Payment of Liquidated Damages With respect to any Liquidated Damages that accrue, Owner shall invoice Contractor for such Liquidated Damages. Contractor shall pay such Liquidated Damages within ten (10) Days after Contractor’s receipt of such invoice. To the extent Contractor does not pay such Liquidated Damages within such ten (10) Day period, Owner may, at its option, do one or more of the following: (i) withhold from Contractor amounts that are otherwise due and payable to Contractor in the amount of such Liquidated Damages and/or (ii) collect on the Letter of Credit in the amount of such Liquidated Damages. For the avoidance of doubt, prior to exercising such right to withhold or collect on the Letter of Credit, Owner shall not be required to provide the notice as set forth in Section 7.8. As used in this Agreement, Liquidated Damages are “paid” if and to the extent Owner exercises option (i) or (ii) above for the collection of Liquidated Damages.
Waiver of Liquidated Damages If the Partnership is unable to cause a Registration Statement to become effective on or before the Target Effective Date, then the Partnership may request a waiver of the Liquidated Damages, which may be granted by the consent of the Holders of at least the Registrable Securities Required Voting Percentage, in their sole discretion, and which such waiver shall apply to all the Holders of Registrable Securities included on such Registration Statement.
Maximum Amount (a) It is the intention of the Borrowers and the Lenders to conform strictly to the usury and similar laws relating to interest from time to time in force, and all agreements between the Loan Parties and their respective Subsidiaries and the Lenders, whether now existing or hereafter arising and whether oral or written, are hereby expressly limited so that in no contingency or event whatsoever, whether by acceleration of maturity hereof or otherwise, shall the amount paid or agreed to be paid in the aggregate to the Lenders as interest (whether or not designated as interest, and including any amount otherwise designated but deemed to constitute interest by a court of competent jurisdiction) hereunder or under the other Loan Documents or in any other agreement given to secure the Indebtedness evidenced hereby or other Obligations of the Borrowers, or in any other document evidencing, securing or pertaining to the Indebtedness evidenced hereby, exceed the maximum amount permissible under applicable usury or such other laws (the “Maximum Amount”). If under any circumstances whatsoever fulfillment of any provision hereof, or any of the other Loan Documents, at the time performance of such provision shall be due, shall involve exceeding the Maximum Amount, then, ipso facto, the obligation to be fulfilled shall be reduced to the Maximum Amount. For the purposes of calculating the actual amount of interest paid and/or payable hereunder in respect of laws pertaining to usury or such other laws, all sums paid or agreed to be paid to the holder hereof for the use, forbearance or detention of the Indebtedness of the Borrowers evidenced hereby, outstanding from time to time shall, to the extent permitted by Applicable Law, be amortized, pro-rated, allocated and spread from the date of disbursement of the proceeds of the Loans until payment in full of all of such Indebtedness, so that the actual rate of interest on account of such Indebtedness is uniform through the term hereof. The terms and provisions of this Section 11.20(a) shall control and supersede every other provision of all agreements between the Borrowers or any endorser of the Loans and the Lenders.
Minimum Amount of Each Borrowing; Maximum Number of Borrowings The aggregate principal amount of each Borrowing of Loans shall be in a multiple of $100,000 and shall not be less than the Minimum Borrowing Amount. More than one Borrowing may occur on any date; provided that at no time shall there be outstanding more than four (4) Borrowings of LIBOR Loans under this Agreement.
Maximum Advance Amount The amount of an Advance requested by the Company shall not exceed the Maximum Advance Amount. In addition, in no event shall the number of shares issuable to the Investor pursuant to an Advance cause the aggregate number of shares of Common Stock beneficially owned by the Investor and its affiliates to exceed nine and 9/10 percent (9.9%) of the then outstanding Common Stock of the Company. For the purposes of this section beneficial ownership shall be calculated in accordance with Section 13(d) of the Exchange Act.
Maximum Loan Amount “Maximum Loan Amount” has the meaning set forth in Section 2.1(a).
Minimum Amounts and Maximum Number of Eurodollar Tranches Notwithstanding anything to the contrary in this Agreement, all borrowings, conversions, continuations and optional prepayments of Eurodollar Loans hereunder and all selections of Interest Periods hereunder shall be in such amounts and be made pursuant to such elections so that, (a) after giving effect thereto, the aggregate principal amount of the Eurodollar Loans comprising each Eurodollar Tranche shall be equal to $5,000,000 or a whole multiple of $1,000,000 in excess thereof and (b) no more than ten Eurodollar Tranches shall be outstanding at any one time.
Liquidated Damages The Company’s obligations to pay any partial liquidated damages or other amounts owing under the Transaction Documents is a continuing obligation of the Company and shall not terminate until all unpaid partial liquidated damages and other amounts have been paid notwithstanding the fact that the instrument or security pursuant to which such partial liquidated damages or other amounts are due and payable shall have been canceled.
Obligation Absolute; Partial Liquidated Damages The Company’s obligations to issue and deliver the Conversion Shares upon conversion of this Debenture in accordance with the terms hereof are absolute and unconditional, irrespective of any action or inaction by the Holder to enforce the same, any waiver or consent with respect to any provision hereof, the recovery of any judgment against any Person or any action to enforce the same, or any setoff, counterclaim, recoupment, limitation or termination, or any breach or alleged breach by the Holder or any other Person of any obligation to the Company or any violation or alleged violation of law by the Holder or any other Person, and irrespective of any other circumstance which might otherwise limit such obligation of the Company to the Holder in connection with the issuance of such Conversion Shares; provided, however, that such delivery shall not operate as a waiver by the Company of any such action the Company may have against the Holder. In the event the Holder of this Debenture shall elect to convert any or all of the outstanding principal amount hereof, the Company may not refuse conversion based on any claim that the Holder or anyone associated or affiliated with the Holder has been engaged in any violation of law, agreement or for any other reason, unless an injunction from a court, on notice to Holder, restraining and or enjoining conversion of all or part of this Debenture shall have been sought and obtained, and the Company posts a surety bond for the benefit of the Holder in the amount of 150% of the outstanding principal amount of this Debenture, which is subject to the injunction, which bond shall remain in effect until the completion of arbitration/litigation of the underlying dispute and the proceeds of which shall be payable to the Holder to the extent it obtains judgment. In the absence of such injunction, the Company shall issue Conversion Shares or, if applicable, cash, upon a properly noticed conversion. If the Company fails for any reason to deliver to the Holder such Conversion Shares pursuant to Section 4(c)(ii) by the Share Delivery Date, the Company shall pay to the Holder, in cash, as liquidated damages and not as a penalty, for each $1,000 of principal amount being converted, $10 per Trading Day (increasing to $20 per Trading Day on the fifth (5th) Trading Day after such liquidated damages begin to accrue) for each Trading Day after such Share Delivery Date until such Conversion Shares are delivered or Holder rescinds such conversion. Nothing herein shall limit a Hxxxxx’s right to pursue actual damages or declare an Event of Default pursuant to Section 8 hereof for the Company’s failure to deliver Conversion Shares within the period specified herein and the Holder shall have the right to pursue all remedies available to it hereunder, at law or in equity including, without limitation, a decree of specific performance and/or injunctive relief. The exercise of any such rights shall not prohibit the Holder from seeking to enforce damages pursuant to any other Section hereof or under applicable law.
Minimum Amount of Each Borrowing The aggregate principal amount of each Borrowing of Loans shall not be less than the Minimum Borrowing Amount. More than one Borrowing may occur on the same date, but at no time shall there be outstanding more than 15 Borrowings of Euro Rate Loans.
