completeness of work 3 ❒ 3 ❒ 2 ❒ 2 ❒ 1 ❒ 1 ❒

  • Ability to Service The Servicer is an approved seller/servicer of conventional residential mortgage loans for Xxxxxx Xxx or Xxxxxxx Mac, with the facilities, procedures and experienced personnel necessary for the sound servicing of mortgage loans of the same type as the Mortgage Loans. The Servicer is in good standing to service mortgage loans for either Xxxxxx Mae or Xxxxxxx Mac. The Servicer is a member in good standing of the MERS system;

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!