MANAGEMENT OF THE TYPHOID PROJECTS Sample Clauses

Open Split View

Download

Share

Cite

MANAGEMENT OF THE TYPHOID PROJECTS. 3.1 The following provisions of this clause 3 apply to all Typhoid Projects individually.

Sample 1Sample 2Sample 3

Save

Copy

Related to MANAGEMENT OF THE TYPHOID PROJECTS

• Development of the Project 4.1 TSP's obligations in development of the Project: a. for procuring and maintaining in full force and effect all Consents, Clearances and Permits, required in accordance with Law for development of the Project; b. for financing, constructing, owning and commissioning each of the Element of the Project for the scope of work set out in Schedule 1 of this Agreement in accordance with: i. the Electricity Act and the Rules made thereof; ii. the Grid Code; iii. the CEA Regulations applicable, and as amended from time to time, for Transmission Lines and sub-stations: • the Central Electricity Authority (Technical Standards for Connectivity to the Grid) Regulations, 2007; • Central Electricity Authority (Technical Standards for construction of Electrical Plants and Electric Lines) Regulation, 2010; • Central Electricity Authority (Grid Standard) Regulations, 2010; • Central Electricity Authority (Safety requirements for construction, operation and maintenance of Electrical Plants and Electrical Lines) Regulation, 2011; • Central Electricity Authority (Measures relating to Safety and Electricity Supply) Regulation, 2010; • Central Electricity Authority (Technical Standards for Communication System in Power System Operation) Regulations, 2020. iv. Safety/ security Guidelines laid down by the Government; v. Prudent Utility Practices, relevant Indian Standards and the Law; not later than the Scheduled COD as per Schedule 2 of this Agreement; c. for entering into a Connection Agreement with the concerned parties in accordance with the Grid Code. d. for owning the Project throughout the term of this Agreement free and clear of any encumbrances except those expressly permitted under Article 15 of this Agreement; e. to co-ordinate and liaise with concerned agencies and provide on a timely basis relevant information with regard to the specifications of the Project that may be required for interconnecting the Project with the Interconnection Facilities; f. for providing all assistance to the Arbitrators as they may require for the performance of their duties and responsibilities; g. to provide to the Nodal Agency and CEA, on a monthly basis, progress reports with regard to the Project and its execution (in accordance with prescribed form) to enable the CEA to monitor and co-ordinate the development of the Project matching with the Interconnection Facilities; h. to comply with Ministry of Power order no. 25-11/6/2018 – PG dated 02.07.2020 as well as other Guidelines issued by Govt. of India pertaining to this; i. to procure the products associated with the Transmission System as per provisions of Public Procurement (Preference to Make in India) orders issued by Ministry of Power vide orders No. 11/5/2018 - Coord. dated 28.07.2020 for transmission sector, as amended from time to time read with Department for Promotion of Industry and Internal Trade (DPIIT) orders in this regard (Procuring Entity as defined in above orders shall deemed to have included Selected Bidder and/ or TSP). Also, to comply with Department of Expenditure, Ministry of Finance vide Order (Public Procurement No 1) bearing File No. 6/18/2019- PPD dated 23.07.2020, Order (Public Procurement No 2) bearing File No. 6/18/2019-PPD dated 23.07.2020 and Order (Public Procurement No. 3) bearing File No. 6/18/2019-PPD, dated 24.07.2020, as amended from time to time, regarding public procurement from a bidder of a country, which shares land border with India; j. to submit to Nodal Agency information in the prescribed format [To be devised by Nodal Agency] for ensuring compliance to Article 4.1 i) above. k. to comply with all its obligations undertaken in this Agreement. 4.2 Roles of the Nodal Agency in implementation of the Project: 4.2.1 Subject to the terms and conditions of this Agreement, the Nodal Agency shall be the holder and administrator of this Agreement and shall inter alia: a. appoint an Independent Engineer within 90 days of the Effective Date b. provide letters of recommendation to the concerned Indian Governmental Instrumentality, as may be requested by the TSP from time to time, for obtaining the Consents, Clearances and Permits required for the Project; c. coordinate among TSP and upstream/downstream entities in respect of Interconnection Facilities; and d. monitor the implementation of the Agreement and take appropriate action for breach thereof including revocation of guarantees, cancellation of Agreement, blacklisting etc e. provide all assistance to the Arbitrators as required for the performance of their duties and responsibilities; and f. perform any other responsibility (ies) as specified in this Agreement.

• MANAGEMENT OF THE BUSINESS Pursuant to Section 00-00-000 of the Act, and as stated in its Articles, the Company’s day to day affairs are managed by the Member. The Member is responsible for the daily operations of the business.

• Development of the Property Except as modified by this Agreement, the Development and the Property will be developed in accordance with all applicable local, state, and federal regulations, including but not limited to the City’s ordinances and the zoning regulations applicable to the Property, and such amendments to City ordinances and regulations that that may be applied to the Development and the Property under Chapter 245, Texas Local Government Code, and good engineering practices (the “Applicable Regulations”). If there is a conflict between the Applicable Regulations and the Development Standards, the Development Standards shall control.

• Project 3.01. The Recipient declares its commitment to the objectives of the Project. To this end, the Recipient shall carry out the Project in accordance with the provisions of Article IV of the General Conditions.

• Projects There shall be a thirty (30) km free zone around the projects excluding the Metro Vancouver Area. For local residents, kilometers shall be paid from the boundary of the free zone around the project. Workers employed by any contractor within an identified free zone who resides outside of that same free zone will be paid according to the Kilometer Chart from the project to their residence less thirty

• MANAGEMENT OF EVALUATION OUTCOMES 12.1 Where the Employer is, any time during the Employee’s employment, not satisfied with the Employee’s performance with respect to any matter dealt with in this Agreement, the Employer will give notice to the Employee to attend a meeting; 12.2 The Employee will have the opportunity at the meeting to satisfy the Employer of the measures being taken to ensure that his performance becomes satisfactory and any programme, including any dates, for implementing these measures; 12.3 Where there is a dispute or difference as to the performance of the Employee under this Agreement, the Parties will confer with a view to resolving the dispute or difference; and 12.4 In the case of unacceptable performance, the Employer shall – 12.4.1 Provide systematic remedial or developmental support to assist the Employee to improve his performance; and 12.4.2 After appropriate performance counselling and having provided the necessary guidance and/or support as well as reasonable time for improvement in performance, the Employer may consider steps to terminate the contract of employment of the Employee on grounds of unfitness or incapacity to carry out his or her duties.

• Construction of the Project Highway (i) The Contractor shall construct the Project Highway as specified in Schedule- B and Schedule-C, and in conformity with the Specifications and Standards set forth in Schedule-D. The Contractor shall be responsible for the correct positioning of all parts of the Works, and shall rectify any error in the positions, levels, dimensions or alignment of the Works. The [650th (six hundred and fiftieth) day] from the Appointed Date shall be the scheduled completion date (the “Scheduled Completion Date”) and the Contractor agrees and undertakes that the construction shall be completed on or before the Scheduled Completion Date, including any extension thereof. (ii) The Contractor shall construct the Project Highway in accordance with the Project Completion Schedule set forth in Schedule-J. In the event that the Contractor fails to achieve any Project Milestone or the Scheduled Completion Date within a period of 30 (thirty) days from the date set forth in Schedule-J, unless such failure has occurred due to Force Majeure or for reasons solely attributable to the Authority, it shall pay Damages to the Authority of a sum calculated at the rate of 0.05% (zero point zero five percent) of the Contract Price for delay of each day reckoned from the date specified in Schedule –J and until such Project Milestone is achieved or the Project Highway is completed; provided that if the period for any or all Project Milestones or the Scheduled Completion Date is extended in accordance with the provisions of this Agreement, the dates set forth in Schedule-J shall be deemed to be modified accordingly and the provisions of this Agreement shall apply as if Schedule-J has been amended as above; provided further that in the event the Project Highway is completed within or before the Scheduled Completion Date including any Time Extension, applicable for that work or section, the Damages paid under this Clause 10.3 (ii) shall be refunded by the Authority to the Contractor, but without any interest thereon. The Parties agree that for determining achievement or delays in completion of the Project Milestones or the Project on the due date, the works affected due to delay in providing the site for which time extension has been granted beyond the Scheduled Completion Date will be excluded. For example on the due date to achieve the Project Milestone-I (i.e., Stage Payments of 10% (ten percent) of Contract Price on 180th (one hundred and eighty) day from the Appointed Date), if 5% (five percent) of the project length corresponding to the Project Milestone-I is not handed over or lately handed over resulting in the extension of completion of this 5% (five percent) length beyond Scheduled Completion Date, Stage Payment of 10% X 0.95 = 9.5% only is to be achieved by 180th (one hundred and eighty) day. For the avoidance of doubt, it is agreed that recovery of Damages under this Clause 10.3 (ii) shall be without prejudice to the rights of the Authority under this Agreement including the right of Termination thereof. The Parties further agree that Time Extension hereunder shall only be reckoned for and in respect of the affected Works as specified in Clause 10.5 (ii). (iii) The Authority shall notify the Contractor of its decision to impose Damages in pursuance with the provisions of this Clause 10.3. Provided that no deduction on account of Damages shall be effected by the Authority without notifying the Contractor of its decision to impose the Damages, and taking into consideration the representation, if any, made by the Contractor within 20 (twenty) days of such notice. The Parties expressly agree that the total amount of Damages under Clause 10.3 (ii) shall not exceed 10% (ten percent) of the Contract Price. If the damages exceed 10% (ten percent) of the Contract Price, the Contractor shall be deemed to be in default of this agreement having no cure and the Authority shall be entitled to terminate this Agreement by issuing a Termination Notice in accordance with the provisions of Clause 23.1 (ii). (iv) In the event that the Contractor fails to achieve the Project Completion within a period of 90 (ninety) days from the Schedule Completion Date set forth in Schedule-J, unless such failure has occurred due to Force Majeure or for reasons solely attributable to the Authority, the contractor shall be deemed to be ineligible for bidding any future projects of the Authority, both as the sole party or as one of the parties of Joint Venture/ Consortium during the period from Scheduled Completion Date to issuance of Completion Certificate. This restriction is applicable if the contract value of the delayed project is not less than Rs. 300 Crore.

• COMMENCEMENT AND COMPLETION OF THE PROJECT Section 3.01 The Project (a) The Company intends and expects, together with any Sponsor Affiliate, to (i) construct and acquire the Project, and (ii) meet the Contract Minimum Investment Requirement within the Investment Period. The Company anticipates that the first Phase of the Project will be placed in service during the calendar year ending December 31, 2020. (b) Pursuant to the FILOT Act and subject to Section 4.03 hereof, the Company and the County hereby agree that the Company and any Sponsor Affiliates shall identify annually those assets which are eligible for FILOT payments under the FILOT Act and which the Company or any Sponsor Affiliate selects for such treatment by listing such assets in its annual PT-300S form (or comparable form) to be filed with the Department (as such may be amended from time to time) and that by listing such assets, such assets shall automatically become Economic Development Property and therefore be exempt from all ad valorem taxation during the Exemption Period. Anything contained in this Fee Agreement to the contrary notwithstanding, the Company and any Sponsor Affiliates shall not be obligated to complete the acquisition of the Project. However, if the Company, together with any Sponsor Affiliates, does not meet the Contract Minimum Investment Requirement within the Investment Period, the provisions of Section 4.03 hereof shall control. (c) The Company may add to the Land such real property, located in the same taxing District in the County as the original Land, as the Company, in its discretion, deems useful or desirable. In such event, the Company, at its expense, shall deliver an appropriately revised Exhibit A to this Fee Agreement, in form reasonably acceptable to the County.

• Procurement of the Site (i) The Authority Representative, the Contractor and Authority’s Engineer shall, within 10 (ten) days of the date of this Agreement, inspect the Site and prepare a detailed memorandum containing an inventory of the Site including the vacant and unencumbered land, buildings, structures, road works, trees and any other immovable property on or attached to the Site (hereinafter referred to as the “Handover Memorandum”). Subject to the provisions of Clause 8.2 (iii), the Handover Memorandum shall have appended thereto an appendix (the “Appendix”) specifying in reasonable detail those parts of the Site to which vacant access and Right of Way has not been given to the Contractor along with details of hindrances in the Construction Zone. For sake of clarity the Handover Memorandum shall clearly specify the parts of Site where work can be executed. Signing of the Handover Memorandum, in three counterparts (each of which shall constitute an original), by the authorized representatives of the Authority, Contractor and Authority’s Engineer shall be deemed to constitute a valid evidence of giving the Right of Way to the Contractor for discharging its obligations under and in accordance with the provisions of this Agreement and for no other purpose whatsoever. (ii) Whenever the Authority is ready to hand over any part or parts of the Site included in the Appendix, it shall inform the Contractor, by notice, of the proposed date and time such of hand over. The Authority Representative and the Contractor shall, on the date so notified, inspect the specified parts of the Site, and prepare a memorandum containing an inventory of the vacant and unencumbered land, buildings, structures, road works, trees and any other immovable property on or attached to the Site so handed over. The signing of the memorandum, in three (3) counterparts (each of which shall constitute an original), by the authorised representatives of the Parties shall be deemed to constitute a valid evidence of giving the relevant Right of Way to the Contractor. If the contractor fails to join for site inspection or disputes the parts of the site available for work, the Authority’s Engineer shall decide the parts of the site where work can be executed and notify to both the parties within 3 days of the proposed date of inspection. The parties agree that such notification of the Authority’s Engineer as mentioned hereinabove shall be final and binding on the parties. (iii) The Authority shall provide the Right of Way to the Contractor in respect of all land included in the Appendix by the date specified in Schedule-A for those parts of the Site referred to therein, and in the event of delay for any reason other than Force Majeure or breach of this Agreement by the Contractor, it shall pay to the Contractor, Damages in a sum calculated in accordance with Clause 8.3. The Contractor agrees that it shall not be entitled to claim any other damages on account of any such delay by the Authority. (iv) Notwithstanding anything to the contrary contained in this Clause 8.2, the Authority shall specify the parts of the Site, if any, for which Right of Way shall be provided to the Contractor on the dates specified in Schedule-A. Such parts shall also be included in the Appendix prepared in pursuance of Clause 8.2 (i). (v) The Authority further acknowledges and agrees that prior to the Appointed Date, it shall have procured issuance of the statutory notification under Applicable Laws for vesting of all the land comprising the Project in the Authority and has taken possession of area for Construction Zone for at least 90% (ninety per cent) of the total length of the Project Highway. The Parties also acknowledge and agree that the conditions specified in this Clause 8.2 (iii) shall not be modified or waived by either Party. (vi) For the avoidance of doubt, the Parties expressly agree that the Appendix shall in no event contain sections of the Project Highway the cumulative length of which exceeds 10% (ten percent) of the total length of the Project Highway. (vii) Pursuant to signing of Handover Memorandum under clause 8.2 (i), Contractor shall submit to the Authority’s Engineer, a monthly land possession report till expiry of 180 (one hundred and eighty) days from Appointed Date, in respect of those parts of the site to which vacant access and right of way was not given to the contractor and included in Appendix to the memorandum signed under clause 8.2 (i), duly specifying the part of the site, if any, for which the right of way is yet to be handed over.

• PROFESSIONAL DEVELOPMENT AND EDUCATIONAL IMPROVEMENT A. The Board of Education agrees to pay the actual tuition costs of courses taken by a teacher at accredited colleges or universities up to three courses per two (2) year fiscal periods from July 1, 2006 to June 30, 2008 and July 1, 2008 to June 30, 2010 respectively, except as follows: 1. No teacher may be reimbursed for courses taken during the first year of teaching in Vineland. 2. Teachers taking courses in the second and third years of employment in Vineland will not receive remuneration until tenure has been secured. The remuneration will then be retroactive and will be paid to the teacher in a lump sum within sixty (60) days after the teacher has secured tenure. 3. All courses must be pre-approved by the Superintendent or his designee subject to the following requirements: (a) A teacher must provide official documentation that he/she has obtained a grade of B or better; (b) Reimbursement shall be paid only for courses directly related to teacher’s teaching field which increase the teacher’s content knowledge and are related to the teacher’s current certification, as determined by the Superintendent or his/her designee in his/her sole discretion; no reimbursement shall be paid for courses leading to a post graduate or professional degree in a field other than education or teaching. Further, effective September 1, 2010, all newly hired teachers shall not be eligible for reimbursement until they are tenured, and they shall not be eligible for retroactive reimbursement upon gaining tenure for courses taken prior to being tenured. (c) The maximum total payments to be made by the Board shall not exceed $130,000.00. Courses shall be applied for no earlier than the following dates: Summer Session - April 1 Fall/Winter Session - June 1 Spring Session - October 1 Courses must, as set forth hereinabove in this sub-article 18.A.3, be pre-approved by the Superintendent or his designee, prior to the teacher commencing the course(s); and (d) Teacher taking courses shall sign a contract requiring them to reimburse the Board for all tuition paid for a course if the teacher shall voluntarily leave the employ of the Board within one (1) full school/academic year of completion of said course, except that reimbursement shall not be required when the teacher shall voluntarily leave the employ of the Board due to a significant, documented life change. 4. Tuition reimbursement costs shall be a sum not to exceed the actual cost of college credits charged in an accredited public State college/University of the State of New Jersey. B. When the Superintendent initiates in-service training courses, workshops, conferences and programs designed to improve the quality of instruction, the cooperation of the Vineland Education Association will be solicited. Notwithstanding the above, the initiation of in-service training courses, workshops, conferences and programs shall be determined solely at the discretion of the Board. C. One professional leave day may be granted to a teacher upon request, according to the following guidelines: 1. The professional day may be for attendance at a workshop, seminar or visit to another school for the expressed purpose of self professional improvement for the job. 2. The request shall arrive in the office of the Superintendent of Schools at least ten (10) working days prior to the date requested and shall be reviewed by the immediate supervisor prior to submission. The Board reserves the right to deny a professional leave day before or immediately following a holiday or on a day which by its nature suggests a hardship for providing a substitute. 3. No more than two teachers from any one elementary school or from any one department in the secondary schools may be granted a professional leave for a given day. 4. The teacher may be required to submit a report to the Superintendent of Schools, Assistant Superintendent, supervisor (s), principal and staff regarding the activity of the professional day. 5. Costs incurred by the teacher for the professional day authorized under this Section shall be the teacher’s responsibility. 6. A maximum of 90 professional leave days may be authorized for the school year which shall be apportioned as follows: elementary, 35; grades seven and eight, 20; and high school, 35. D. If the Board initiates a teacher’s attendance at a professional workshop, seminar or visit, the expenses shall be the responsibility of the Board. Further, this day shall not be subtracted from the 90 professional leave days granted to teachers of the Association. E. The Board agrees to pay the full cost of courses taken by secretaries related to skills and knowledge improvement when such courses are required and approved by the Board. F. The Board and the Association agree that it is important to communicate when developing and implementing current and future learning technologies, including but not limited to distance and on-line learning.