Required Repairs (a) Borrower shall make the repairs and improvements to each Individual Property as set forth on Schedule 9.1 and as more particularly described in the Property Condition Reports prepared in connection with the closing of the Loan (such repairs hereinafter referred to as “Required Repairs”). Borrower shall complete the Required Repairs in a good and workmanlike manner on or before the date that is twelve (12) months from the Closing Date or within such other time frame for completion specifically set forth on Schedule 9.1.
(b) Borrower shall establish on the date hereof an Eligible Account with Lender or Lender’s agent to fund the Required Repairs (the “Required Repair Account”) into which Borrower shall deposit on the date hereof the amount of $0.00. Amounts so deposited shall hereinafter be referred to as the “Required Repair Funds”.
(c) Upon the earliest to occur of (i) the timely completion of all Required Repairs and any Additional Required Repairs, if any, in accordance with the requirements of this Agreement, as verified by Lender in its reasonable discretion, (ii) the payment in full of the Debt or (iii) the earlier release of the Lien of the Mortgage (and all related obligations) in accordance with the terms of this Agreement and the other Loan Documents, provided no Event of Default is then continuing, all amounts remaining on deposit, if any, in the Required Repair Account shall be returned to Borrower.
Emergency Repairs a) The landlord must post and maintain in a conspicuous place on the residential property, or give to the tenant in writing, the name and telephone number of the designated contact person for emergency repairs.
b) If emergency repairs are required, the tenant must make at least two attempts to telephone the designated contact person, and then give the landlord reasonable time to complete the repairs.
c) If the emergency repairs are still required, the tenant may undertake the repairs, and claim reimbursement from the landlord, provided a statement of account and receipts are given to the landlord. If the landlord does not reimburse the tenant as required, the tenant may deduct the cost from rent. The landlord may take over completion of the emergency repairs at any time.
d) Emergency repairs must be urgent and necessary for the health and safety of persons or preservation or use of the residential property and are limited to repairing i) major leaks in pipes or the roof,
Repairs If this Lease is not terminated as provided above, it shall continue in full force and effect, and Landlord shall promptly and diligently, subject to reasonable delays for insurance adjustment, and subject to all other terms of this Article, restore the Premises, the Common Areas and the portions of the Project serving the Premises and Tenant shall assign to Landlord all insurance proceeds payable to Tenant as to any Alterations; provided that if the cost of the restoration of any Alterations by Landlord exceeds the amount of Tenant’s insurance proceeds therefor, as assigned by Tenant to Landlord, such excess shall be paid by Tenant to Landlord prior to Landlord’s restoration thereof. Such restoration shall be to substantially the same condition of such items as prior to the casualty, except for modifications (a) required by Law; (b) required by the holder of a mortgage on the Building, or the lessor of a ground or underlying lease with respect to the Property; or (c) to the Common Areas reasonably deemed desirable by Landlord, and which are consistent with the character of the Project. No such modifications shall materially impair access to the Premises and any Common Areas serving the Premises. Tenant shall be responsible, at its sole cost and expense, for the repair, restoration, and replacement of Tenant’s Property. Landlord shall not be liable for any loss of business, inconvenience, or annoyance arising from any casualty or any repair or restoration of any portion of the Premises, the Building, or the Project as a result of any damage from any casualty. All work by Tenant shall be subject to the terms and conditions of Article 11.
Installation, Maintenance, Testing and Repair Unless otherwise agreed in writing by the Parties, to the extent required by Applicable Law, Interconnection provided by a Party shall be equal in quality to that provided by such Party to itself, any subsidiary, affiliates or third party. If either Party is unable to fulfill its obligations under this Section 14.2, it shall notify the other Party of its inability to do so and will negotiate alternative intervals in good faith. The Parties agree that to the extent required by Applicable Law, the standards to be used by a Party for isolating and clearing any disconnections and/or other outages or troubles shall be at parity with standards used by such Party with respect to itself, any subsidiary, affiliate or third party.
Maintenance & Repairs 5.1 Lessee shall at all times be responsible for maintaining at its own expense the leased premises in a clean, orderly and safety condition, except as hereinafter provided. Lessee shall be responsible, at its own expense, to clean and maintain all trade fixtures, machinery and equipment furnished by Lessee within the leased premises. Lessee shall be responsible to deposit normal office waste and rubbish at a location at the Central School as designated by Lessor.
5.2 Lessee shall be responsible to perform all repairs the need for which is caused by Xxxxxx's use of the premises except that Lessor shall be responsible to perform major repairs of a structural nature. Lessor shall be responsible to arrange for removal of waste and rubbish from the location designated as the deposit location for lessees. All costs incurred by Lessor pursuant to the obligations of this Paragraph shall be included within "operating costs".
5.3 Lessor shall provide custodian services for the common areas of Central School. Costs incurred by Lessor in providing such custodian services shall be included within "operating costs".
Maintenance Repairs and Alterations A. Except to the extent such obligations are imposed upon Landlord hereunder, Tenant shall, at its sole cost and expense, maintain the interior of the Premises in good order, condition and repair throughout the entire Lease Term, ordinary wear and tear excepted. Tenant agrees to keep the areas visible from outside the Premises in a neat, clean and attractive condition at all times. Tenant shall, within thirty (30) days after Landlord’s written demand therefor, reimburse Landlord for the cost of all repairs, replacements and alterations (collectively, “Repairs”) in and to the Premises, Building and Property and the facilities and systems thereof, plus an administration charge often percent (10%) of such cost, the need for which Repairs arises out of (and provided Landlord has given prior written notice to Tenant of such need): (1) Tenant’s use of the Premises in contravention of the terms and conditions of this Lease, or Tenant’s failure to perform maintenance or repairs which are Tenant’s obligation hereunder, (2) the installation, removal, use or operation of Tenant’s Property, if undertaken by Landlord at Tenant’s request or by virtue of Tenant’s default in undertaking such obligations, (3) the moving of Tenant’s Property into or out of the Building, or (4) the act, omission, misuse or negligence of Tenant, its agents, contractors, employees or invitees.
B. Tenant shall not make or allow to be made any alterations, additions or improvements to the Premises (collectively, “Alterations”), without first obtaining the written consent of Landlord, which consent shall not be unreasonably withheld or delayed; provided however, Tenant shall have the right to perform, without Landlord’s consent, certain Alterations that do not cost in excess of $25,000.00 in the aggregate (at any one time), and do not affect any mechanical or electrical or life safety systems or plumbing in the Building, provided that advance notice has been given to Landlord in each instance. Landlord reserves the right to require Tenant to remove at the end of the Lease Term any Alterations installed without the Landlord’s consent. Prior to commencing any such Alterations and as a condition to obtaining Landlord’s consent where necessary, Tenant shall deliver to Landlord plans and specifications acceptable to Landlord; names and addresses of contractors reasonably acceptable to Landlord; copies of contracts; necessary permits and approvals; evidence of contractor’s and subcontractor’s insurance in accordance with Section 13 hereof; and a payment bond or other security, all in form and amount satisfactory to Landlord. Tenant shall be responsible for insuring that all such persons procure and maintain insurance coverage against such risks, in such amounts and with such companies as Landlord may reasonably require. All Alterations shall be constructed in a good and workmanlike manner using Building standard materials or other new materials of equal or greater quality. Landlord, to the extent reasonably necessary to avoid any disruption to the tenants and occupants of the Building, shall have the right to designate the time when any Alterations may be performed and to otherwise designate reasonable rules, regulations and procedures for the performance of work in the Building. Upon completion of the Alterations, Tenant shall deliver to Landlord “as-built” plans, contractor’s affidavits and full and final waivers of lien and receipted bills covering all labor and materials. All Alterations shall comply with the insurance requirements and with applicable codes, ordinances, laws and regulations. Tenant shall reimburse Landlord upon demand for all reasonable sums, if any, expended by Landlord for third party examination of the architectural, mechanical, electrical and plumbing plans for any Alterations. In addition, if Landlord so requests, Landlord shall be entitled to oversee the construction of any Alterations, and in such event, Tenant shall reimburse Landlord for Landlord’s actual out of pocket costs incurred in connection therewith, which may include the cost of management personnel working outside of Normal Business Hours. Landlord’s approval of Tenant’s plans and specifications for any Alterations performed for or on behalf of Tenant shall not be deemed to be representation by Landlord that such plans and specifications comply with applicable insurance requirements, building codes, ordinances, laws or, regulations or that the Alterations constructed in accordance with such plans and specifications will be adequate for Tenant’s use.
Completion of Repairs Borrower will commence any Repairs as soon as practicable after the date of this Loan Agreement and will diligently proceed with and complete such Repairs on or before the Completion Date. All Repairs and Capital Replacements will be completed in a good and workmanlike manner, with suitable materials, and in accordance with good building practices and all applicable laws, ordinances, rules, regulations, building setback lines and restrictions applicable to the Mortgaged Property. Borrower agrees to cause the replacement of any material or work that is defective, unworkmanlike or that does not comply with the requirements of this Loan Agreement, as determined by Lender.
Tenant’s Repairs Tenant, at its expense, shall promptly make all repairs and replacements of every kind and nature, whether foreseen or unforeseen, which may be required to be made upon or in connection with the Premises. Landlord shall not be required to make any repair, whether foreseen or unforeseen, or to maintain any of the Premises in any way. Any repair or replacement shall be performed at the Tenant's expense by contractors approved by Landlord, or at Landlord's option, by Landlord. Such repair and replacements include capital expenditures and repairs whose benefit extend beyond the Lease Term. Heating, ventilation and air conditioning systems and other mechanical and building systems serving the Premises shall be maintained at Tenant's expense pursuant to maintenance service contracts entered into by Tenant. The scope of services and contractors under such maintenance contracts shall be reasonably approved by Landlord. If Tenant fails to perform any repair or replacement for which it is responsible, Landlord may perform such work and be reimbursed by Tenant within ten (10) days after demand therefor. Subject to the Restoration and Condemnation Paragraphs, Tenant shall bear the full cost of any repair or replacement to any part of the Premises that results from damage caused by Tenant, its agents, contractors, or invitees and any repair that benefits only the Premises. If any present or future improvements to the Premises are made or authorized to be made by Tenant, its agents or employees, and such improvements shall encroach upon any property or street adjacent to the Premises, or shall violate any agreement or condition contained in any restrictive covenant affecting or applicable to the Premises, or shall impair the rights of others under any easement or right-of-way to which the Premises are subject, then upon request of Landlord, Tenant, at its cost and expense, shall take such action as shall be necessary to remove such encroachments or end such violation or impairment. Notwithstanding the foregoing, Tenant shall not be required to remove any such encroachments if Tenant has or obtains such easements, licenses or similar rights as may be necessary to permit such encroachments to remain.
Landlord’s Repairs Landlord, as an Operating Expense, shall maintain all of the structural, exterior, parking and other Common Areas of the Project, including HVAC, plumbing, fire sprinklers, elevators and all other building systems serving the Premises and other portions of the Project (“Building Systems”), in good repair, reasonable wear and tear and uninsured losses and damages caused by Tenant, or by any of Tenant’s agents, servants, employees, invitees and contractors (collectively, “Tenant Parties”) excluded. Losses and damages caused by Tenant or any Tenant Party shall be repaired by Landlord, to the extent not covered by insurance, at Tenant’s sole cost and expense. Landlord reserves the right to stop Building Systems services when necessary (i) by reason of accident or emergency, or (ii) for planned repairs, alterations or improvements, which are, in the judgment of Landlord, desirable or necessary to be made, until said repairs, alterations or improvements shall have been completed. Landlord shall have no responsibility or liability for failure to supply Building Systems services during any such period of interruption; provided, however, that Landlord shall, except in case of emergency, make a commercially reasonable effort to give Tenant 24 hours advance notice of any planned stoppage of Building Systems services for routine maintenance, repairs, alterations or improvements. Tenant shall promptly give Landlord written notice of any repair required by Landlord pursuant to this Section, after which Landlord shall make a commercially reasonable effort to effect such repair. Landlord shall not be liable for any failure to make any repairs or to perform any maintenance unless such failure shall persist for an unreasonable time after Tenant’s written notice of the need for such repairs or maintenance. Tenant waives its rights under any state or local law to terminate this Lease or to make such repairs at Landlord’s expense and agrees that the parties’ respective rights with respect to such matters shall be solely as set forth herein. Repairs required as the result of fire, earthquake, flood, vandalism, war, or similar cause of damage or destruction shall be controlled by Section 18.
Alterations and Repairs Lessee shall not make or permit to be made any other alterations, additions, improvements, or changes (collectively, “Alterations”), in the premises, without Lessor’s prior written approval, which approval Lessor may withhold in Lessor’s sole discretion. Subject to the services to be rendered by Lessor as set forth in the Schedule, Lessee shall, at Lessee’s expense, keep the premises generally consistent with the standard maintained by other tenants of premises in the Building during the tenancy. If Lessee does not make repairs promptly and adequately, Lessor may, but need not, make repairs, and Lessee shall pay promptly the reasonable cost thereof. At any time or times, Lessor, either voluntarily or pursuant to governmental requirement, may, at Lessor’s expense, make repairs, alterations, or improvements in or to the Building or any part thereof, including the premises, and, during such operations Lessor may close entrances, doors, corridors, elevators, or other facilities, all without any liability to Lessee or deduction of rent by reason of interference, inconvenience, or annoyance; provided that Lessee shall have access to the premises sufficient for conduct of Lessee’s business. Lessor shall not be liable to Lessee for any expense, injury, loss, or damage resulting from work done in or upon, or the use of, any adjacent or nearby building, land, street, or alley, provided that Lessor makes a reasonable effort to minimize the disruption to Lessee’s business. In the event Lessee requests that repairs, alterations, decorating, or other work in the premises be made during periods other than ordinary business hours, Lessee shall pay Lessor for overtime and other additional expenses incurred because of such request.
