Minimum Customer Support Requirements for TIPS Sales Vendor shall provide timely and commercially reasonable support for TIPS Sales or as agreed to in the applicable Supplemental Agreement.
LIST OF TABLES Table 1.1
Background and Narrative of Budget Reductions 2. Assumptions Used in the Deficit Reduction Plan: - EBF and Estimated New Tier Funding: - Equal Assessed Valuation and Tax Rates: - Employee Salaries and Benefits: - Short and Long Term Borrowing: - Educational Impact: - Other Assumptions: - Has the district considered shared services or outsourcing (Ex: Transportation, Insurance) If yes please explain:
LIST OF SUB-PROCESSORS The controller has authorised the use of the following sub-processors:
LIST OF SCHEDULES Schedule 1.1
Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.
ACCOUNTS SUBJECT TO ERISA The ERISA Rider is applicable to all Customers Under Section II of this Schedule A.
List of Contracts The information set forth in the List of Contracts is true, complete and correct in all material respects as of the Cutoff Date.
Minimum Shipping Requirements for TIPS Sales Vendor shall ship, deliver, or provide ordered goods and services within a commercially reasonable time after acceptance of the order. If a delay in delivery is anticipated, Vendor shall notify the TIPS Member as to why delivery is delayed and provide an updated estimated time for completion. The TIPS Member may cancel the order if the delay is not commercially acceptable or not consistent with the Supplemental Agreement applicable to the order.
DNS name server availability Refers to the ability of a public-‐DNS registered “IP address” of a particular name server listed as authoritative for a domain name, to answer DNS queries from an Internet user. All the public DNS-‐registered “IP address” of all name servers of the domain name being monitored shall be tested individually. If 51% or more of the DNS testing probes get undefined/unanswered results from “DNS tests” to a name server “IP address” during a given time, the name server “IP address” will be considered unavailable.
