Mobilisation Delivery Redelivery Demobilisation and Purchase Option
Mobilisation Delivery Redelivery Demobilisation and Purchase Option Sample Clauses
Related to Mobilisation Delivery Redelivery Demobilisation and Purchase Option
Shipping must be Freight On Board Destination to the delivery location designated on the Customer purchase order The Contractor will retain title and control of all goods until delivery is completed and the Customer has accepted the delivery. All risk of transportation and all related charges are the responsibility of the Contractor. The Customer will notify the Contractor and H-GAC promptly of any damaged goods and will assist the Contractor in arranging for inspection. The Contractor must file all claims for visible or concealed damage. Unless otherwise stated in the Agreement, deliveries must consist only of new and unused merchandise.
SPECIAL DELIVERY INSTRUCTIONS All shipments will be FOB destination (as specified on Ordering Entity Purchase Order).
Notification of Delivery Destination Prior to final acceptance of contract requirements by STATE, PURCHASER shall notify STATE, in a form and manner prescribed by STATE, of the delivery destination of all timber purchased under this contract. STATE may hold PURCHASER's performance bond until satisfactory delivery destination information has been received. Notice of Transfer of State Timber. Prior to selling, trading, exchanging, or otherwise conveying unprocessed timber sold under this contract to any other person, PURCHASER must first obtain a certification of the person's eligibility to purchase unprocessed State timber, and their intent to comply with the terms and conditions contained in OAR 629-031-0005 through 629-031-0045. The certification shall be made in a form and manner prescribed by STATE, and shall be forwarded to STATE upon completion of the transaction. Obtaining the certification shall not relieve PURCHASER of the responsibility to provide STATE with an accounting of the delivery destination of that timber.
DELIVERY: FOB DESTINATION, INSIDE DELIVERY, FREIGHT PAID Whenever possible, contractors should give the ordering entities 3 working days prior notice of any deliveries and/or installations. Furniture contractors will not be responsible for the removal/moving of existing furnishings unless requested by the ordering entity. Contractors should verify site readiness prior to delivery. All deliveries will be made during normal working hours unless otherwise arranged with the ordering entity. Contractor will communicate any scheduling delays and/or changes immediately. Agencies will not be responsible for any freight damage, concealed or otherwise.
Delivery Date Warranties begin on the date of delivery, or on the date of installation if installed by us. If you schedule or delay such installation by us more than thirty (30) days after delivery, your warranty period will begin on the 31st day after delivery.
PRODUCT DELIVERY Delivery must be made as ordered to the address specified on the Purchase Order and in accordance with the terms of the Contract or Contract Award Notice. Unless otherwise specified in the Bid Documents, delivery shall be made within thirty calendar days after receipt of a Purchase Order by the Contractor. The decision of the Commissioner as to compliance with delivery terms shall be final. The burden of proof for delay in receipt of Purchase Order shall rest with the Contractor. In all instances of a potential or actual delay in delivery, the Contractor shall immediately notify the Commissioner and the Authorized User, and confirm in writing the explanation of the delay, and take appropriate action to avoid any subsequent late deliveries. Any extension of time for delivery must be requested in writing by the Contractor and approved in writing by the Authorized User. Failure to meet such delivery time schedule may be grounds for cancellation of the order or, in the Commissioner’s discretion, the Contract.
Delivery to Escrow Agent You may tender your escrow securities to a person or company in a business combination. At least five business days prior to the date the escrow securities must be tendered under the business combination, you must deliver to the Escrow Agent:
Harvest Share Use Section 7.2 is administrative except to the extent that it applies to the 17 Sector managers ability to impose and utilize legal means to recover Liquated damages as 18 authorized in section §10.10 of this agreement, in which case NMFS enforcement procedures 19 may apply.
Delivery Location All Goods shall be delivered to the address specified in this Order (the "Delivery Location") during Buyer's normal business hours or as otherwise instructed by Buyer.
Sale and Purchase Upon the basis of the representations and warranties and subject to the terms and conditions herein set forth, the Company agrees to issue and sell Ordinary Shares in the form of Firm ADSs, and each of the Selling Securityholders agrees to sell, in each case severally and not jointly, to the respective Underwriters and each of the Underwriters, severally and not jointly, agrees to purchase the number of Firm ADSs set forth opposite the name of such Underwriter in Schedule A attached hereto, subject to adjustment in accordance with Section 11 hereof, in each case at a purchase price of $[ ] per Firm ADS. The Company and the Selling Securityholders are advised by you that the Underwriters intend (i) to make a public offering of their respective portions of the Firm ADSs as soon after the effective date of the Registration Statement as in your judgment is advisable and (ii) initially to offer the Firm ADSs upon the terms set forth in the Prospectus. You may from time to time increase or decrease the public offering price after the initial public offering to such extent as you may determine. In addition, the Company and the Selling Securityholders, in each case severally and not jointly, hereby grant to the several Underwriters the option (the “Over-Allotment Option”) to purchase, and upon the basis of the representations and warranties and subject to the terms and conditions herein set forth, the Underwriters shall have the right to purchase, severally and not jointly, from the Company Ordinary Shares in the form of Firm ADSs and the Selling Securityholders Firm ADSs, ratably in accordance with the number of Firm ADSs to be purchased by each of them, all or a portion of the Additional ADSs as may be necessary to cover over-allotments made in connection with the offering of the Firm ADSs, at the same purchase price per share to be paid by the Underwriters to the Company and the Selling Securityholders for the Firm ADSs. The Over-Allotment Option may be exercised by the Representatives on behalf of the several Underwriters at any time and from time to time on or before the thirtieth day following the date of the Prospectus, by written notice to the Company and the Selling Securityholders. Such notice shall set forth the aggregate number of Additional ADSs as to which the Over-Allotment Option is being exercised and the date and time when the Additional ADSs are to be delivered (any such date and time being herein referred to as an “additional time of purchase”); provided, however, that no additional time of purchase shall be earlier than the “time of purchase” (as defined below) nor earlier than the second business day after the date on which the Over-Allotment Option shall have been exercised nor later than the tenth business day after the date on which the Over-Allotment Option shall have been exercised. The number of Additional ADSs to be sold to each Underwriter shall be the number which bears the same proportion to the aggregate number of Additional ADSs being purchased as the number of Firm ADSs set forth opposite the name of such Underwriter on Schedule A hereto bears to the total number of Firm ADSs (subject, in each case, to such adjustment as the Representatives may determine to eliminate fractional ADSs), subject to adjustment in accordance with Section 11 hereof. [Upon any exercise of the Over-Allotment Option, the number of Additional ADSs to be purchased from the Company shall be the number which bears the same proportion to the aggregate number of Additional ADSs being purchased as [# of company Additional ADSs] bears to [# of Additional ADSs], and the number of Additional ADSs to be purchased from each Selling Securityholder shall be the number which bears the same proportion to the aggregate number of Additional ADSs being purchased as the number of Additional ADSs set forth opposite the name of such Selling Securityholder in Schedule C annexed hereto bears to [# of Additional ADSs], subject, in each case, to such adjustment as the Representatives may determine solely to eliminate fractional ADSs.] [To be updated depending on over-allotment allocation.] Pursuant to powers of attorney (the “Powers of Attorney”) granted by each Selling Securityholder (which Powers of Attorney shall be satisfactory to the Representatives), [ ] and [ ] shall act as representatives of the Selling Securityholders. Each of the foregoing representatives (collectively, the “Representatives of the Selling Securityholders”) is authorized, on behalf of each Selling Securityholder, among other things, to execute any documents necessary or desirable in connection with the sale of the Offered ADSs to be sold hereunder by such Selling Securityholder, to make delivery of the certificates of such Offered ADSs, to receive the proceeds of the sale of such Offered ADSs, to give receipts for such proceeds, to pay therefrom the expenses to be borne by such Selling Securityholder in connection with the sale and public offering of the Offered ADSs, to distribute the balance of such proceeds to such Selling Securityholder, to receive notices on behalf of such Selling Securityholder and to take such other action as may be necessary or desirable in connection with the transactions contemplated by this Agreement.
