Liquidated Damages The Company’s obligations to pay any partial liquidated damages or other amounts owing under the Transaction Documents is a continuing obligation of the Company and shall not terminate until all unpaid partial liquidated damages and other amounts have been paid notwithstanding the fact that the instrument or security pursuant to which such partial liquidated damages or other amounts are due and payable shall have been canceled.
Payment of Liquidated Damages With respect to any Liquidated Damages that accrue, Owner shall invoice Contractor for such Liquidated Damages. Contractor shall pay such Liquidated Damages within ten (10) Days after Contractor’s receipt of such invoice. To the extent Contractor does not pay such Liquidated Damages within such ten (10) Day period, Owner may, at its option, do one or more of the following: (i) withhold from Contractor amounts that are otherwise due and payable to Contractor in the amount of such Liquidated Damages and/or (ii) collect on the Letter of Credit in the amount of such Liquidated Damages. For the avoidance of doubt, prior to exercising such right to withhold or collect on the Letter of Credit, Owner shall not be required to provide the notice as set forth in Section 7.8. As used in this Agreement, Liquidated Damages are “paid” if and to the extent Owner exercises option (i) or (ii) above for the collection of Liquidated Damages.
Closing Fees, Expenses, etc The Administrative Agent shall have received for its own account, or for the account of each Lender, as the case may be, all fees, costs and expenses due and payable pursuant to Sections 3.3 and 10.3, if then invoiced.
Closing Fees On the Effective Date, the Borrower agrees to pay to the Administrative Agent and each Lender all loan fees as have been agreed to in writing by the Parent and the Joint Lead Arrangers.
Indemnification for Expenses as a Witness Notwithstanding any other provision of this Agreement except for Section 26 hereof, to the extent that Indemnitee is, by reason of his Corporate Status, a witness in any Proceeding, he shall be indemnified against all Expenses actually and reasonably incurred by him or on his behalf in connection therewith.
INDEMNIFICATION FOR EXPENSES OF A WITNESS Notwithstanding any other provision of this Agreement except for Section 27, to the extent that Indemnitee is, by reason of Indemnitee’s Corporate Status, a witness or deponent in any Proceeding to which Indemnitee was or is not a party or threatened to be made a party, Indemnitee shall, to the fullest extent permitted by applicable law, be indemnified, held harmless and exonerated against all Expenses actually and reasonably incurred by Indemnitee or on Indemnitee’s behalf in connection therewith.
Indemnification for Expenses of Successful Party Notwithstanding any other provisions of this Article SIXTH, to the extent that an Indemnitee has been successful, on the merits or otherwise, in defense of any action, suit or proceeding referred to in Sections 1 and 2 of this Article SIXTH, or in defense of any claim, issue or matter therein, or on appeal from any such action, suit or proceeding, Indemnitee shall be indemnified against all expenses (including attorneys’ fees) actually and reasonably incurred by or on behalf of Indemnitee in connection therewith. Without limiting the foregoing, if any action, suit or proceeding is disposed of, on the merits or otherwise (including a disposition without prejudice), without (i) the disposition being adverse to Indemnitee, (ii) an adjudication that Indemnitee was liable to the Corporation, (iii) a plea of guilty or nolo contendere by Indemnitee, (iv) an adjudication that Indemnitee did not act in good faith and in a manner he or she reasonably believed to be in or not opposed to the best interests of the Corporation, and (v) with respect to any criminal proceeding, an adjudication that Indemnitee had reasonable cause to believe his or her conduct was unlawful, Indemnitee shall be considered for the purposes hereof to have been wholly successful with respect thereto.
Debits for expenses etc The Agent shall be entitled (but not obliged) from time to time to debit any Earnings Account without prior notice in order to discharge any amount due and payable under Clause 20 or 21 to a Creditor Party or payment of which any Creditor Party has become entitled to demand under Clause 20 or 21.
Filing Fees, Excise Taxes, Etc The Grantors, jointly and severally, agree to pay or to reimburse the Collateral Agent and its counsel and agents for any and all amounts in respect of all search, filing, recording and registration fees, excise taxes and other similar imposts that are payable in respect of the execution, delivery, performance and enforcement of this Agreement, the Intercreditor Agreement and each Security Document. The obligations of the Grantors under this Section 5(e) shall survive the termination of the other provisions of this Agreement and the resignation or removal of the Collateral Agent.
Obligation Absolute; Partial Liquidated Damages The Company’s obligations to issue and deliver the Conversion Shares upon conversion of this Debenture in accordance with the terms hereof are absolute and unconditional, irrespective of any action or inaction by the Holder to enforce the same, any waiver or consent with respect to any provision hereof, the recovery of any judgment against any Person or any action to enforce the same, or any setoff, counterclaim, recoupment, limitation or termination, or any breach or alleged breach by the Holder or any other Person of any obligation to the Company or any violation or alleged violation of law by the Holder or any other Person, and irrespective of any other circumstance which might otherwise limit such obligation of the Company to the Holder in connection with the issuance of such Conversion Shares; provided, however, that such delivery shall not operate as a waiver by the Company of any such action the Company may have against the Holder. In the event the Holder of this Debenture shall elect to convert any or all of the outstanding principal amount hereof, the Company may not refuse conversion based on any claim that the Holder or anyone associated or affiliated with the Holder has been engaged in any violation of law, agreement or for any other reason, unless an injunction from a court, on notice to Holder, restraining and or enjoining conversion of all or part of this Debenture shall have been sought and obtained, and the Company posts a surety bond for the benefit of the Holder in the amount of 150% of the outstanding principal amount of this Debenture, which is subject to the injunction, which bond shall remain in effect until the completion of arbitration/litigation of the underlying dispute and the proceeds of which shall be payable to the Holder to the extent it obtains judgment. In the absence of such injunction, the Company shall issue Conversion Shares or, if applicable, cash, upon a properly noticed conversion. If the Company fails for any reason to deliver to the Holder such Conversion Shares pursuant to Section 4(c)(ii) by the Share Delivery Date, the Company shall pay to the Holder, in cash, as liquidated damages and not as a penalty, for each $1,000 of principal amount being converted, $10 per Trading Day (increasing to $20 per Trading Day on the fifth (5th) Trading Day after such liquidated damages begin to accrue) for each Trading Day after such Share Delivery Date until such Conversion Shares are delivered or Holder rescinds such conversion. Nothing herein shall limit a Hxxxxx’s right to pursue actual damages or declare an Event of Default pursuant to Section 8 hereof for the Company’s failure to deliver Conversion Shares within the period specified herein and the Holder shall have the right to pursue all remedies available to it hereunder, at law or in equity including, without limitation, a decree of specific performance and/or injunctive relief. The exercise of any such rights shall not prohibit the Holder from seeking to enforce damages pursuant to any other Section hereof or under applicable law.
