Location of the Account. Your Account is established in Memphis, Tennessee.
Location of the Account Sample Clauses
Related to Location of the Account
Investment of Funds in the Accounts The Trustee may direct any depository institution maintaining the Certificate Account or the Reserve Account, if any, for the Series and any other segregated Eligible Account, which Eligible Account shall be a Securities Account the contents of which are held for the benefit of Certificateholders of such applicable Series (each, an "Account"), to invest the funds therein at the specific written direction of the Depositor in one or more Eligible Investments bearing interest or sold at a discount, which shall be held to maturity unless payable on demand and which funds shall not be reinvested upon the maturity or demand for payment of such Eligible Investment. If the Depositor does not provide any investment directions by 10:00 a.m. on any Business Day, funds held in any Account will be invested in the Eligible Investments specified in clause (iv) of the definition thereof until receipt of investment directions to the contrary. Investments of such funds shall be invested in Eligible Investments that will mature so that such funds will be available for distribution on the next Distribution Date. Except as otherwise provided in the applicable Supplement, any earnings with respect to such Eligible Investments shall be paid to, and any losses with respect to such Eligible Investments shall be solely for the account of, the Certificateholders in proportion to their interest in the invested funds. In the event amounts on deposit in an Account are at any time invested in an Eligible Investment payable on demand, the Securities Intermediary, on behalf of the Trustee and the Trust, shall: (i) consistent with any notice required to be given thereunder, demand that payment thereon be made on the last day such Eligible Investment may otherwise mature hereunder in an amount equal to the lesser of (1) all amounts then payable thereunder and (2) the amount required to be withdrawn on such date; and (ii) demand same day payment of all amounts due thereunder upon a determination by the Trustee that such Eligible Investment would not constitute an Eligible Investment in respect of funds thereafter on deposit in any Account. None of the Trustee, the Depositor or the Securities Intermediary shall in any way be held liable by reason of any insufficiency in any Account resulting from any loss on any Eligible Investment made in accordance with this Trust Agreement.
The Account 1. AEME is fully authorized to manage and operate the Card Account and to debit all Charges, Transactions made on the Card or any Supplementary Card, fees and other amounts for all of which the Cardmember shall be liable. The Cardmember irrevocably undertakes and promises to pay to AEME all Charges and amounts debited to or outstanding on the Card Account including Charges incurred on any Supplementary Card whether or not a record of the Charge or Transaction has been issued and or signed at the Service Establishment. 2. Except for what is provided under Clauses 9 and 14 of this Agreement, the Cardmember acknowledges and agrees that all Charges debited at any time by AEME to his or her Card Account are true and accurate. The Cardmember also acknowledges that all records and data maintained by AEME on microfilm or in any printed or electronic form in connection with the Transactions, Charges, Card or Card Account are true, accurate and complete and may be used in any court of law as conclusive evidence which may not be disputed or challenged in any manner. 3. AEME may, at its ultimate discretion, refuse any request for authorization and may decline any Transaction including Cash Withdrawals regardless of the reason and without giving any notice to the Cardmember. Also, AEME may not be liable to provide or process authorization for any Transaction due to technical failures or any other reason of similar nature. In both circumstances and in any other similar situation, AEME is not liable whether directly or indirectly for any damages of any nature including monetary, liquidated, punitive or consequential damages which the Cardmember may sustain as a result of any unsuccessful, uncompleted or declined Transaction. 4. Xxxxxxxxxx promises to pay AEME for debits made on his Account for purchases and all other amounts owed to AEME under the Terms and Conditions of this Agreement. 5. If the Cardmember is on direct debit with a bank, the bank will also receive a monthly summary of Charges and will use the summary to directly debit the Cardmember account.
Administration of the Agreement The Agreement shall be administered by the Board of Directors of the Company or its delegate (the “Administrator”). Subject to the provisions of the Agreement, the Administrator shall have full and final authority in its discretion to take any action with respect to the Agreement including, without limitation, the authority to (i) determine all matters relating to the payments; (ii) establish, amend and rescind rules and regulations for the administration of the Agreement; and (iii) construe and interpret the Agreement, to interpret rules and regulations for administering the Agreement and to make all other determinations deemed necessary or advisable for administering the Agreement. Except to the extent otherwise required under Section 409A of the Internal Revenue Code of 1986, as amended (“Code”), the Administrator shall have the authority, in its sole discretion, to accelerate the date that any Consultation Payments or Separation Payments which were not otherwise vested or earned shall become vested or earned in whole or in part without any obligation to accelerate such date with respect to any other employee. The Administrator also may in its sole discretion determine that Executive’s rights or payments under the Agreement shall be subject to reduction, cancellation, forfeiture or recoupment due to conduct by Executive that is determined by the Administrator to be detrimental to the business or reputation of the Company, including, without limitation, upon termination of employment for cause; violation of policies of the Company; or breach of non-solicitation, noncompetition, confidentiality or other restrictive covenants that apply to the Executive. In addition to action by meeting in accordance with applicable laws, any action of the Administrator with respect to the Agreement may be taken by a written instrument signed by the Administrator (including, where the Board or a committee serves as the Administrator, by written consent signed by all of the members of the Board, or all of the members of a committee, and any such action so taken by written consent shall be as fully effective as if it had been taken by a majority of the members at a meeting duly held and called). No individual shall be liable while acting as Administrator for any action or determination made in good faith with respect to the Agreement, and any such individual shall be entitled to indemnification and reimbursement in the manner provided in the Company’s certificate of incorporation and bylaws and/or under applicable law.
POSSESSION OF THE APARTMENT/PLOT 7.1 Schedule for possession of the said [Apartment/Plot] - The Promoter agrees and understands that timely delivery of possession of the [Apartment/Plot] to the allottee and the common areas to the association of allottees or the competent authority, as the case may be, is the essence of the Agreement. The Promoter assures to hand over possession of the [Apartment/Plot] along with ready and complete common areas with all specifications, amenities and facilities of the project in place on , unless there is delay or failure due to war, flood, drought, fire, cyclone, earthquake or any other calamity caused by nature affecting the regular development of the real estate project (“Force Majeure”). If, however, the completion of the Project is delayed due to the Force Majeure conditions then the Allottee agrees that the Promoter shall be entitled to the extension of time for delivery of possession of the [Apartment/Plot], provided that such Force Majeure conditions are not of a nature which make it impossible for the contract to be implemented. The Allottee agrees and confirms that, in the event it becomes impossible for the Promoter to implement the project due to Force Majeure conditions, then this allotment shall stand terminated and the Promoter shall refund to the Allottee the entire amount received by the Promoter from the allotment within 60 days from that date. The promoter shall intimate the allottee about such termination at least thirty days prior to such termination. After refund of the money paid by the Allottee, the Allottee agrees that he/ she shall not have any rights, claims etc. against the Promoter and that the Promoter shall be released and discharged from all its obligations and liabilities under this Agreement.
Application of the Agreement (1) This Agreement shall apply to investments made in the territory of either Contracting Party in accordance with its legislation by investors of the other Contracting Party prior as well as after the entry into force of this Agreement. (2) This Agreement shall not apply to claims which have been settled or procedures which have been initiated prior to its entry into force.
Operation of the Agreement The Parties recognize that it is impractical in this Agreement to provide for every contingency which may arise during the life of the Agreement, and the Parties hereby agree that it is their intention that this Agreement shall operate fairly as between them, and without detriment to the interest of either of them, and that, if during the term of this Agreement either Party believes that this Agreement is operating unfairly, the Parties will use their best efforts to agree on such action as may be necessary to remove the cause or causes of such unfairness, but failure to agree on any action pursuant to this Clause 8.2 shall not give rise to a dispute subject to arbitration in accordance with Clause 9 hereof.
Investment for Own Account The Securities are being issued to Laurus for its own account for investment only, and not as a nominee or agent and not with a view towards or for resale in connection with their distribution.
Agent’s Own Account; Clients’ Account The Company consents to the Agent trading, in compliance with applicable law, in the Common Shares for the Agent’s own account and for the account of its clients at the same time as sales of the Shares occur pursuant to this Agreement.
Application of Funds in the Collection Account The Master Servicer may, from time to time, make, or cause to be made, withdrawals from the Collection Account for the following purposes: (i) to reimburse itself or any Servicer for Advances made by it or by such Servicer pursuant to Section 5.04 or the applicable Servicing Agreement; provided, however, that the Master Servicer’s right to reimburse itself pursuant to this subclause is limited to amounts received on or in respect of particular Mortgage Loans (including, for this purpose, Liquidation Proceeds and amounts representing Insurance Proceeds with respect to the property subject to the related Mortgage) which represent late recoveries (net of the applicable Servicing Fee and the Master Servicing Fee) of payments of principal or interest respecting which any such Advance was made; provided, further, that following the final liquidation of a Mortgage Loan, the Master Servicer may reimburse itself for previously unreimbursed Advances in excess of Liquidation Proceeds or Insurance Proceeds with respect to such Mortgage Loans from any funds in the Collection Account, it being understood, in the case of any such reimbursement, that the Master Servicer’s or Servicer’s right thereto shall be prior to the rights of the Certificateholders; (ii) to reimburse itself or any Servicer for any Servicing Advances made by it or by such Servicer that it or such Servicer determines in good faith will not be recoverable from amounts representing late recoveries of payments of principal or interest respecting the particular Mortgage Loan as to which such Servicing Advance was made or from Liquidation Proceeds or Insurance Proceeds with respect to such Mortgage Loan, it being understood, in the case of any such reimbursement, that such Master Servicer’s or Servicer’s right thereto shall be prior to the rights of the Certificateholders; (iii) to reimburse itself or any Servicer from Liquidation Proceeds for Liquidation Expenses and for amounts expended by it pursuant to Sections 9.20 and 9.22(a) or the applicable Servicing Agreement in good faith in connection with the restoration of damaged property and, to the extent that Liquidation Proceeds after such reimbursement exceed the unpaid principal balance of the related Mortgage Loan, together with accrued and unpaid interest thereon at the applicable Mortgage Rate less the applicable Servicing Fee and the Master Servicing Fee for such Mortgage Loan to the Due Date next succeeding the date of its receipt of such Liquidation Proceeds, to pay to itself out of such excess the amount of any unpaid assumption fees, late payment charges or other Mortgagor charges on the related Mortgage Loan and to retain any excess remaining thereafter as additional servicing compensation, it being understood, in the case of any such reimbursement or payment, that such Master Servicer’s or Servicer’s right thereto shall be prior to the rights of the Certificateholders; (iv) to reimburse itself or any Servicer for expenses incurred by and recoverable by or reimbursable to it or such Servicer pursuant to Section 9.04, 9.05, 9.06, 9.16 or 9.22(a) or pursuant to the applicable Servicing Agreement, and to reimburse itself for any expenses reimbursable to it pursuant to Section 10.01(c); (v) to pay to the applicable Person, with respect to each Mortgage Loan or REO Property acquired in respect thereof that has been repurchased by such Person pursuant to this Agreement, all amounts received thereon and not distributed on the date on which the related repurchase was effected; (vi) subject to Section 5.05, to pay to itself income earned on the investment of funds deposited in the Collection Account; (vii) to make payments to the Trustee for deposit into the Certificate Account in the amounts and in the manner provided for in Section 4.01(c); (viii) to make distributions of any Retained Interest to the Retained Interest Holder on each Distribution Date (other than any Retained Interest not deposited into the Collection Account in accordance with Section 4.01(d)(iii)); (ix) to make payment to itself, the Trustee and others pursuant to any provision of this Agreement; (x) to withdraw funds deposited in error in the Collection Account; (xi) to clear and terminate the Collection Account pursuant to Section 7.02; (xii) to reimburse a successor Master Servicer (solely in its capacity as successor Master Servicer), for any fee or advance occasioned by a termination of the Master Servicer, and the assumption of such duties by the Trustee or a successor Master Servicer appointed by the Trustee pursuant to Section 6.14, in each case to the extent not reimbursed by the terminated Master Servicer, it being understood, in the case of any such reimbursement or payment, that the right of the Master Servicer or the Trustee thereto shall be prior to the rights of the Certificateholders; and (xiii) to reimburse any Servicer for such amounts as are due thereto under the applicable Servicing Agreement and have not been retained by or paid to such Servicer to the extent provided in such Servicing Agreement. If provided in the related Servicing Agreement, each Servicer shall be entitled to retain as additional servicing compensation any Prepayment Interest Excess (to the extent not offset by Prepayment Interest Shortfalls). In the event that the Master Servicer fails on any Deposit Date to remit to the Trustee any amounts required to be so remitted to the Trustee pursuant to subclause (vii) by 12 noon (New York time) on such date, the Master Servicer shall pay the Trustee, for the account of the Trustee, interest calculated at the “prime rate” (as published in the “Money Rates” section of The Wall Street Journal) on such amounts not timely remitted for the period from and including that Deposit Date to but not including the related Distribution Date. In connection with withdrawals pursuant to subclauses (i), (iii), (iv) and (vi) above, the Master Servicer’s or Servicer’s entitlement thereto is limited to collections or other recoveries on the related Mortgage Loan, except as provided herein. The Master Servicer shall therefore keep and maintain a separate accounting for each Mortgage Loan it master services for the purpose of justifying any withdrawal from the Collection Account it maintains pursuant to subclauses (i), (iii), (iv) and (vi) above.
POSSESSION OF THE APARTMENT PLOT 8.1 Schedule for possession of the said Apartment: The Promoter agrees and understands that timely delivery of possession of the Apartment to the Allottee and the Common Areas to the Association of the Allottees , is the essence of the Agreement. Provided that the Promoter shall be entitled to reasonable extension of time as agreed by and between the Allottee and the Promoter for giving possession of the Apartment on the aforesaid date and the same shall not include the period of extension given by the Authority for registration. The Promoter, based on the approved plans and specifications, assures to hand over possession of the Apartment on …………,with a grace period of twelve months (Completion date) in case the Promoter fails to complete the Project. unless there is a delay or failure due to war, flood, drought, fire, cyclone, earthquake or any other calamity or order, rule, notification of the Government and/or other public or competent authority/court and/or caused by nature affecting the regular development of the real estate project (“Force Majeure”). If, however, the completion of the Project is delayed due to the Force Majeure conditions then the Allottee agrees that the Promoter shall be entitled to the extension of time for delivery of possession of the Apartment, Provided that such Force Majeure conditions are not of a nature which make it impossible for the contract to be implemented. Promoter will be entitled to give block-wise and phase-wise possession upon obtaining the Completion Certificate/ Partial Completion Certificate of a building block or a particular phase as the case may be irrespective of the fact that construction of other Blocks and/or other phases and/or provision of facilities may be incomplete. The Allottee agrees and confirms that, in the event it becomes impossible for the Promoter to implement the project due to Force Majeure conditions, then this allotment shall stand terminated and the Promoter shall refund to the Allottee the entire amount received by the Promoter from the allotment within 45 days from that date.After refund of the money paid by the Allottee, the Allottee agrees that he/ she shall not have any rights, claims etc. against the Promoter and that the Promoter shall be released and discharged from all its obligations and liabilities under this Agreement. It is clarified that all amounts collected as taxes, charges, levies, cess, assessments and impositions and deposited with the appropriate authorities concerned shall not be returned by the Promoter and the Allottee shall be free to approach the authorities concerned for refund of such taxes, charges, levies, cess, assessments and impositions. 8.2 The right of the Allottee shall remain restricted to the respective Apartment and the properties appurtenant thereto and the Allottee shall have no right, title or interest nor shall claim any right, title or interest of any kind whatsoever over and in respect of any other Apartment or space and/or any other portions of the Project or Complex. 8.3 The Promoter has provided to the Allottee a time schedule for construction progress based on the milestones on which payment is due. The dates provided are only tentative and for the purpose of dealing with contractors and will also make efforts to complete various stages as per the time schedule upto completion of the Project including the provisions of civic infrastructure like water, electricity, sanitation and all other above mentioned internal/external development works but the Promoter knows there will definitely be delays in the timelines provided but the Promoter assures the Allottee that the Project will be completed within the ‘Completion date’ provided in Clause 8.1 above.
