Minimum Condition and Warranty Requirements for TIPS Sales All goods quoted or sold through a TIPS Sale shall be new unless clearly stated otherwise in writing. All new goods and services shall include the applicable manufacturers minimum standard warranty unless otherwise agreed to in the Supplemental Agreement.
Accessibility of Web-Based Information and Applications For State Agency Authorized User Acquisitions: Any web-based information and applications development, or programming delivered pursuant to the contract or procurement, will comply with New York State Enterprise IT Policy NYS-P08-005, Accessibility of Web-Based Information and Applications as follows: Any web-based information and applications development, or programming delivered pursuant to the contract or procurement, will comply with New York State Enterprise IT Policy NYS-P08- 005, Accessibility of Web-Based Information and Applications as such policy may be amended, modified or superseded, which requires that state agency web-based information and applications are accessible to persons with disabilities. Web-based information and applications must conform to New York State Enterprise IT Policy NYS-P08-005 as determined by quality assurance testing. Such quality assurance testing will be conducted by the State Agency Authorized User and the results of such testing must be satisfactory to the Authorized User before web-based information and applications will be considered a qualified deliverable under the contract or procurement.
Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.
GEOGRAPHIC AREA AND SECTOR SPECIFIC ALLOWANCES, CONDITIONS AND EXCEPTIONS The following allowances and conditions shall apply where relevant: Where the company does work which falls under the following headings, the company agrees to pay and observe the relevant respective conditions and/or exceptions set out below in each case.
Meteorological Data Reporting Requirement (Applicable to wind generation facilities only) The wind generation facility shall, at a minimum, be required to provide the Transmission Provider with site-specific meteorological data including: • Temperature (degrees Fahrenheit) • Wind speed (meters/second) • Wind direction (degrees from True North) • Atmosphere pressure (hectopascals) • Forced outage data (wind turbine and MW unavailability)
Responsibility for Quality of Materials and Installation Contractor acknowledges that he has full, total, and complete responsibility for providing materials, labor, and all other items necessary for providing the level of quality specified in the Contract Documents. He agrees that this responsibility is indivisible, non-delegable, non- transferable, and not diminished by any inspections provided by the Design Professional or his consulting engineers, nor by any inspections provided by the Owner. In recognition of this, Contractor will prepare for submission and review by the Design Professional, a written program describing the efforts that will be taken to insure the proper quality level is achieved. The program shall be submitted prior to the issuance of a Proceed Order.
Exclusions and Limitations for Third Party Software SUBJECT TO THE EXCLUSION OF DAMAGES STATED IN SECTION 9.2 AND WITH RESPECT TO THIRD PARTY SOFTWARE, UNDER NO CIRCUMSTANCES AND REGARDLESS OF THE NATURE OF ANY CLAIM SHALL SAP OR ITS LICENSORS’ BE LIABLE FOR AN AMOUNT IN EXCESS OF THE PAID LICENSE FEES FOR THE THIRD PARTY SOFTWARE DIRECTLY CAUSING THE DAMAGES.
Minimum Shipping Requirements for TIPS Sales Vendor shall ship, deliver, or provide ordered goods and services within a commercially reasonable time after acceptance of the order. If a delay in delivery is anticipated, Vendor shall notify the TIPS Member as to why delivery is delayed and provide an updated estimated time for completion. The TIPS Member may cancel the order if the delay is not commercially acceptable or not consistent with the Supplemental Agreement applicable to the order.
Technical Standards Applicable to a Wind Generating Plant i. Low Voltage Ride-Through (LVRT) Capability A wind generating plant shall be able to remain online during voltage disturbances up to the time periods and associated voltage levels set forth in the standard below. The LVRT standard provides for a transition period standard and a post-transition period standard.
Technical Feasibility of String While ICANN has encouraged and will continue to encourage universal acceptance of all top-‐level domain strings across the Internet, certain top-‐level domain strings may encounter difficulty in acceptance by ISPs and webhosters and/or validation by web applications. Registry Operator shall be responsible for ensuring to its satisfaction the technical feasibility of the TLD string prior to entering into this Agreement.
