General Responsibilities of the Parties 1. The Parties will work together in a spirit of cooperation and partnership, with the responsibilities and accountabilities set out in this Agreement, to implement the Programme Documents in full in a timely, efficient, and effective, manner.
2. The Parties agree to carry out their respective responsibilities in accordance with the provisions of this Agreement, including the Programme Documents.
3. The Parties shall keep each other informed of all relevant activities pertaining to the implementation of the Programme Documents, and shall hold consultations when either Party considers it appropriate, including any circumstance that may affect the achievement of the results of the Programme and the Programme Documents.
4. The Parties shall fulfill their commitments with the fullest regard for the terms and conditions of this Agreement and the principles of the United Nations.
Professional Responsibilities Other activities to support the delivery of the Xxxxxx Xxxxxx Business Plan and Xxxxxx Mission Strategic Plan, as requested by your manager • As an employee, be responsible under the Work Health & Safety Act for the health and safety of all persons they come into contact with, during employment • All hazards and injuries must be reported through the normal process as set out in Xxxxxx Mission’s Work Health, Safety and Rehabilitation Quality Management System and site procedures • Participate in the review and maintenance of industry specific and internal audit processes, as per Xxxxxx Mission’s standard policy and procedures • In relation to Xxxxxx Mission and the Uniting Church in Australia, attend such functions, meetings, seminars, training courses as directed by your supervisor • In relation to Xxxxxx Mission attend worship services as encouraged by your supervisor • Participate on a quarterly basis in Xxxxxx Mission’s Employee contribution and development process • Take responsibility for personal career development and training • Participate in Xxxxxx Mission’s Orientation program, so as to gain an understanding of, and • promote, the application of the EEO, Affirmative Action, Privacy Act, Work Health & Safety Act and other relevant legislation • Administer Xxxxxx Mission’s philosophy of care and other relevant policy documents as appropriate • Demonstrate responsible stewardship of all resources, and willingness to report impropriety in keeping with the values of Xxxxxx Mission • Ensure the reputation and integrity of Xxxxxx Mission is maintained at all times • Maintain confidentiality
Contractor’s General Responsibilities The Contractor, regardless of any delegation or subcontract entered by the Contractor, shall be responsible for the following when providing information technology staff augmentation services:
3.1 The Contractor is responsible for the comprehensive management of Staff. Staff shall not be deemed an employee of the State or deemed to be entitled to any benefits associated with such employment and the Contractor shall be responsible for the administration and maintenance of all employment and payroll records, payroll processing, remittance of payroll and taxes, and all administrative tasks required by state and federal law associated with payment of Staff.
3.2 The Contractor shall provide Staff in accordance with Customer Requests for Quote (RFQ), and as described in Contract Exhibit J, Job Family Descriptions document. Customers may include detailed scopes of work, specific requirements of the work to be performed, and any requirements of Staff within the Request for Quote.
3.3 The Contractor shall possess the professional and technical staff necessary to allocate, outsource, and manage qualified Staff to perform the services requested by the Customer.
3.4 The Contractor shall provide Customers with Staff who have sufficient skill and experience to perform the services assigned to them.
3.5 The Contractor is responsible for ensuring that all information technology staff augmentation services furnished under the Contract meet the professional standards and quality that prevails among information technology professionals in the same discipline and of similar knowledge and skill engaged in related work throughout Florida under the same or similar circumstances.
3.6 The Contractor shall provide, at its own expense, training necessary for keeping Contractor’s Staff abreast of industry advances and for maintaining proficiency in equipment and systems that are available on the commercial market.
3.7 The Contractor shall, at its own expense, be responsible for adhering to the Contract background screening requirements, testing, evaluations, advertising, recruitment, and disciplinary actions of Contractor’s Staff.
3.8 The Contractor, throughout the term of the Contract, shall maintain all licenses, permits, qualifications, insurance, and approvals of whatever nature that are legally required for Contractor and Staff to perform the information technology staff augmentation services.
3.9 Contractor shall be responsible for all costs associated with the administration of this Contract.
3.10 The Contractor shall adhere to all work policies, procedures, and standards established by the Department and Customer.
3.11 The Contractor shall ensure that Staff conform with the Customer’s policies in all respects while on the Customer’s premises, and is responsible for obtaining all rules, regulations, policies, etc.
3.12 Contractor shall only provide information technology staff augmentation services for those Job Titles awarded to the Contractor and shall be paid on an hourly basis. Contracts resulting from this solicitation should not be structured as fixed-price agreements or used for any services requiring authorization for payment of milestone tasks.
Additional Responsibilities This paragraph applies to all phases of Architect's work.
(a) Architect shall be responsible for the professional quality, technical accuracy, timely completion and coordination of all of Architect's work, including that performed by Architect's consultants, and including designs, Drawings, Specifications, reports and other services, irrespective of Owner's approval or acquiescence in same. Architect shall, without additional compensation, correct or revise any errors, omissions or other deficiencies in his work.
(b) Architect shall be responsible, in accordance with applicable law, to Owner for all loss or damage to Owner caused by Architect's negligent act or omission; except that Architect hereby irrevocably waives and excuses Owner and its attorneys from compliance with any requirement to obtain a certificate of review as a condition precedent to commencement of an action, including any such requirements set forth in Section 00-00-000, C.R.S. or similar statute.
(c) Architect's professional responsibility shall comply with the standard of care applicable to the type of engineering and architectural services provided, commensurate with the size, scope and nature of the Project.
(d) Architect shall be completely responsible for the safety of Architect's employees in the execution of work under this Agreement, shall provide all necessary safety equipment for said employees, and shall hold harmless and indemnify and defend Owner from any and all claims, suits, loss or injury to Architect's employees.
(e) Architect acknowledges that, due to the nature of architectural and related professional services and the impact of same on the Project, the Owner has a substantial interest in the personnel and consultants to whom Architect assigns principal responsibility for services performed under this Agreement. Consequently, Architect represents that Architect has selected and intends to employ or assign the key personnel and consultants identified in Appendix C - "Identification of Personnel, Subcontractors and Task Responsibility", attached hereto for the Project assignments and areas of responsibility stated therein. Within 10 days of execution of this Agreement, Owner shall have the right to object in writing to employment on the Project of any such key person, consultant or assignment of principal responsibility, in which case Architect will employ alternate personnel for such function or reassign such responsibility to another to whom Owner has no reasonable objection. Thereafter, Architect shall not assign or reassign Project work to any person to whom Owner has reasonable objection. Within 5 days of execution of this Agreement, Architect shall designate in writing a Project representative who shall have complete authority to bind Architect, and to whom Owner should address communications.
(f) Promptly after execution of this Agreement and upon receipt of authorization from Owner to proceed, Architect shall submit to Owner for approval a schedule showing the order in which Architect proposes to accomplish his work, with dates on which he will commence and complete each major work item. The schedule shall provide for performance of the work in a timely manner so as to not delay Owner's time table for achievement of interim tasks and final completion of Project work, provided however, the Architect will not be responsible for delays beyond his control.
(g) Before undertaking any work which Architect considers beyond or in addition to the scope of work and services which Architect has contractually agreed to perform under the terms of this Agreement, Architect shall advise Owner in writing (i) that Architect considers the work beyond the scope of this Agreement, (ii) the reasons the Architect believes the out of scope or additional work should be performed, and (iii) a reasonable estimate of the cost of such work. Architect shall not proceed with such out of scope or additional work until authorized in writing by Owner. The compensation for such authorized work shall be negotiated, but in the event the parties fail to negotiate or are unable to agree as to compensation, then Architect shall be compensated for his direct costs and professional time at the rates set forth in Appendix B - "Fee Schedule".
ARCHITECT’S RESPONSIBILITIES § 2.1 The Architect shall provide professional services as set forth in this Agreement. The Architect represents that it is properly licensed in the jurisdiction where the Project is located to provide the services required by this Agreement, or shall cause such services to be performed by appropriately licensed design professionals.
§ 2.2 The Architect shall perform its services consistent with the professional skill and care ordinarily provided by architects practicing in the same or similar locality under the same or similar circumstances. The Architect shall perform its services as expeditiously as is consistent with such professional skill and care and the orderly progress of the Project.
§ 2.3 The Architect shall identify a representative authorized to act on behalf of the Architect with respect to the Project.
§ 2.4 Except with the Owner’s knowledge and consent, the Architect shall not engage in any activity, or accept any employment, interest or contribution that would reasonably appear to compromise the Architect’s professional judgment with respect to this Project.
§ 2.5 The Architect shall maintain the following insurance until termination of this Agreement. If any of the requirements set forth below are in addition to the types and limits the Architect normally maintains, the Owner shall pay the Architect as set forth in Section 11.9.
§ 2.5.1 Commercial General Liability with policy limits of not less than « » ($ « » ) for each occurrence and « » ($ « » ) in the aggregate for bodily injury and property damage.
§ 2.5.2 Automobile Liability covering vehicles owned, and non-owned vehicles used, by the Architect with policy limits of not less than « » ($ « » ) per accident for bodily injury, death of any person, and property damage arising out of the ownership, maintenance and use of those motor vehicles, along with any other statutorily required automobile coverage.
§ 2.5.3 The Architect may achieve the required limits and coverage for Commercial General Liability and Automobile Liability through a combination of primary and excess or umbrella liability insurance, provided such primary and excess or umbrella liability insurance policies result in the same or greater coverage as the coverages
Responsibilities of Contractor A. The Contractor shall perform all work on the described project as required by the Contract documents. The work to be performed includes the labor and services necessary to produce such replacement, and all materials, supplies, tools, transportation, equipment, and machinery required for replacement.
B. This project bid includes all materials, labor and equipment to complete the reconstruction and resurfacing of streets as outlined in the Project Manual for WWREYN - XXXXXXXX SANITARY SEWER - PHASE 1 dated March 25th, 2021 as outlined in Attachment A.
Professional Responsibility 19.01 The parties agree that resident care is enhanced if concerns relating to professional practice and workload are resolved in a timely and effective manner, as set out below; In the event that the Home assigns a number of residents or a workload to an individual employee or group of employees, such that she or they have cause to believe that she or they are being asked to perform more work than is consistent with proper resident care, she or they shall:
i) At the time the workload issue occurs, discuss the issue within the Home to develop strategies to meet resident care needs using current resources. If necessary, using established lines of communication, seek immediate assistance from an individual(s) identified by the Home who has responsibility for timely resolution of workload issues.
ii) Failing resolution at the time of occurrence of the workload issue, complain in writing to the Union-Management Committee within twenty (20) calendar days of the alleged improper assignment. The chairperson of the Union-Management Committee shall convene a meeting of the Union-Management Committee within twenty (20) calendar days of the filing of the complaint. The Union-Management Committee shall hear and attempt to resolve the complaint to the satisfaction of both parties. The Employer will provide a written response to the Union, with a copy to the ONA representation within ten (10) calendar days.
iii) Prior to the complaint being forwarded to the Independent Assessment Committee, the Union may forward a written report outlining the complaint and recommendations to the Director of Resident Care and/or the Administrator.
iv) At any time during this process, the parties may agree to the use of a mediator to assist in the resolution of the Professional Practice issues.
v) Any settlement arrived at under 19.01 (a) i) – iii) shall be signed by the parties.
vi) Failing resolution of the complaint within twenty (20) calendar days of the meeting of the Union-Management Committee, the complaint shall be forwarded to an independent Assessment Committee composed of three (3) registered nurses; one chosen by the Ontario Nurses' Association, one chosen by the Home and one chosen from a panel of independent registered nurses who are well respected within the profession. The member of the Committee chosen from the panel of independent registered nurses shall act as Chairperson.
vii) The Independent Assessment Committee shall set a date to conduct a hearing into the complaint, within twenty (20) calendar days of its appointment, and shall be empowered to investigate as is necessary to properly assess the merits of the complaint. The Independent Assessment Committee shall report its findings, in writing, to the parties within twenty (20) calendar days following completion of its hearing.
(b) i) The list of Independent Assessment Committee Chairpersons is attached as Appendix “B”. The members of the panel shall sit in rotation as agreed by the parties. If a panel member is unable to sit within the time limit stipulated, the panel member next scheduled to sit will be appointed by the parties.
Patent Filing Responsibilities and Costs 1. The invention and patent rights herein apply to any patent application or patents covering an invention made under this Agreement. Each Party is responsible for its own costs of obtaining and maintaining patents covering sole inventions of its employees. The Parties may agree otherwise, upon the reporting of any invention (sole or joint) or in any license granted.
2. Partner shall include the following in patent applications for an invention made jointly between NASA employees, its Related Entity employees and Partner employees: The invention described herein may be manufactured and used by or for the U.S. Government for U.S. Government purposes without the payment of royalties thereon or therefore.
Joint Responsibilities The relationship between SAE ITC, the Activities and its Members shall be, and at all times, advisory only, and no party shall have the authority to enter into any contract or commitment in the name of, or on behalf of, any other party. Nothing in this Agreement shall be construed to confer upon either party the status of employee, agent, partner, joint venturer or legal representative of the other, it being intended by all parties to remain independent legal entities solely responsible for its own actions.
Specific Responsibilities Without limiting the responsibilities of the Manager, the Manager will:
1. Maintain office facilities (which may be in the offices of the Manager or a corporate affiliate but shall be in such location as the Trust reasonably determines).
2. Furnish statistical and research data, clerical services and stationery and office supplies.
3. Compile data for, prepare for execution by the Fund and file all the Fund’s federal and state tax returns and required tax filings other than those required by this Agreement to be made by the Fund’s custodian and transfer agent.
4. Prepare compliance filings pursuant to state securities laws with the advice of the Trust’s counsel.
5. Prepare the Trust’s Annual and Semi-Annual Reports to Shareholders and amendments to its Registration Statements (on Form N-1A or any replacement therefor).
6. Compile data for, prepare and file timely Notices to the SEC required pursuant to Rule 24f-2 under the 1940 Act.
7. Determine the daily pricing of the portfolio securities and computation of the net asset value and the net income of Fund in accordance with the Prospectus, resolutions of the Trust’s Board of Trustees, and the procedures set forth in EXHIBIT A: NET ASSET VALUE CALCULATIONS.
8. Keep and maintain the financial accounts and records of the Fund and provide the Trust with certain reports, as needed or requested by the Fund.
9. Provide officers for the Trust as requested by the Trust’s Board of Trustees.
10. Perform fund accounting services for the Fund as set forth in EXHIBIT B: FUND ACCOUNTING FUNCTIONS.
11. Generally assist in all aspects of the operations of the Fund.
