Limit of CID’s Liability for Increased Costs Sample Clauses

Limit of CID’s Liability for Increased Costs. In connection with any claim by Firm against CID for compensation in excess of the Contract Price, any liability of CID (1) shall be strictly limited to the Cost of the Work and Services as allowed in hereinabove and shall in no event include indirect, consequential impact, or other costs, expenses, or damages of Firm or its Subconsultants. CID shall not be liable to Firm for claims of third parties, including Subconsultants, for acts, omissions, events, or conditions for which XXX would not be liable to Firm under the terms of the Contract. As a condition precedent to XXX's liability to Firm for any loss or damage resulting from claims of third parties, including Subconsultants, such third parties must have complied with all conditions contained in their agreements with Firm and such claims must have been submitted to CID by Firm in strict compliance with all the requirements of this Section 8. CID shall not be liable to Firm for claims of third parties including Subconsultants, unless and until the liability of Firm therefore has been established in a court of competent jurisdiction.
Sample 1
AutoNDA by SimpleDocs

Related to Limit of CID’s Liability for Increased Costs

  • Limitation of Liability of the Adviser; Indemnification The Adviser (and its officers, managers, partners, agents, employees, controlling persons, members and any other person or entity affiliated with the Adviser, including without limitation its general partner and the Administrator) shall not be liable to the Corporation for any action taken or omitted to be taken by the Adviser in connection with the performance of any of its duties or obligations under this Agreement or otherwise as an investment adviser of the Corporation, except to the extent specified in Section 36(b) of the Investment Company Act concerning loss resulting from a breach of fiduciary duty (as the same is finally determined by judicial proceedings) with respect to the receipt of compensation for services, and the Corporation shall indemnify, defend and protect the Adviser (and its officers, managers, partners, agents, employees, controlling persons, members and any other person or entity affiliated with the Adviser, including without limitation its general partner and the Administrator, each of whom shall be deemed a third party beneficiary hereof) (collectively, the “Indemnified Parties”) and hold them harmless from and against all damages, liabilities, costs and expenses (including reasonable attorneys’ fees and amounts reasonably paid in settlement) incurred by the Indemnified Parties in or by reason of any pending, threatened or completed action, suit, investigation or other proceeding (including an action or suit by or in the right of the Corporation or its security holders) arising out of or otherwise based upon the performance of any of the Adviser’s duties or obligations under this Agreement or otherwise as an investment adviser of the Corporation. Notwithstanding the preceding sentence of this Paragraph 9 to the contrary, nothing contained herein shall protect or be deemed to protect the Indemnified Parties against or entitle or be deemed to entitle the Indemnified Parties to indemnification in respect of, any liability to the Corporation or its security holders to which the Indemnified Parties would otherwise be subject by reason of willful misfeasance, bad faith or gross negligence in the performance of the Adviser’s duties or by reason of the reckless disregard of the Adviser’s duties and obligations under this Agreement (as the same shall be determined in accordance with the Investment Company Act and any interpretations or guidance by the Securities and Exchange Commission or its staff thereunder).

  • Exception to Right of Indemnification or Advance of Expenses Notwithstanding any other provision of this Agreement, Indemnitee shall not be entitled to indemnification or advance of Expenses under this Agreement with respect to any Proceeding brought by Indemnitee, unless (a) the Proceeding is brought to enforce indemnification under this Agreement, and then only to the extent in accordance with and as authorized by Sections 8 and 11 of this Agreement, or (b) the Company's Bylaws, as amended, the Charter, a resolution of the stockholders entitled to vote generally in the election of directors or of the Board of Directors or an agreement approved by the Board of Directors to which the Company is a party expressly provide otherwise.

  • Additional Indemnification; Limitation of Liability A. Subject to Section 2(A), USBFS CANNOT AND DOES NOT GUARANTEE AVAILABILITY OF THE ELECTRONIC SERVICES. Accordingly, USBFS’s sole liability to the Trust or any third party (including End Users) for any claims, notwithstanding the form of such claims (e.g., contract, negligence, or otherwise), arising out of the delay of or interruption in the Electronic Services to be provided by USBFS hereunder shall be to use its best reasonable efforts to commence or resume the Electronic Services as promptly as is reasonably possible. B. USBFS shall, at its sole cost and expense, defend, indemnify, and hold harmless the Trust and its trustees, officers and employees from and against any and all claims, demands, losses, expenses and liabilities of any and every nature (including reasonable attorneys’ fees) arising out of or relating to (a) any infringement, or claim of infringement, of any United States patent, trademark, copyright, trade secret, or other proprietary rights based on the use or potential use of the Electronic Services and (b) the provision of the Trust Files (as defined below) or Confidential Information (as defined below) to a person other than a person to whom such information may be properly disclosed hereunder. C. If an injunction is issued against the Trust’s use of the Electronic Services by reason of infringement of a patent, copyright, trademark, or other proprietary rights of a third party, USBFS shall, at its own option and expense, either (i) procure for the Trust the right to continue to use the Electronic Services on substantially the same terms and conditions as specified hereunder, or (ii) after notification to the Trust, replace or modify the Electronic Services so that they become non-infringing, provided that, in the Trust’s judgment, such replacement or modification does not materially and adversely affect the performance of the Electronic Services or significantly lessen their utility to the Trust. If in the Trust’s judgment, such replacement or modification does materially adversely affect the performance of the Electronic Services or significantly lessen their utility to the Trust, the Trust may terminate all rights and responsibilities under this Exhibit C immediately on written notice to USBFS. D. Because the ability of USBFS to deliver Electronic Services is dependent upon the Internet and equipment, software, systems, data and services provided by various telecommunications carriers, equipment manufacturers, firewall providers and encryption system developers and other vendors and third parties, USBFS shall not be liable for delays or failures to perform its obligations hereunder to the extent that such delays or failures are attributable to circumstances beyond its reasonable control which interfere with the delivery of the Electronic Services by means of the Internet or any of the equipment, software and services which support the Internet provided by such third parties. USBFS shall also not be liable for the actions or omissions of any third party wrongdoers (i.e., hackers not employed by USBFS or its affiliates) or of any third parties involved in the Electronic Services and shall not be liable for the selection of any such third party, unless USBFS selected the third party in bad faith or in a grossly negligent manner. E. USBFS shall not be responsible for the accuracy of input material from End Users nor the resultant output derived from inaccurate input. The accuracy of input and output shall be judged as received at USBFS’s data center as determined by the records maintained by USBFS. F. Notwithstanding anything to the contrary contained herein, USBFS shall not be obligated to ensure or verify the accuracy or actual receipt, or the transmission, of any data or information contained in any transaction via the Electronic Services or the consummation of any inquiry or transaction request not actually reviewed by USBFS.

  • Limitation of Liability of Sub-Adviser and Indemnification Sub-Adviser shall not be liable for any costs or liabilities arising from any error of judgment or mistake of law or any loss suffered by the Fund or the Trust in connection with the matters to which this Contract relates except a loss resulting from willful misfeasance, bad faith or gross negligence on the part of Sub-Adviser in the performance by Sub-Adviser of its duties or from reckless disregard by Sub-Adviser of its obligations and duties under this Contract. Any person, even though also an officer, partner, employee, or agent of Sub-Adviser, who may be or become a Trustee, officer, employee or agent of the Trust, shall be deemed, when rendering services to a Fund or the Trust or acting with respect to any business of a Fund or the Trust to be rendering such service to or acting solely for the Fund or the Trust and not as an officer, partner, employee, or agent or one under the control or direction of Sub-Adviser even though paid by it.

  • Liability for Specific Obligations The Administrator will be liable only for its specific obligations under this Agreement. All other liability is expressly waived and released as a condition of, and consideration for, the execution of this Agreement by the Administrator. The Administrator will be liable for its willful misconduct, bad faith or negligence in performing its obligations under this Agreement.

  • Liability for Incidental and Consequential Damages Contractor shall be responsible for incidental and consequential damages resulting in whole or in part from Contractor’s acts or omissions.

  • Liability of Servicer; Indemnification (a) The Servicer shall not be relieved of its obligations under this Agreement notwithstanding any Sub-Servicing Agreement or any of the provisions of this Agreement relating to agreements or arrangements between the Servicer and a Sub-Servicer and the Servicer shall be obligated to the same extent and under the same terms and conditions as if it alone were servicing and administering the Home Equity Loans. The Servicer shall be entitled to enter into any agreement with a Sub-Servicer for indemnification of the Servicer by such Sub-Servicer and nothing contained in such Sub-Servicing Agreement shall be deemed to limit or modify this Agreement. (b) The Servicer agrees to indemnify and hold the Trustee, the Depositor and each Owner harmless against any and all claims, losses, penalties, fines, forfeitures, legal fees and related costs, judgments, and any other costs, fees and expenses that the Trustee, the Depositor and any Owner may sustain in any way related to the failure of the Servicer to perform its duties and service the Home Equity Loans in compliance with the terms of this Agreement. The Servicer shall immediately notify the Trustee, the Depositor and each Owner if a claim is made by a third party with respect to this Agreement, and the Servicer shall assume (with the consent of the Trustee) the defense of any such claim and pay all expenses in connection therewith, including reasonable counsel fees, and promptly pay, discharge and satisfy any judgment or decree which may be entered against the Servicer, the Trustee, the Depositor and/or Owner in respect of such claim. The Trustee shall, in accordance with written instructions received from the Servicer, reimburse the Servicer only from amounts otherwise distributable on the Class R Certificates for all amounts advanced by it pursuant to the preceding sentence, except when a final nonappealable adjudication determines that the claim relates directly to the failure of the Servicer to perform its duties in compliance with the Agreement. The provisions of this Section 8.05(b) shall survive the termination of this Agreement, the resignation or removal of the Trustee, and the payment of the outstanding Certificates.

  • Limitation of Liability of the Adviser The Adviser shall not be liable for any error of judgment or mistake of law or for any loss arising out of any investment or for any act or omission in the execution and management of the Fund, except for willful misfeasance, bad faith or gross negligence in the performance of its duties and obligations hereunder. As used in this Article 6, the term "Adviser" shall include Directors, officers and employees of the Adviser as well as that corporation itself.

  • Specific Limitations on Indemnification Notwithstanding anything in this Agreement to the contrary, the Corporation shall not be obligated under this Agreement to make any payment to Indemnitee with respect to any Proceeding: (a) To the extent that payment is actually made to Indemnitee under any insurance policy, or is made to Indemnitee by the Corporation or an affiliate otherwise than pursuant to this Agreement. Notwithstanding the availability of such insurance, Indemnitee also may claim indemnification from the Corporation pursuant to this Agreement by assigning to the Corporation any claims under such insurance to the extent Indemnitee is paid by the Corporation; (b) Provided there has been no Change in Control, for Liabilities in connection with Proceedings settled without the Corporation’s consent, which consent, however, shall not be unreasonably withheld; (c) For an accounting of profits made from the purchase or sale by Indemnitee of securities of the Corporation within the meaning of section 16(b) of the Securities Exchange Act of 1934, as amended (the “Exchange Act”), or similar provisions of any state statutory or common law; (d) To the extent it would be otherwise prohibited by law, if so established by a judgment or other final adjudication adverse to Indemnitee; or (e) In connection with a Proceeding commenced by Indemnitee (other than a Proceeding commenced by Indemnitee to enforce Indemnitee’s rights under this Agreement) unless the commencement of such Proceeding was authorized by the Board of Directors.

  • Limitation of Liability of the Administrator; Indemnification The Administrator (and its members, managers, officers, employees, agents, controlling persons and any other person or entity affiliated with it) shall not be liable to the Company for any action taken or omitted to be taken by the Administrator in connection with the performance of any of its duties or obligations under this Agreement or otherwise as administrator for the Company and the Company shall indemnify, defend and protect the Administrator (and its officers, managers, partners, agents, employees, controlling persons, members, and any other person or entity affiliated with the Administrator each of whom shall be deemed a third party beneficiary hereof) (collectively, the “Indemnified Parties”) and hold them harmless from and against all damages, liabilities, costs and expenses (including reasonable attorneys’ fees and amounts reasonably paid in settlement) incurred by the Indemnified Parties in or by reason of any pending, threatened or completed action, suit, investigation or other proceeding (including an action or suit by or in the right of the Company or its security holders) arising out of or otherwise based upon the performance of any of the Administrator’s duties or obligations under this Agreement or otherwise as administrator for the Company. Notwithstanding the preceding sentence of this Section 5 to the contrary, nothing contained herein shall protect or be deemed to protect the Indemnified Parties against or entitle or be deemed to entitle the Indemnified Parties to indemnification in respect of, any liability to the Company or its security holders to which the Indemnified Parties would otherwise be subject by reason of willful misfeasance, bad faith or gross negligence in the performance of the Administrator’s duties or by reason of the reckless disregard of the Administrator’s duties and obligations under this Agreement (to the extent applicable, as the same shall be determined in accordance with the Investment Company Act and any interpretations or guidance by the SEC or its staff thereunder).

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!