Construction of Terms If any provision of this Agreement is held unenforceable by a court of competent jurisdiction, that provision shall be severed and shall not affect the validity or enforceability of the remaining provisions.
ALTERATION OF TERMS 17 A. This Agreement, together with Exhibits A, B, and C attached hereto and incorporated herein, 18 fully expresses the complete understanding of COUNTY and CONTRACTOR with respect to the 19 subject matter of this Agreement. 20 B. Unless otherwise expressly stated in this Agreement, no addition to, or alteration of the terms of 21 this Agreement or any Exhibits, whether written or verbal, made by the parties, their officers, employees 22 or agents shall be valid unless made in the form of a written amendment to this Agreement, which has 23 been formally approved and executed by both parties. 24
No Construction as Employment Agreement Nothing contained in this Agreement shall be construed as giving Indemnitee any right to be retained in the employ of the Company or any of its subsidiaries.
Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE 1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State. 1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent. 1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State. 1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress. 1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER. 1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period. 1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State. 1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work. 1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon. 1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval. 1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6. 1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover. 1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions. 1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment. 1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.
Interpretation of Terms In the provisions herein contained attaching to the Series 7 Preferred Limited Partnership Units:
Application of Terms Grantee shall advise any sub-grantee of funds awarded through this Agreement of the requirements imposed on them by federal and state laws and regulations, and the provisions of this Agreement. The terms of this Agreement shall apply to all subawards authorized in accordance with Paragraph 17.1. 2 CFR 200.101(b)(2).
Duration and Termination of this Agreement This Agreement shall remain in force until March 1, 1998, and continue in force from year to year thereafter, but only so long as such continuance is specifically approved at least annually (a) by the vote of a majority of the Trustees who are not parties to this Agreement or interested persons of any party to this Agreement, cast in person at a meeting called for the purpose of voting on such approval, and (b) by the Trustees of the Trust, or by the vote of a majority of the outstanding voting securities of the Fund. The aforesaid requirement that continuance of this Agreement be "specifically approved at least annually" shall be construed in a manner consistent with the 1940 Act and the rules and regulations thereunder and any applicable SEC exemptive order therefrom. This Agreement may be terminated with respect to the Fund at any time, without the payment of any penalty, by the vote of a majority of the outstanding voting securities of the Fund or by the Trust's Board of Trustees on 60 days' written notice to you, or by you on 60 days' written notice to the Trust. This Agreement shall terminate automatically in the event of its assignment. This Agreement may be terminated with respect to the Fund at any time without the payment of any penalty by the Board of Trustees or by vote of a majority of the outstanding voting securities of the Fund in the event that it shall have been established by a court of competent jurisdiction that you or any of your officers or directors has taken any action which results in a breach of your covenants set forth herein.
Term and Termination of this Agreement The term of employment of -------------------------------------- Executive (the "Term") pursuant to this Agreement shall commence on the date hereof and shall continue for a term of five (5) years from the date hereof (the "Term"). (a) Executive's employment hereunder shall be terminated during the Term upon the death or Disability of Executive. (b) Executive's employment hereunder may be terminated during the Term by the Company (i) with Cause at any time, and (ii) without Cause upon thirty (30) days written notice to Executive, provided that Executive shall immediately cease the performance of his duties hereunder if the Company shall so request following the date of such notice. In the event Executive's employment is terminated without Cause, the Company shall pay to Executive, as severance pay hereunder, an amount equal to the annual Base Salary paid to Executive at the Effective Date of Termination, which amount shall be paid in twelve (12) substantially equal monthly installments (less such deductions and withholdings as are required by law or the policies of the Company) commencing with the first day of the calendar month next following. (c) Upon termination of Executive's employment hereunder pursuant to subsection 4(a) or for Cause pursuant to subsection 4(b), or upon voluntary termination by Executive of Executive's employment hereunder, the Company shall have no further obligation to Executive or his personal representative with respect to remuneration due under this Agreement, except for Base Salary earned but unpaid at the Effective Date of Termination and, in the case of termination of employment under subsection 4(a), a pro rata portion (based on the number of days of the fiscal year of the Company in which such termination occurred during which this Agreement was in effect) of the bonus, if any, payable under Section 3(b) with respect to such fiscal year. Payment of such bonus, if any, shall be made at such time as similar bonuses are paid to other executives of the Company with respect to such fiscal year. (d) If Executive's employment hereunder is terminated during the Term by the Company without Cause pursuant to subsection 4(b), the Company shall have no obligation to Employee with respect to renumeration due under this Agreement or such termination other than (i) Base Salary earned but unpaid at the Effective Date of Termination, and (ii) a pro rata portion (based on the number of days of the fiscal year of the Company in which the Effective Date of Termination occurred during which this Agreement was in effect) of the bonus, if any, payable under Section 3(b) with respect to such fiscal year, and (iii) the severance pay described in subsection 4(b). Payment pursuant to clause (ii) of the preceding sentence shall be made when such bonuses are paid to other executive officers receiving bonus payments with respect to such fiscal year. (e) Notwithstanding anything to the contrary expressed or implied herein, the covenants and agreements of Executive in Sections 5 and 6 of this Agreement shall survive the termination of Executive's employment hereunder.
TERM AND TERMINATION OF THIS AGREEMENT; NO ASSIGNMENT (a) This Agreement shall go into effect as to the Fund on the date set forth above and shall, unless terminated as hereinafter provided, continue in effect for a period of two years from the date of approval by shareholders of the Fund at a meeting called for the purpose of such approval. This Agreement shall continue in effect thereafter for additional periods not exceeding one (l) year so long as such continuation is approved for the Fund at least annually by (i) the Board of Trustees of the Trust or by the vote of a majority of the outstanding voting securities of the Fund and (ii) the vote of a majority of the Trustees of the Trust who are not parties to this Agreement nor interested persons thereof, cast in person at a meeting called for the purpose of voting on such approval. The terms “majority of the outstanding voting securities” and “interested persons” shall have the meanings as set forth in the 1940 Act; (b) This Agreement may be terminated by the Trust on behalf of the Fund at any time without payment of any penalty, by the Board of Trustees of the Trust, by the Manager, or by vote of a majority of the outstanding voting securities of a Fund without the payment of any penalties, upon sixty (60) days’ written notice to the Sub-Adviser, and by the Sub-Adviser upon sixty (60) days’ written notice to the Fund and the Manager. In the event of a termination, the Sub-Adviser shall cooperate in the orderly transfer of the Fund’s affairs and, at the request of the Board of Trustees or the Manager, transfer any and all books and records of the Fund maintained by the Sub-Adviser on behalf of the Fund; and (c) This Agreement shall terminate automatically in the event of any transfer or assignment thereof, as defined in the 1940 Act. This Agreement will also terminate in the event that the Management Agreement is terminated.
Termination of the Contract 1. The Contractor may terminate the contract if the Partner has inadequately discharged or failed to discharge any of the contractual obligations, insofar as this is not due to force majeure, after notification of the Partner by registered letter has remained without effect for one month. 2. The Partner shall immediately notify the Contractor, supplying all relevant information, of any event likely to prejudice the performance of this contract.
