Project Implementation The Borrower shall:
Project Implementation Manual The Recipient, through the PCU, shall: (i) take all action required to carry out Parts 1.1, 1.3, 1.4, 2, 3.1(b), 3.2, 3.3 and 4 (ii) of the Project in accordance with the provisions and requirements set forth or referred to in the Project Implementation Manual; (ii) submit recommendations to the Association for its consideration for changes and updates of the Project Implementation Manual as they may become necessary or advisable during Project implementation in order to achieve the objective of Parts 1.1, 1.3, 1.4, 2, 3.1(b), 3.2, 3.3 and 4(ii) of the Project; and (iii) not assign, amend, abrogate or waive the Project Implementation Manual or any of its provisions without the Association’s prior agreement. Notwithstanding the foregoing, if any of the provisions of the Project Implementation Manual is inconsistent with the provisions of this Agreement, the provisions of this Agreement shall prevail and govern.
COOPERATION IN IMPLEMENTATION On demand of the other Spouse and without undue delay or expense, each Spouse shall execute, acknowledge, or deliver any instrument, furnish any information, or perform any other acts reasonably necessary to carry out the provisions of this Agreement. If a Spouse fails to execute any document as required by this provision, the court may appoint the court clerk or his or her authorized designee to execute the document on that Xxxxxx’s behalf.
Implementation Services Vendor shall provide the Implementation Services, if any, described in Exhibit A. The Services Fees for any Implementation Services shall be described in Exhibit A.
Operation and Maintenance Manuals Receipts for transmittal of Operation and Maintenance Manuals, Brochures and Data to the Design Professional (or Commissioning Agent) as required by Section 6.1.1.5.
Implementation Plan The Authority shall cause to be prepared an Implementation Plan meeting the requirements of Public Utilities Code Section 366.2 and any applicable Public Utilities Commission regulations as soon after the Effective Date as reasonably practicable. The Implementation Plan shall not be filed with the Public Utilities Commission until it is approved by the Board in the manner provided by Section 4.9.
Construction Progress Schedule A schedule indicating proposed activity sequences and durations, milestone dates for receipt and approval of pertinent information, preparation, submittal, and processing of Shop Drawings and Samples, delivery of materials or equipment requiring long-lead time procurement, and proposed date(s) of Material Completion and Occupancy and Final Completion. The schedule will be developed to represent the sixteen or seventeen CSI Specification Divisions. It shall have a minimum number of activities as required to adequately represent to Owner the complete scope of work and define the Project’s critical path and associated activities. If the Project is to be phased, then each individual Phase should be identified from start through completion of the overall Project and should be individually scheduled and described, including any Owner’s occupancy requirements and showing portions of the Project having occupancy priority. The format of the schedule will have dependencies indicated on a monthly grid identifying milestone dates such as construction start, phase construction, structural top out, dry-in, rough-in completion, metal stud and drywall completion, equipment installation, systems operational, Material Completion and Occupancy Date, final inspection dates, Punchlist, and Final Completion date.
Access Toll Connecting Trunk Group Architecture 9.2.1 If CSTC chooses to subtend a Verizon access Tandem, CSTC’s NPA/NXX must be assigned by CSTC to subtend the same Verizon access Tandem that a Verizon NPA/NXX serving the same Rate Center Area subtends as identified in the LERG.
9.2.2 CSTC shall establish Access Toll Connecting Trunks pursuant to applicable access Tariffs by which it will provide Switched Exchange Access Services to Interexchange Carriers to enable such Interexchange Carriers to originate and terminate traffic to and from CSTC’s Customers.
9.2.3 The Access Toll Connecting Trunks shall be two-way trunks. Such trunks shall connect the End Office CSTC utilizes to provide Telephone Exchange Service and Switched Exchange Access to its Customers in a given LATA to the access Tandem(s) Verizon utilizes to provide Exchange Access in such LATA.
9.2.4 Access Toll Connecting Trunks shall be used solely for the transmission and routing of Exchange Access to allow CSTC’s Customers to connect to or be connected to the interexchange trunks of any Interexchange Carrier which is connected to a Verizon access Tandem.
Operational All expenses for running and operating all machinery, equipments and installations comprised in the Common Areas, including elevators, diesel generator set, changeover switch, pump and other common installations including their license fees, taxes and other levies (if any) and expenses ancillary or incidental thereto and the lights of the Common Areas and the road network.
SERVICE MONITORING, ANALYSES AND ORACLE SOFTWARE 11.1 We continuously monitor the Services to facilitate Oracle’s operation of the Services; to help resolve Your service requests; to detect and address threats to the functionality, security, integrity, and availability of the Services as well as any content, data, or applications in the Services; and to detect and address illegal acts or violations of the Acceptable Use Policy. Oracle monitoring tools do not collect or store any of Your Content residing in the Services, except as needed for such purposes. Oracle does not monitor, and does not address issues with, non-Oracle software provided by You or any of Your Users that is stored in, or run on or through, the Services. Information collected by Oracle monitoring tools (excluding Your Content) may also be used to assist in managing Oracle’s product and service portfolio, to help Oracle address deficiencies in its product and service offerings, and for license management purposes.
11.2 We may (i) compile statistical and other information related to the performance, operation and use of the Services, and (ii) use data from the Services in aggregated form for security and operations management, to create statistical analyses, and for research and development purposes (clauses i and ii are collectively referred to as “Service Analyses”). We may make Service Analyses publicly available; however, Service Analyses will not incorporate Your Content, Personal Data or Confidential Information in a form that could serve to identify You or any individual. We retain all intellectual property rights in Service Analyses.
11.3 We may provide You with the ability to obtain certain Oracle Software (as defined below) for use with the Services. If we provide Oracle Software to You and do not specify separate terms for such software, then such Oracle Software is provided as part of the Services and You have the non-exclusive, worldwide, limited right to use such Oracle Software, subject to the terms of this Agreement and Your order (except for separately licensed elements of the Oracle Software, which separately licensed elements are governed by the applicable separate terms), solely to facilitate Your use of the Services. You may allow Your Users to use the Oracle Software for this purpose, and You are responsible for their compliance with the license terms. Your right to use any Oracle Software will terminate upon the earlier of our notice (by web posting or otherwise) or the end of the Services associated with the Oracle Software. Notwithstanding the foregoing, if Oracle Software is licensed to You under separate terms, then Your use of such software is governed by the separate terms. Your right to use any part of the Oracle Software that is licensed under the separate terms is not restricted in any way by this Agreement.
