Monitoring Management and Construction Management Agreements. General Partner shall monitor and supervise Manager's activities under or in connection with the Construction Management Agreement and the Management Agreement.
Monitoring Management and Construction Management Agreements Sample Clauses
Related to Monitoring Management and Construction Management Agreements
Construction Management Landlord or its Affiliate or agent shall supervise the Work, make disbursements required to be made to the contractor, and act as a liaison between the contractor and Tenant and coordinate the relationship between the Work, the Building and the Building’s Systems. In consideration for Landlord’s construction supervision services, Tenant shall pay to Landlord a construction supervision fee equal to three percent (3%) of Tenant’s Costs specified in Section 7.
Management and Control Systems Grantee will: 1. maintain an appropriate contract administration system to ensure that all terms, conditions, and specifications are met during the term of the contract through the completion of the closeout procedures. 2. develop, implement, and maintain financial management and control systems that meet or exceed the requirements of Uniform Statewide Accounting System (UGMS). Those requirements and procedures include, at a minimum, the following: i. Financial planning, including the development of budgets that adequately reflect all functions and resources necessary to carry out authorized activities and the adequate determination of costs; ii. Financial management systems that include accurate accounting records that are accessible and identify the source and application of funds provided under each Contract of this Contract, and original source documentation substantiating that costs are specifically and solely allocable to a Contract and its Contract and are traceable from the transaction to the general ledger; iii. Effective internal and budgetary controls; iv. Comparison of actual costs to budget; determination of reasonableness, allowableness, and allocability of costs; v. Timely and appropriate audits and resolution of any findings; vi. Billing and collection policies; and vii. Mechanism capable of billing and making reasonable efforts to collect from clients and third parties.
Property Management Agreement The Property Management Agreement is in full force and effect and, to Borrower's Knowledge, there are no defaults thereunder by any party thereto and no event has occurred that, with the passage of time and/or the giving of notice would constitute a default thereunder.
Construction Management Services a. A-E may be required to review and recommend approval of submittals, shop drawings, Request for Information (RFI) and/or calculations for temporary structures such as trench shoring, false work and other temporary structural forms. b. A-E may be required to review and advise the County Representative on the overall project schedule, including staging and completion dates, duration, milestones, and interfaces. Immediately notify Representative if the proposed work schedule does not conform to the contract documents, including the plans, specifications, and permits or that may require special inspection or testing, or work stoppage. c. Review on a monthly basis the project schedule and/or Critical Path Method (CPM) schedule submitted by the Construction Contractor. Make recommendations concerning the Construction Contractor’s adherence thereto. Recommend possible solutions to scheduling problems so as to complete the project on time, within budget, and in accordance with the contract drawings and specifications. d. Review scope of work and identify potential contract change orders. Prepare independent cost estimates for any changes resulting from design revisions or change in field conditions. Prepare and recommend for approval all contract change orders. e. Evaluate the merit of any potential claims or requests for equitable adjustment submitted by the Construction Contractor. Prepare analysis of potential claims include recommendations regarding settlement of the claims. f. Assist County staff in project related issues with other Agencies, or departments, engineering and material testing support firms, CEQA consultants, utilities agencies, etc. g. Assist in community outreach meetings and media relations h. Review for acceptance/approval of Storm Water Pollution Prevention Plan (SWPPP) in accordance with the general Permit of Discharges of Storm Water Associated with Construction Activity (Construction General Permit, including dewatering/diversion plans per the State’s DeMinimus Permit).
Construction Management Plan Contractor shall prepare and furnish to the Owner a thorough and complete plan for the management of the Project from issuance of the Proceed Order through the issuance of the Design Professional's Certificate of Material Completion. Such plan shall include, without limitation, an estimate of the manpower requirements for each trade and the anticipated availability of such manpower, a schedule prepared using the critical path method that will amplify and support the schedule required in Article 2.1.5 below, and the Submittal Schedule as required in Article 2.2.3. The Contractor shall include in his plan the names and resumés of the Project Superintendent, Project Manager and the person in charge of Safety.
Project Management Project Management Institute (PMI) certified project manager executing any or all of the following: • Development of Project Charter • Development of project plan and schedule • Coordination and scheduling of project activities across customer and functional areas • Consultation on operational and infrastructure requirements, standards and configurations • Facilitate project status meetings • Timely project status reporting • Address project issues with functional areas and management • Escalation of significant issues to customers and executive management • Manage project scope and deliverable requirements • Document changes to project scope and schedule • Facilitate and document project closeout
Project Management and Coordination The Engineer shall coordinate all subconsultant activity to include quality of and consistency of work and administration of the invoices and monthly progress reports. The Engineer shall coordinate with necessary local entities.
Management and Control (a) Management and control of the business of the Fund shall be vested in the Board, which shall have the right, power, and authority, on behalf of the Fund and in its name, to exercise all rights, powers, and authority of managers under the Delaware Act and to do all things necessary and proper to carry out the objective and business of the Fund and their duties hereunder. No Manager shall have the authority individually to act on behalf of or to bind the Fund except within the scope of such Manager's authority as delegated by the Board. The parties hereto intend that, except to the extent otherwise expressly provided herein, (i) each Manager shall be vested with the same powers, authority, and responsibilities on behalf of the Fund as are customarily vested in each director of a Delaware corporation and (ii) each Independent Manager shall be vested with the same powers, authority and responsibilities on behalf of the Fund as are customarily vested in each director of a closed-end Management investment company registered under the 1940 Act that is organized as a Delaware corporation who is not an "interested person" of such company, as such term is defined by the 1940 Act. During any period in which the Fund shall have no Managers, CSFB Alternative Capital, as the initial Member, shall have the authority to manage the business and affairs of the Fund. (b) Members, in their capacity as Members, shall have no right to participate in and shall take no part in the management or control of the Fund's business and shall have no right, power or authority to act for or bind the Fund. Members shall have the right to vote on any matters only as provided in this Agreement or on any matters that require the approval of the holders of voting securities under the 1940 Act or as otherwise required in the Delaware Act. (c) The Board may delegate to any other person any rights, power and authority vested by this Agreement in the Board to the extent permissible under applicable law, and may appoint persons to serve as officers of the Fund, with such titles and authority as may be determined by the Board consistent with applicable law. (d) The Board shall have full power and authority to adopt By-Laws providing for the conduct of the business of the Fund and containing such other provisions as they deem necessary, appropriate or desirable, and, subject to the voting powers of one or more Classes created pursuant to this section 3.1, to amend and repeal such By-Laws. Unless the By-Laws specifically require that Members authorize or approve the amendment or repeal of a particular provision of the By-Laws, any provision of the By-Laws may be amended or repealed by the Board without Member authorization or approval. (e) The Board shall have the full power and authority, without Member approval, to authorize one or more Classes of Units; Units of each such Class having such preferences, voting powers and special or relative rights or privileges (including conversion rights, if any) as the Board may determine and as shall be set forth in a resolution adopted in accordance with the By-Laws.
Interconnection Facilities Engineering Procurement and Construction Interconnection Facilities, Network Upgrades, and Distribution Upgrades shall be studied, designed, and constructed pursuant to Good Utility Practice. Such studies, design and construction shall be based on the assumed accuracy and completeness of all technical information received by the Participating TO and the CAISO from the Interconnection Customer associated with interconnecting the Large Generating Facility.
Construction Phase - Administration of the Construction Contract INDICATE IN STATEMENT OF WORK “NOT APPLICABLE” IF SECTION IS NOT APPLICABLE 1.1.9.1. The Construction Phase will commence with the award of the Construction Contract to a selected vendor (“Contractor”) and will terminate when final payment is made by the State to the Contractor. In any event, the construction phase will not extend 60 days beyond the substantial completion date unless extended by change order. If such extension occurs, additional costs due to the ARCHITECT/ENGINEER shall be negotiated with the State. 1.1.9.2. The ARCHITECT/ENGINEER shall work with the State during the construction of the Project to provide the administration of the contract between the State and the Contractor in accordance with the terms herein and consistent with the contract between the State and the Contractor, and the extent of his/her duties and responsibilities and the limitations of his/her authority as assigned therein shall not be modified without his/her written consent. 1.1.9.3. The ARCHITECT/ENGINEER shall advise and consult with the State, and all of the State's instructions to the Contractor shall be issued through the ARCHITECT/ENGINEER after authorization by the State. 1.1.9.4. The ARCHITECT/ENGINEER shall, at all times, have access to the work wherever it is in preparation or progress. 1.1.9.5. The ARCHITECT/ENGINEER shall make periodic visits to the Project site, at least biweekly, and shall make such further visits when reasonably requested by the State, as to familiarize himself/herself with the progress and quality of the work performed and as to determine, on the basis of such visits, if such progress and quality are in accordance with the Contract Documents. The ARCHITECT/ENGINEER shall be responsible for project meeting minutes. In addition to this, the ARCHITECT/ENGINEER shall periodically report his/her findings thereon to the State, at such times as in the exercise of his/her professional judgment such findings are appropriate and at least monthly, at the conference provided for in Section 1.1.9.6, and further at such times as the State may reasonably request. The ARCHITECT/ENGINEER shall not be required to make exhaustive or continuous on-site inspections, except as required in the exercise of his/her professional judgment for said reports and, except in particular, to fulfill the commissioning requirements. The ARCHITECT/ENGINEER shall not be responsible for construction means, methods, techniques, sequences or procedures or for safety precautions and programs in connection with the work, and he/she shall not be responsible for the Contractor's failure to carry out the work in accordance with the Contract Documents except as provided for herein specifically between the State and the ARCHITECT/ENGINEER. 1.1.9.6. In preparing the bid documents, to the extent that the ARCHITECT/ENGINEER utilizes sub- consultants for their expertise, such as, but not limited to: Landscape Architects, Civil, Structural, Mechanical, and Electrical Engineers, these consultants, in effect, become an extension of the ARCHITECT/ENGINEER. Where the term ARCHITECT/ENGINEER is used in Section 1.1.9.2 as well as 1.1.9.5, it shall include those sub-consultants when work is being performed in their area of expertise. For example, the Mechanical Engineer would inspect the under slab plumbing before it is backfilled, but then wouldn’t necessarily be needed on site until the rest of the mechanical systems are being installed. The sub-consultant shall also be required to periodically inspect the progress of the “As-builts” and verify that they are up-to-date and verify such to the ARCHITECT/ENGINEER, before the ARCHITECT/ENGINEER issues the certificate of payment for that pay period. 1.1.9.7. Based upon his/her determinations and reports made under Section 1.1.9.5 of this Agreement and upon the Contractor's applications for payment, the ARCHITECT/ENGINEER shall once every month, after an on-site conference between the State, the Contractor and the ARCHITECT/ENGINEER, determine the amount then owing to the Contractor and shall then issue a certificate of payment for the amount agreed upon. The issuance of a Certificate for Payment shall constitute a representation by the ARCHITECT/ENGINEER to the State, based on such ARCHITECT/ENGINEER'S determination and report and the data supplied to him/her by the Contractor (without affecting his/her duties defined in Section 1.1.9.5.), that the work has progressed to the point indicated; that the quality of the work is in accordance with the Contract Documents (subject to the results of any specified subsequent tests required by the Contract Documents, to immaterial and insubstantial deviations from the Contract Documents, which will be corrected prior to completion, and to any further specific qualifications stated in the Certificate for Payment); and that the Contractor is entitled to such payment in the amount certified. Provided, however, the issuance of such certificate will not affect any obligations of the Contractor to the State. By issuing a certificate for payment, the ARCHITECT/ENGINEER shall not be deemed to represent that he/she has made any examination to ascertain how and for what purpose the Contractor has used the monies paid on account of the contract sum. ARCHITECT/ENGINEER shall not accept any part of the work on behalf of the State; ARCHITECT/ENGINEER may only recommend acceptance. Final acceptance is a right reserved solely to the State. 1.1.9.8. The ARCHITECT/ENGINEER shall be, in the first instance, the interpreter of the requirements of all Construction Documents, and shall have all requisite authority relating thereto for the purposes of authorizing the Contractor to proceed or stop with any component of the project after consultation and agreement with the State. The ARCHITECT/ENGINEER shall not be liable to the State for any loss or cost incurred by the State arising from delays in the construction schedule caused by any decision made by the ARCHITECT/ENGINEER in the reasonable exercise of professional judgment either to exercise or not to exercise his/her authority to stop the Work. 1.1.9.9. The ARCHITECT/ENGINEER shall review and respond to shop drawings, samples, and other submissions of the Contractor as in conformance with the design concept and information in the Contract Documents and the designs and plans relating to the project until approved or not requiring re-submission. The ARCHITECT/ENGINEER shall also review the submittal log at construction meetings and report to the State, on a monthly basis, their findings thereon. 1.1.9.10. The ARCHITECT/ENGINEER shall prepare all change orders and supporting data for the State's approval. 1.1.9.11. The ARCHITECT/ENGINEER shall conduct inspections to determine the Dates of Substantial Completion and Final Completion and shall receive written guarantees and related documents assembled by the Contractors and shall issue a final certificate of payment in accordance with Section 1.1.9.6. 1.1.9.12. The ARCHITECT/ENGINEER shall be responsible for system commissioning in accordance with the BGS Design Guidelines and as indicated in the BGS Commissioning Guidelines. Please see the BGS website xxxx://xxx.xxxxxxx.xxx/facilities/forms . The ARCHITECT/ENGINEER shall inspect, and document, each and every system to ensure that it complies with design intent, including but not limited to: system installation, system operation, and seasonal changeover. 1.1.9.13. Except in the manner specifically provided for herein, the ARCHITECT/ENGINEER shall not be responsible to the State for the acts or omissions of the Contractor or any of the Contractor’s agents or employees, or any other person not an employee or agent of the ARCHITECT/ENGINEER performing work on the Project. The ARCHITECT/ENGINEER shall be responsible for and shall pay the amount of any increase in the total Contract Price or the total Change Order(s) Price, which increase results from an error, inconsistency, or omission in the Contract Documents or instructions. 1.1.9.14. ARCHITECT/ENGINEER shall furnish to the State, a complete set of marked-up drawings and specifications showing all the changes to the Construction Documents made by Addenda, Change Orders, Shop Drawings, RFIs and other information received from the Clerk; and General Contractor’s As-built markups. The changes to the drawings are to be created on a separate layer in the DWG set and highlighted in a box, cloud or the like in the PDF set. The specifications are also to differentiate the changes made by highlighting in a box, cloud, etc. and be provided in Microsoft Word. These drawings and specifications shall be supplied within three (3) months of the date of Substantial Completion and before final payment. 1.1.9.15. Architect/Engineer (and design team members as required) shall conduct a one-year warranty inspection of the completed construction project between the eleventh and twelfth month from the date of substantial completion and shall issue a list of defective items needing correction to the Contractor.
