Contractor’s Project Manager and Key Personnel Contractor shall appoint a Project Manager to direct the Contractor’s efforts in fulfilling Contractor’s obligations under this Contract. This Project Manager shall be subject to approval by the County and shall not be changed without the written consent of the County’s Project Manager, which consent shall not be unreasonably withheld. The Contractor’s Project Manager shall be assigned to this project for the duration of the Contract and shall diligently pursue all work and services to meet the project time lines. The County’s Project Manager shall have the right to require the removal and replacement of the Contractor’s Project Manager from providing services to the County under this Contract. The County’s Project manager shall notify the Contractor in writing of such action. The Contractor shall accomplish the removal within five (5) business days after written notice by the County’s Project Manager. The County’s Project Manager shall review and approve the appointment of the replacement for the Contractor’s Project Manager. The County is not required to provide any additional information, reason or rationale in the event it The County is not required to provide any additional information, reason or rationale in the event it requires the removal of Contractor’s Project Manager from providing further services under the Contract.
RECORDS MANAGEMENT AND MAINTENANCE CONTRACTOR, its officers, agents, employees and subcontractors shall, throughout the term 12 of this Agreement, prepare, maintain and manage records appropriate to the services provided and in 13 accordance with this Agreement and all applicable requirements.
Servicing and Maintenance Standards On behalf of the Issuer, the Servicer shall (a) manage, service, administer, bill, collect and calculate Securitized Utility Tariff Charges in accordance with the Securitization Law and post collections in respect of the Securitized Utility Tariff Property with reasonable care and in material compliance with applicable Requirements of Law, including all applicable MPSC Regulations and guidelines, using the same degree of care and diligence that the Servicer exercises with respect to similar assets for its own account and, if applicable, for others; (b) follow customary standards, policies and procedures for the industry in Missouri in performing its duties as Servicer; (c) use all reasonable efforts, consistent with its customary servicing procedures, to enforce, and maintain rights in respect of, the Securitized Utility Tariff Property and to bill and collect the Securitized Utility Tariff Charges; (d) comply with all Requirements of Law, including all applicable MPSC Regulations and guidelines, applicable to and binding on it relating to the Securitized Utility Tariff Property; (e) file all MPSC notices described in the Securitization Law and file and maintain the effectiveness of UCC financing statements with respect to the property transferred under the Sale Agreement, and (f) take such other action on behalf of the Issuer to ensure that the Lien of the Indenture Trustee on the Securitized Utility Tariff Collateral remains perfected and of first priority. The Servicer shall follow such customary and usual practices and procedures as it shall deem necessary or advisable in its servicing of all or any portion of the Securitized Utility Tariff Property, which, in the Servicer’s judgment, may include the taking of legal action, at the Issuer’s expense but subject to the priority of payments set forth in Section 8.02(e) of the Indenture.
Contractor Personnel Contractor's staff is expected to present a professional appearance. All personnel of the Contractor will be neat, well groomed, properly uniformed in industry standard uniforms and are expected to conduct themselves at all times in a responsible and courteous manner while performing any work under this Agreement and/or whenever they are on District property. The following code of conduct will be adhered to by the Contractor, his agent(s) and/or his employees. If Contractor fails to ensure that its employees or other agents comply with these requirements, then Contractor may be terminated for cause under this Agreement: A. All employees of the Contractor shall wear a recognizable uniform. No hats will be worn inside the building. All of Contractor’s employees and agents performing work must carry a government-issued photo ID. Contractor’s employees and agents will present ID to District Staff upon request. This provision will be strictly enforced. B. The use of tobacco or tobacco products on Board property is prohibited by State law. C. The Contractor will not be permitted to utilize Day Labor or Temporary Workers to provide any services at any District facility. This includes any employees or agents that are hired prior to contract award. Failure to comply with this requirement could result in immediate termination of contract with the Contractor liable for any breach, including liquidated damages for delay damages and/or forfeiture of Performance Bond. D. The Contractor or employees or agents of the Contractor are not permitted to play loud music, to make unnecessary noises, or to use vulgar or inappropriate language that causes offense to others. E. The employment of unauthorized or illegal aliens by the Contractor is considered a violation of Section 247A (e) of the Immigration and Naturalization Act. If the Contractor knowingly employs unauthorized aliens, such a violation shall also be cause for termination of this Agreement. F. Possession of firearms will not be tolerated on Board property. No person who has a firearm in their vehicle will be permitted to park on District property. Any employee of the Contractor found in violation of this policy will be immediately asked to leave, and will not be allowed to return to perform further work without the consent of the District. G. The Contractor certifies that he/she will not engage in the unlawful manufacture, sale distribution, dispensation, possession, or use of a controlled substance or drug during the performance of the contract and that a drug-free workplace will be provided for the Contractor’s employees or agents during the performance of the contract. The Contractor also certifies that he will secure from any subcontractor who works on the contract, written certification of the same drug free workplace requirements. False certification or violation by failing to carry out requirements of O.C.G.A. § 50-24-3 may cause suspension, termination of contract, or debarment of such bidder Please Note: If any employee or agent of the Contractor or Sub-contractor is found to have brought a firearm on District property, the Contractor or Sub-contractor shall prohibit them from continuing to perform any work on District property. If the Contractor or Sub-contractor fails to do so, then the District may terminate this Agreement for cause as set forth below.
Supervision of Contractor Personnel The Contractor must supply all necessary and sufficient supervision over the work that is being performed and will be held solely responsible for the conduct and performance of his employees or agents involved in work under the Agreement.
Operating and Maintenance Costs The Participating Generator shall be responsible for all its costs incurred in connection with operating and maintaining the Generating Units identified in Schedule 1 for the purpose of meeting its obligations under this Agreement.
Operations and Maintenance Seller shall not during the months of June through September inclusive schedule any non-emergency maintenance that reduces the energy generating capability of the Facility by more than ten percent (10%), unless (i) such outage is required to avoid damage to the Facility, (ii) such maintenance is necessary to maintain equipment warranties and cannot be scheduled outside the months of June through September, (iii) such outage is required in accordance with prudent electrical practices, or (iv) the Parties agree otherwise in writing.
Operation and Maintenance Manuals Receipts for transmittal of Operation and Maintenance Manuals, Brochures and Data to the Design Professional (or Commissioning Agent) as required by Section 6.1.1.5.
Records Maintenance and Access Grantee must maintain all financial records relating to this Grant in accordance with generally accepted accounting principles. In addition, Grantee must maintain any other records, whether in paper, electronic or other form, pertinent to this Grant in such a manner as to clearly document Grantee’s performance. All financial records and other records, whether in paper, electronic or other form, that are pertinent to this Grant, are collectively referred to as “Records.” Grantee acknowledges and agrees Agency and the Oregon Secretary of State's Office and the federal government and their duly authorized representatives will have access to all Records to perform examinations and audits and make excerpts and transcripts. Grantee must retain and keep accessible all Records for a minimum of six (6) years, or such longer period as may be required by applicable law, following termination of this Grant, or until the conclusion of any audit, controversy or litigation arising out of or related to this Grant, whichever date is later.
Network Maintenance and Management 38.1 The Parties will work cooperatively to implement this Agreement. The Parties will exchange appropriate information (for example, maintenance contact numbers, network information, information required to comply with law enforcement and other security agencies of the government, escalation processes, etc.) to achieve this desired result. 38.2 Each Party will administer its network to ensure acceptable service levels to all users of its network services. Service levels are generally considered acceptable only when End Users are able to establish connections with little or no delay encountered in the network. Each Party will provide a twenty four (24)-hour contact number for Network Traffic Management issues to the other’s surveillance management center. 38.3 Each Party maintains the right to implement protective network traffic management controls, such as “cancel to”, “call gapping” or seven (7)-digit and ten (10)-digit code gaps, to selectively cancel the completion of traffic over its network, including traffic destined for the other Party’s network, when required to protect the public-switched network from congestion as a result of occurrences such as facility failures, switch congestion or failure or focused overload. Each Party shall immediately notify the other Party of any protective control action planned or executed. 38.4 Where the capability exists, originating or terminating traffic reroutes may be implemented by either Party to temporarily relieve network congestion due to facility failures or abnormal calling patterns. Reroutes shall not be used to circumvent normal trunk servicing. Expansive controls shall be used only when mutually agreed to by the Parties. 38.5 The Parties shall cooperate and share pre-planning information regarding cross-network call-ins expected to generate large or focused temporary increases in call volumes to prevent or mitigate the impact of these events on the public-switched network, including any disruption or loss of service to the other Party’s End Users. Facsimile (FAX) numbers must be exchanged by the Parties to facilitate event notifications for planned mass calling events. 38.6 Neither Party shall use any Interconnection Service provided under this Agreement or any other service related thereto or used in combination therewith in any manner that interferes with or impairs service over any facilities of AT&T-21STATE, its affiliated companies or other connecting telecommunications carriers, prevents any carrier from using its Telecommunications Service, impairs the quality or the privacy of Telecommunications Service to other carriers or to either Party’s End Users, causes hazards to either Party’s personnel or the public, damage to either Party’s or any connecting carrier’s facilities or equipment, including any malfunction of ordering or billing systems or equipment. Upon such occurrence either Party may discontinue or refuse service, but only for so long as the other Party is violating this provision. Upon any such violation, either Party shall provide the other Party notice of the violation at the earliest practicable time. 38.7 AT&T TENNESSEE hereby commits to provide Disaster Recovery to CLEC according to the plan below. 38.7.1 AT&T TENNESSEE Disaster Recovery Plan 38.7.2 In the unlikely event of a disaster occurring that affects AT&T TENNESSEE’s long-term ability to deliver traffic to a CLEC, general procedures have been developed by AT&T TENNESSEE to hasten the recovery process in accordance with the Telecommunications Service Priority (TSP) Program established by the FCC to identify and prioritize telecommunication services that support national security or emergency preparedness (NS/EP) missions. A description of the TSP Program as it may be amended from time to time is available on AT&T TENNESSEE’s Wholesale – Southeast Region Web site. Since each location is different and could be affected by an assortment of potential problems, a detailed recovery plan is impractical. However, in the process of reviewing recovery activities for specific locations, some basic procedures emerge that appear to be common in most cases. 38.7.3 These general procedures should apply to any disaster that affects the delivery of traffic for an extended time period. Each CLEC will be given the same consideration during an outage, and service will be restored as quickly as possible. AT&T TENNESSEE reserves the right to make changes to these procedures as improvements become available or as business conditions dictate. 38.7.4 This plan will cover the basic recovery procedures that would apply to every CLEC.
