Common use of Make-Ready Work Clause in Contracts

Make-Ready Work. If in the reasonable judgment of Pole Owner the accommodation of any of Licensee's Attachments necessitates Make-ready Work, in the response to Licensee’s application Pole Owner will indicate the Make-ready Work that will be necessary to accommodate the Attachments requested and the estimated cost thereof within the application processing time period identified in Section 3.02. If Licensee is willing to bear the cost of all Make-ready Work necessary, as determined by Pole Owner, Licensee shall so indicate via ENS or in writing within thirty (30) days of the date of Pole Owner’s response to Licensee’s initial application. Pole Owner will provide Licensee an estimated completion date for any Make-ready Work, taking into account the overall scope of the Licensee’s project, the volume of applications received from other licensees, as well as the availability of crews to perform the work. The Licensee and the Pole Owner shall negotiate solutions in good faith when the estimated time to perform the Make-ready Work does not meet the Licensee’s project requirements. At Licensee’s option, Licensee may request to perform the Make-ready Work using plans and contractors pre- approved by Pole Owner consistent with this Agreement. Pole Owner will perform such Make-ready Work as may be required and Licensee will reimburse, upon demand, Pole Owner for the entire expense thereby actually and reasonably incurred. Licensee shall pay the costs of all Make-ready Work undertaken by Pole Owner where such work is initiated as a result of the proposed installation of Attachments on any poles without regard to whether Licensee elects not to use the pole or poles after Make-ready Work has commenced. An itemized statement detailing the actual material, hours, equipment costs, and any other associated costs will be provided to Licensee for payment of Make-ready Work.

Make-Ready Work. If in the reasonable judgment of Pole Owner the accommodation of any of Licensee's Attachments necessitates Make-ready Work, in the response to Licensee’s application Pole Owner will indicate the Make-ready Work that will be necessary to accommodate the Attachments requested and the estimated cost thereof within the application processing time period identified in Section 3.02. If Licensee is willing to bear the cost of all Make-ready Work necessary, as determined by Pole Owner, Licensee shall so indicate via ENS or in writing within thirty (30) days of the date of Pole Owner’s response to Licensee’s initial application. Pole Owner will provide Licensee an estimated completion date for any Make-ready Work, taking into account the overall scope of the Licensee’s project, the volume of applications received from other licensees, as well as the availability of crews to perform the work. The Licensee and the Pole Owner shall negotiate solutions in good faith when the estimated time to perform the Make-ready Work does not meet the Licensee’s project requirements. At Licensee’s option, Licensee may request either assistance with the work by Licensee or by qualified contractors hired by the Licensee, payment of premium rates for Pole Owner’s employees to be dedicated to perform work solely on Licensee’s project, or similar measures designed to augment the Make-ready Work using plans and contractors pre- approved by Pole Owner consistent with this AgreementOwner’s capabilities. Pole Owner will perform such Make-ready Work as may be required and Licensee will reimburse, upon demand, Pole Owner for the entire expense thereby actually and reasonably incurred. Licensee shall pay the costs of all Make-ready Work undertaken by Pole Owner where such work is initiated as a result of the proposed installation of Attachments on any poles without regard to whether Licensee elects not to use the pole or poles after Make-ready Work has commenced. An itemized statement detailing the actual material, hours, equipment costs, and any other associated costs will be provided to Licensee for payment of Make-ready Work.

Make-Ready Work. If in the reasonable judgment of Pole Owner CenturyLink the accommodation of any of Licensee's Attachments necessitates Make-ready Work, in the response to Licensee’s application Pole Owner CenturyLink will indicate the Make-ready Work that will be necessary to accommodate the Attachments requested and the estimated cost thereof within the application processing time period identified in Section 3.02. If Licensee is willing to bear the cost of all Make-ready Work necessary, as determined by Pole OwnerCenturyLink, Licensee shall so indicate via ENS or in writing within thirty (30) days of the date of Pole OwnerCenturyLink’s response to Licensee’s initial application. Pole Owner CenturyLink will provide Licensee an estimated completion date for any Make-ready Work, taking into account the overall scope of the Licensee’s project, the volume of applications received from other licensees, as well as the availability of crews to perform the work. The Licensee and the Pole Owner CenturyLink shall negotiate solutions in good faith when the estimated time to perform the Make-ready Work does not meet the Licensee’s project requirements. At Licensee’s option, Licensee may request to perform the Make-ready Work using plans and contractors pre- approved by Pole Owner CenturyLink consistent with this Agreement. Pole Owner CenturyLink will perform such Make-ready Work as may be required and Licensee will reimburse, upon demand, Pole Owner CenturyLink for the entire expense thereby actually and reasonably incurred. Licensee shall pay the costs of all Make-ready Work undertaken by Pole Owner CenturyLink where such work is initiated as a result of the proposed installation of Attachments on any poles without regard to whether Licensee elects not to use the pole or poles after Make-ready Work has commenced. An itemized statement detailing the actual material, hours, equipment costs, and any other associated costs will be provided to Licensee for payment of Make-ready Work.

Make-Ready Work. If in the reasonable judgment of Pole Owner the accommodation of any of Licensee's Attachments necessitates Make-ready Work, in the response to Licensee’s application Pole Owner will indicate the Make-ready Work that will be necessary to accommodate the Attachments requested and the estimated cost thereof within the application processing time period identified in Section 3.02. If Licensee is willing to bear the cost of all Make-ready Work necessary, as determined by Pole Owner, Licensee shall so indicate via ENS or in writing writingthat if the issue is not resolved within thirty (30) days of the date of Pole Owner’s response to Licensee’s initial application. Pole Owner will provide Licensee an estimated completion date for any Make-ready Work, taking into account the overall scope of the Licensee’s project, the volume of applications received from other licensees, as well as the availability of crews to perform the work. The Licensee and the Pole Owner shall negotiate solutions in good faith when the estimated time to perform the Make-ready Work does not meet the Licensee’s project requirements. At Licensee’s option, Licensee may request either assistance with the work by Licensee or by qualified contractors hired by the Licensee, payment of premium rates for Pole Owner’s employees to be dedicated to perform work solely on Licensee’s project, or similar measures designed to augment the Make-ready Work using plans and contractors pre- approved by Pole Owner consistent with this AgreementOwner’s capabilities. Pole Owner will perform such Make-ready Work as may be required and Licensee will reimburse, upon demand, Pole Owner for the entire expense thereby actually and reasonably incurred. Licensee shall pay the costs of all Make-ready Work undertaken by Pole Owner where such work is initiated as a result of the proposed installation of Attachments on any poles without regard to whether Licensee elects not to use the pole or poles after Make-ready Work has commenced. An itemized statement detailing the actual material, hours, equipment costs, and any other associated costs will be provided to Licensee for payment of Make-ready Work.

Make-Ready Work. If in the reasonable judgment of Pole Owner the accommodation of any of Licensee's Attachments necessitates Make-ready Work, in the response to at Licensee’s application Pole Owner will indicate the Make-ready Work that will be necessary to accommodate the Attachments requested and the estimated cost thereof within the application processing time period identified in Section 3.02. If Licensee is willing to bear the cost of all Make-ready Work necessary, as determined by Pole Owner, Licensee shall so indicate via ENS or in writing within thirty (30) days of the date of Pole Owner’s response to Licensee’s initial application. Pole Owner will provide Licensee an estimated completion date for any Make-ready Work, taking into account the overall scope of the Licensee’s project, the volume of applications received from other licensees, as well as the availability of crews to perform the work. The Licensee and the Pole Owner shall negotiate solutions in good faith when the estimated time to perform the Make-ready Work does not meet the Licensee’s project requirements. At Licensee’s option, Licensee may request either assistance with the work by Licensee or by qualified contractors hired by the Licensee, payment of premium rates for Pole Owner’s employees to be dedicated to perform work solely on Licensee’s project, or similar measures designed to augment the Make-ready Work using plans and contractors pre- approved by Pole Owner consistent with this AgreementOwner’s capabilities. Pole Owner will perform such Make-ready Work as may be required and Licensee will reimburse, upon demand, Pole Owner for the entire sole risk and expense thereby actually and reasonably incurred. Licensee shall pay the costs of all Make-ready Work undertaken by Pole Owner where such work is initiated as a result of the proposed installation of Attachments on any poles without regard to whether Licensee elects not to use the pole or poles after Make-ready Work has commenced. An itemized statement detailing the actual material, hours, equipment costs, and any other associated costs will be provided to Licensee for payment of Make-ready Work.

Make-Ready Work. If in the reasonable judgment of Pole Owner OwnerCenturyLink the accommodation of any of Licensee's Attachments necessitates Make-ready Work, in the response to Licensee’s application Pole Owner OwnerCenturyLink will indicate the Make-ready Work that will be necessary to accommodate the Attachments requested and the estimated cost thereof within the application processing time period identified in Section 3.02. If Licensee is willing to bear the cost of all Make-ready Work necessary, as determined by Pole OwnerOwnerCenturyLink, Licensee shall so indicate via ENS or in writing within thirty (30) days of the date of Pole OwnerOwnerCenturyLink’s response to Licensee’s initial application. Pole Owner OwnerCenturyLink will provide Licensee an estimated completion date for any Make-ready Work, taking into account the overall scope of the Licensee’s project, the volume of applications received from other licensees, as well as the availability of crews to perform the work. The Licensee and the Pole Owner OwnerCenturyLink shall negotiate solutions in good faith when the estimated time to perform the Make-ready Work does not meet the Licensee’s project requirements. At Licensee’s option, Licensee may request to perform the Make-ready Work using plans and contractors pre- pre-approved by Pole Owner OwnerCenturyLink consistent with this Agreement. Pole Owner OwnerCenturyLink will perform such Make-ready Work as may be required and Licensee will reimburse, upon demand, Pole Owner OwnerCenturyLink for the entire expense thereby actually and reasonably incurred. Licensee shall pay the costs of all Make-ready Work undertaken by Pole Owner OwnerCenturyLink where such work is initiated as a result of the proposed installation of Attachments on any poles without regard to whether Licensee elects not to use the pole or poles after Make-ready Work has commenced. An itemized statement detailing the actual material, hours, equipment costs, and any other associated costs will be provided to Licensee for payment of Make-ready Work.