Owner’s Rights B.1.1 The Owner shall have the right to perform work related to the project and to award contracts in connection with the project that are not part of the Consultant’s responsibilities under the AGREEMENT. The consultant shall notify the Owner in writing if any such independent action will in any way compromise the Consultants’ ability to meet their responsibilities under the AGREEMENT. B.1.2 The Owner reserves the right to approve the consultant’s personnel and to require a replacement satisfactory to the Owner. The Owner reserves the right to have such person replaced if, in the judgment of the Owner, any such person proves unsatisfactory. However, such replacement must fit within the rate/fee structure; in the alternative, the Owner shall have the option for a higher rate person for which the Consultant shall be compensated at the higher rate. B.1.3 The Owner shall have the right to effect the removal of any of the Consultant’s employees at any time during the duration of the AGREEMENT if that employee is deemed not to be of the level of competence or ability required under the AGREEMENT, or said employee is for any reason found to be unsuitable for the work. In such case, the Consultant shall promptly submit the name and qualifications of a replacement for approval by the Owner. B.1.4 The Owner shall have the right to assign the administration of any or all contracts related to this project from the Owner to another State Agency, Authority or Commission at any time during the life of the project. In doing so, the Consultant agrees to continue to perform all contractual work under the AGREEMENT. The Consultant shall make no claim against the Owner in the event of such assignment. B.1.5 The Owner may make changes in the scope of services within the general scope of the AGREEMENT. The Owner may also make changes to the scope of the project which may give rise to changes in the scope of the Consultant services. In such case, the Consultant shall be entitled to an adjustment in fee and in other terms and conditions of the AGREEMENT.
GRANTOR'S RIGHT TO POSSESSION AND TO COLLECT ACCOUNTS Until default and except as otherwise provided below with respect to accounts, Grantor may have possession of the tangible personal property and beneficial use of all the Collateral and may use it in any lawful manner not inconsistent with this Agreement or the Related Documents, provided that Grantor's right to possession and beneficial use shall not apply to any Collateral where possession of the Collateral by Lender is required by law to perfect Lender's security interest in such Collateral. Until otherwise notified by Lender, Grantor may collect any of the Collateral consisting of accounts. At any time and even though no Event of Default exists, Lender may exercise its rights to collect the accounts and to notify account debtors to make payments directly to Lender for application to the Indebtedness. If Lender at any time has possession of any Collateral, whether before or after an Event of Default, Lender shall be deemed to have exercised reasonable care in the custody and preservation of the Collateral if Lender takes such action for that purpose as Grantor shall request or as Lender, in Lender's sole discretion, shall deem appropriate under the circumstances, but failure to honor any request by Grantor shall not of itself be deemed to be a failure to exercise reasonable care. Lender shall not be required to take any steps necessary to preserve any rights in the Collateral against prior parties, nor to protect, preserve or maintain any security interest given to secure the Indebtedness.
Preservation of Sellers’ Rights of Recovery Without the prior written consent of the Sellers, the Purchasers shall not amend or modify or grant a waiver under (or agree to amend or modify or grant a waiver under) any Serviced Corporate Trust Contract with respect to any Serviced Appointment in a manner that would materially reduce or materially alter the rights of the Sellers to indemnification, reimbursement or recovery for any costs and expenses incurred by the Sellers or their Affiliates or agents (other than the Purchasers in their capacity as Servicer hereunder) from the sponsor, issuer, obligor, depositor or other source of funds available under the terms of any such Serviced Corporate Trust Contract. Notwithstanding the foregoing, such amendment, modification or waiver shall not require the Sellers’ consent if the Purchasers agree in their sole discretion to indemnify the Sellers to the extent such amendment, modification or waiver reduces the Sellers’ available indemnification, reimbursement or recovery for costs and expenses under the terms of any such Serviced Corporate Trust Contract.
Owner’s Right to Stop Work The Owner reserves the right, for itself and for any designated Construction Inspector retained by Owner, upon observation of apparent nonconforming Work, to immediately stop the affected Work. If the Work is later determined by the Design Professional to be in fact conforming Work, then Contractor shall be entitled upon timely claim to a Change Order for payment by Owner of any reasonable Actual Costs actually incurred by Contractor in connection with the stop Work order and resumption of the Work, as well as an extension in the time for performance of the Work to the extent Contractor is delayed by Owner's stop Work order. The Design Professional shall determine the time, which shall be binding upon both Owner and Contractor, as set forth in Section 3, Part 3.
OWNER’S RIGHT TO CARRY OUT THE WORK If the Contractor defaults or neglects to carry out the Work in accordance with the Contract Documents and fails within a ten (10)-calendar day period after receipt of written notice from the Owner to commence and continue correction of such default or neglect with diligence and promptness, the Owner may, without prejudice to other remedies the Owner may have, correct such deficiencies. In such case an appropriate Change Order shall be issued deducting from payments then or thereafter due the Contractor the reasonable cost of correcting such deficiencies, including Owner’s expenses and compensation for the Architect’s additional services made necessary by such default, neglect or failure. Such action by the Owner and amounts charged to the Contractor are both subject to prior approval of the Architect. If payments then or thereafter due the Contractor are not sufficient to cover such amounts, the Contractor shall pay the difference to the Owner.
Waivers, Rights and Remedies Except as expressly provided in this Agreement, no failure or delay by any Party in exercising any right or remedy relating to this Agreement shall affect or operate as a waiver or variation of that right or remedy or preclude its exercise at any subsequent time. No single or partial exercise of any such right or remedy shall preclude any further exercise of it or the exercise of any other remedy.
LESSOR'S RIGHT OF ENTRY The Lessor or the Lessor's agent may enter at reasonable hours to inspect or show the Premises to prospective lenders and purchasers, and to do anything the Lessor may be required to do hereunder or which the Lessor may deem necessary for the good of the Premises or any building of which they are apart. During the last [#] days of the Term, the Lessor may display a "For Rent" sign on the Premises and show the Premises to prospective lessees.
Secured Party’s Rights and Remedies If at any time (1) an Event of Default or Specified Condition with respect to the Pledgor has occurred and is continuing or (2) an Early Termination Date has occurred or been designated as the result of an Event of Default or Specified Condition with respect to the Pledgor, then, unless the Pledgor has paid in full all of its Obligations that are then due, the Secured Party may exercise one or more of the following rights and remedies: (i) all rights and remedies available to a secured party under applicable law with respect to Posted Collateral held by the Secured Party; (ii) any other rights and remedies available to the Secured Party under the terms of Other Posted Support, if any; (iii) the right to Set-off any amounts payable by the Pledgor with respect to any Obligations against any Posted Collateral or the Cash equivalent of any Posted Collateral held by the Secured Party (or any obligation of the Secured Party to Transfer that Posted Collateral); and (iv) the right to liquidate any Posted Collateral held by the Secured Party through one or more public or private sales or other dispositions with such notice, if any, as may be required under applicable law, free from any claim or right of any nature whatsoever of the Pledgor, including any equity or right of redemption by the Pledgor (with the Secured Party having the right to purchase any or all of the Posted Collateral to be sold) and to apply the proceeds (or the Cash equivalent thereof) from the liquidation of the Posted Collateral to any amounts payable by the Pledgor with respect to any Obligations in that order as the Secured Party may elect. Each party acknowledges and agrees that Posted Collateral in the form of securities may decline speedily in value and is of a type customarily sold on a recognized market, and, accordingly, the Pledgor is not entitled to prior notice of any sale of that Posted Collateral by the Secured Party, except any notice that is required under applicable law and cannot be waived.
Access Rights Upon reasonable notice and supervision by the Granting Party, and subject to any required or necessary regulatory approvals, either the Connecting Transmission Owner or Developer (“Granting Party”) shall furnish to the other of those two Parties (“Access Party”) at no cost any rights of use, licenses, rights of way and easements with respect to lands owned or controlled by the Granting Party, its agents (if allowed under the applicable agency agreement), or any Affiliate, that are necessary to enable the Access Party to obtain ingress and egress at the Point of Interconnection to construct, operate, maintain, repair, test (or witness testing), inspect, replace or remove facilities and equipment to: (i) interconnect the Large Generating Facility with the New York State Transmission System; (ii) operate and maintain the Large Generating Facility, the Attachment Facilities and the New York State Transmission System; and (iii) disconnect or remove the Access Party’s facilities and equipment upon termination of this Agreement. In exercising such licenses, rights of way and easements, the Access Party shall not unreasonably disrupt or interfere with normal operation of the Granting Party’s business and shall adhere to the safety rules and procedures established in advance, as may be changed from time to time, by the Granting Party and provided to the Access Party. The Access Party shall indemnify the Granting Party against all claims of injury or damage from third parties resulting from the exercise of the access rights provided for herein.