Mailing of Class Notice and Related Documents
Mailing of Class Notice and Related Documents Sample Clauses
Related to Mailing of Class Notice and Related Documents
Notice of Legal Actions Each party hereto shall, within five (5) business days of receipt thereof, give written notice to the other party hereto of (i) any notice, advice or other communication from any Governmental Authority or any source whatsoever with respect to Hazardous Substances on, from or affecting the Property, and (ii) any legal action brought against such party or related to the Property, with respect to which Indemnitor may have liability under this Agreement. Such notice shall comply with the provisions of Section 15 hereof.
Notice of Decision The Plan Administrator shall notify the claimant in writing of its decision on review. The Plan Administrator shall write the notification in a manner calculated to be understood by the claimant. The notification shall set forth:
Term, Notice and Effect This Agreement shall have an initial term of three (3) years from the date hereof. Thereafter, this Agreement shall automatically renew for successive one (1) year periods unless either party terminates this Agreement by written notice effective no sooner than seventy-five (75) days following the date that notice to such effect shall be delivered to the other party at its address set forth in Section 12.5 hereof. Notwithstanding the foregoing provisions, either party may terminate this Agreement at any time (a) for cause, which is a material breach of the Agreement not cured within 60 days, in which case termination shall be effective upon written receipt of notice by the non-terminating party, or (b) upon thirty (30) days written notice to the other party in the event that either party is adjudged bankrupt or insolvent, or there shall be commenced against such party a case under any applicable bankruptcy, insolvency, or other similar law now or hereafter in effect.
Notice of Litigation, Etc Tenant shall give prompt Notice to Landlord of any litigation or any administrative proceeding to which it may hereafter become a party of which Tenant has notice or actual knowledge which involves a potential liability equal to or greater than Two Hundred Fifty Thousand Dollars ($250,000) or which may otherwise result in any material adverse change in the business, operations, property, prospects, results of operation or condition, financial or other, of Tenant. Forthwith upon Tenant obtaining knowledge of any Default, Event of Default or any default or event of default under any agreement relating to Indebtedness for money borrowed in an aggregate amount exceeding, at any one time, Two Hundred Fifty Thousand Dollars ($250,000), or any event or condition that would be required to be disclosed in a current report filed by Tenant on Form 8-K or in Part II of a quarterly report on Form 10-Q if Tenant were required to file such reports under the Securities Exchange Act of 1934, as amended, Tenant shall furnish Notice thereof to Landlord specifying the nature and period of existence thereof and what action Tenant has taken or is taking or proposes to take with respect thereto.
Notice of Disputes Written notice of a Dispute must be sent to the Manager or Member by the aggrieved party as described in the notice requirements of Article 15.1 below.
Notice of Delay Within Fourteen (14) days after the date of occurrence of any cause of delay, on account of which the BUILDER claims that it is entitled under this Contract to a postponement of the Delivery Date, the BUILDER shall notify the BUYER in writing or by telefax confirmed in writing of the date when such cause of delay occurred. Likewise, within Fourteen (14) days after the date of ending of such cause of delay, the BUILDER shall notify the BUYER in writing or by xxxxxxx confirmed in writing of the date when such cause of delay ended. The BUILDER shall also notify the BUYER of the period, by which the Delivery Date is postponed by reason of such cause of delay, with all reasonable dispatch after it has been determined. If the BUILDER does not give the timely advice as above, the BUILDER shall lose the right to claim such delays as permissible delay. Failure of the BUYER to acknowledge to the BUILDER’s claim for postponement of the Delivery Date within Fourteen (14) days after receipt by the BUYER of such notice of claim shall be deemed to be a waiver by the BUYER of its right to object to such postponement of the Delivery Date.
NOTICE OF FINAL AGREEMENT THIS AGREEMENT AND THE OTHER LOAN DOCUMENTS REPRESENT THE FINAL AGREEMENT AMONG THE PARTIES RELATING TO THE SUBJECT MATTER HEREOF AND THEREOF AND MAY NOT BE CONTRADICTED BY EVIDENCE OF PRIOR, CONTEMPORANEOUS, OR SUBSEQUENT ORAL AGREEMENTS OF THE PARTIES. THERE ARE NO UNWRITTEN ORAL AGREEMENTS AMONG THE PARTIES.
Legal Action Notice A prompt report of any legal actions pending or threatened in writing against Borrower or any of its Subsidiaries that could result in damages or costs to Borrower or any of its Subsidiaries of, individually or in the aggregate, One Hundred Thousand Dollars ($100,000) or more; and
Manner of Giving Notice Each notice, direction, certificate or other communication hereunder (in this Section referred to collectively as “notices” and singly as a “notice”) which any party is required or permitted to give to the other party pursuant to this Agreement shall be in writing and shall be deemed to have been duly and sufficiently given if:
Mailing Communications to Shareholders; Proxy Materials The Transfer Agent will address and mail to Shareholders of the Funds, all reports to Shareholders, dividend and distribution notices and proxy material for the Funds' meetings of Shareholders. In connection with meetings of Shareholders, the Transfer Agent will prepare Shareholder lists, mail and certify as to the mailing of proxy materials, process and tabulate returned proxy cards, report on proxies voted prior to meetings, act as inspector of election at meetings and certify Shares voted at meetings.
