No Termination or Abatement Lessee shall remain obligated under this Lease in accordance with its terms and shall not take any action to terminate, rescind or avoid this Lease, notwithstanding any action for bankruptcy, insolvency, reorganization, liquidation, dissolution, or other proceeding affecting any Person or any Governmental Authority, or any action with respect to this Lease or any Operative Agreement which may be taken by any trustee, receiver or liquidator of any Person or any Governmental Authority or by any court with respect to any Person, or any Governmental Authority. Lessee hereby waives all right (a) to terminate or surrender this Lease (except as permitted under the terms of the Operative Agreements) or (b) to avail itself of any abatement, suspension, deferment, reduction, setoff, counterclaim or defense with respect to any Rent. Lessee shall remain obligated under this Lease in accordance with its terms and Lessee hereby waives any and all rights now or hereafter conferred by statute or otherwise to modify or to avoid strict compliance with its obligations under this Lease. Notwithstanding any such statute or otherwise, Lessee shall be bound by all of the terms and conditions contained in this Lease.
Termination or Abandonment Notwithstanding anything in this Agreement to the contrary, this Agreement may be terminated and abandoned at any time prior to the Effective Time, whether before or after any approval of the Merger by the stockholders of the Company:
(a) by the mutual written consent of the Company and Parent;
(b) by either Parent or the Company if the Merger shall not have been consummated on or prior to June 30, 2012 (the “End Date”), provided, however, that if all of the conditions to Closing, other than the condition set forth in Section 6.1(c), shall have been satisfied or shall be capable of being satisfied at such time, the End Date may be extended by Parent or the Company from time to time by written notice to the other party up to a date not beyond December 31, 2012, the latest of any of which dates shall thereafter be deemed to be the End Date; and provided, further, that the right to terminate this Agreement pursuant to this Section 7.1(b) shall not be available to a party if the failure of the Closing to occur by such date shall be due to the material breach by such party of any representation, warranty, covenant or other agreement of such party set forth in this Agreement;
(c) by either the Company or Parent if an injunction shall have been entered permanently restraining, enjoining or otherwise prohibiting the consummation of the Merger and such injunction shall have become final and non-appealable; provided that the party seeking to terminate this Agreement pursuant to this Section 7.1(c) shall have used its reasonable best efforts to remove such injunction to the extent such party is required to use its reasonable best efforts pursuant to this Agreement;
(d) by either the Company or Parent if the Stockholders’ Meeting (including any adjournments or postponements thereof) shall have concluded and the Company Stockholder Approval shall not have been obtained;
(e) by the Company, if Parent shall have breached or failed to perform any of its representations, warranties, covenants or other agreements contained in this Agreement, which breach or failure to perform (i) would result in a failure of a condition set forth in Section 6.1 or Section 6.2 and (ii) by its nature, cannot be cured prior to the End Date or, if by its nature such breach or failure is capable of being cured by the End Date, Parent does not diligently attempt or ceases to diligently attempt to cure such breach or failure after receiving written notice from the Company describing such breach or failure in reasonable detail (provided that the Company is not then in material breach of any representation, warranty, covenant or other agreement contained herein);
(f) by Parent, if the Company shall have breached or failed to perform any of its representations, warranties, covenants or other agreements contained in this Agreement, which breach or failure to perform (i) would result in a failure of a condition set forth in Section 6.1 or Section 6.2(f) and (ii) by its nature, cannot be cured prior to the End Date or, if by its nature such breach or failure is capable of being cured by the End Date, the Company does not diligently attempt or ceases to diligently attempt to cure such breach or failure after receiving written notice from Parent describing such breach or failure in reasonable detail (provided that Parent is not then in material breach of any representation, warranty, covenant or other agreement contained herein);
(g) by Parent, (i) prior to the Company Stockholder Approval, in the event of a Change of Recommendation or if the Board of Directors of the Company shall have approved or recommended to its shareholders an Acquisition Transaction, or (ii) the Company shall have willfully and materially breached any of its obligations under Section 5.4; and
(h) by the Company, prior to obtaining the Company Stockholder Approval and if the Company has complied with its obligations under Section 5.4, in order to enter into a definitive agreement with respect to a Superior Offer; provided that any such purported termination by the Company pursuant to this Section 7.1(h) shall be void and of no force or effect unless the Company pays to Parent the expense reimbursement in accordance with Section 7.3(a) and the Breakup Fee in accordance with Section 7.3(c).
Damage, Destruction or Condemnation (a) In the event of damage to or destruction of any portion of the Project resulting from fire or other casualty during the Term, or in the event any portion of the District is condemned or taken for any public or quasi-public use or title thereto is found to be deficient during the Term, the net proceeds of any insurance relating to such damage or destruction, the net proceeds of such condemnation or taking or the net proceeds of any realization on title insurance shall be paid into, and used in accordance with a construction escrow agreement reasonably satisfactory to the City and Developer ("Casualty Escrow").
(b) If, at any time during the Term, the Project or any part thereof shall be damaged or destroyed by a casualty (the "Damaged Facilities"), Developer, at its sole cost and expense, shall commence and thereafter proceed as promptly as possible to repair, restore and replace the Damaged Facilities as nearly as possible to their condition immediately prior to the casualty and shall be entitled to draw upon the Casualty Escrow for payment of said costs.
(c) If at any time during the Term, title to the whole or substantially all of the Project which has previously been conveyed to Developer shall be taken in condemnation proceedings or by right of eminent domain, Developer, at its sole discretion, may terminate this Agreement as of the date of such taking. For purposes of this Section 6.07(c), "substantially all of the District" shall be deemed to have been taken if the City and Developer, each acting reasonably and in good faith, determine that the untaken portion of the District, including the parking improvements, cannot be practically and economically used by Developer for the purposes and at the times contemplated by this Agreement.
(d) In the event of condemnation of less than the whole or substantially all of the District which has previously been conveyed to Developer during the Term, Developer, at its sole cost and expense, shall commence and thereafter proceed as promptly as possible to repair, restore and replace the remaining part of the Project, as nearly as possible, to its former condition, and shall be entitled to draw upon the Casualty Escrow for payment of said costs.
(e) Nothing in this section will require the Developer to expend funds in excess of the Casualty Escrow for the repair, restoration and/or replacement of the Damaged Facilities.
DAMAGE OR DESTRUCTION OF PREMISES a. In the event the Premises are damaged by fire or other perils or casualty covered by fire and extended coverage insurance, Landlord may, in its sole and absolute discretion, repair or rebuild the same within a reasonable time after the event causing such damage. This Lease shall remain in full force and effect, except that Tenant shall be entitled to a proportionate reduction of the rent from the date of damage and while such repairs are being made, such proportionate reduction to be based upon the extent to which the damage and making of such repairs shall reasonably interfere with the business carried on by Tenant in the Premises as determined by Landlord. If the damage is due to the fault or neglect of Tenant or its employees, as determined by Landlord in its sole discretion, there shall be no reduction of rent. Landlord may authorize or direct construction of an alternative structure or may elect to retain any insurance proceeds received by it if Landlord deems reconstruction or construction of an alternative structure to be impractical or unreasonable in its sole discretion.
b. In the event the Premises are damaged to any extent as a result of any cause other than the perils covered by fire and extended coverage insurance, Landlord shall in its sole discretion have the option to: (1.) to repair, reconstruct or restore the Premises within a reasonable time of the event causing the damage, in which case this Lease shall continue in full force and effect, but the rent shall be proportionately reduced as provided above in 11a. during the period of such repair, reconstruction or restoration, or (2.) to give notice to Tenant at any time within sixty (60) days after such damage occurs, terminating this Lease as of the date specified in such notice, which date shall be no more than thirty (30) days after the giving of such notice. In the event of giving to Tenant such notice of termination, this Lease shall terminate and all interests of Tenant in the Premises shall cease on the date so specified in such notice and Tenant shall pay the rent, as proportionately reduced, based upon the extent, if any, to which such damage interfered with the business carried on by Tenant in the Premises, up to the date of such termination.
c. With regard to Landlord’s duty or option to repair, reconstruct or restore the Premises within a reasonable time of the event causing the damage as provided in 11a. and b. above, Landlord shall act promptly and with due diligence, but Landlord shall not be responsible for delays caused by factors beyond Landlord’s control, including but not limited to delays because of strikes, work slowdowns or stoppages, accidents, acts of God, failure of any governmental or other authority to act in a timely manner, or delays caused by contractors. If such delays occur, Tenant agrees that Landlord shall not be responsible for damages, nor shall Landlord be deemed to be in default under this Lease.
d. Landlord shall not be required to repair any damage by fire or other casualty, or to make any repair or replacements of any leasehold improvements, fixtures, or other personal property of Tenant.
No Termination, Abatement, Etc Except as otherwise specifically provided in this Agreement, each of Landlord and Tenant, to the maximum extent permitted by law, shall remain bound by this Agreement in accordance with its terms and shall not take any action without the consent of the other to modify, surrender or terminate this Agreement. In addition, except as otherwise expressly provided in this Agreement, Tenant shall not seek, or be entitled to, any abatement, deduction, deferment or reduction of the Rent, or set-off against the Rent, nor shall the respective obligations of Landlord and Tenant be otherwise affected by reason of (a) any damage to or destruction of the Leased Property, or any portion thereof, from whatever cause or any Condemnation, (b) the lawful or unlawful prohibition of, or restriction upon, Tenant’s use of the Leased Property, or any portion thereof, or the interference with such use by any Person or by reason of eviction by paramount title; (c) any claim which Tenant may have against Landlord by reason of any default (other than a monetary default) or breach of any warranty by Landlord under this Agreement or any other agreement between Landlord and Tenant, or to which Landlord and Tenant are parties; (d) any bankruptcy, insolvency, reorganization, composition, readjustment, liquidation, dissolution, winding up or other proceedings affecting Landlord or any assignee or transferee of Landlord; or (e) for any other cause whether similar or dissimilar to any of the foregoing (other than a monetary default by Landlord). Except as otherwise specifically provided in this Agreement, Tenant hereby waives all rights arising from any occurrence whatsoever, which may now or hereafter be conferred upon it by law (a) to modify, surrender or terminate this Agreement or quit or surrender the Leased Property, or any portion thereof, or (b) which would entitle Tenant to any abatement, reduction, suspension or deferment of the Rent or other sums payable or other obligations to be performed by Tenant hereunder. The obligations of Tenant hereunder shall be separate and independent covenants and agreements, and the Rent and all other sums payable by Tenant hereunder shall continue to be payable in all events unless the obligations to pay the same shall be terminated pursuant to the express provisions of this Agreement.
Damage or Destruction If any Property shall be damaged or destroyed, in whole or in part, by fire or other property hazard or casualty, Borrower shall give prompt notice thereof to Lender and one hundred (100%) percent of the net amount of all insurance proceeds received by Lender or Borrower as a result of such damage or destruction after deduction of reasonable costs and the expenses, if any, in collecting the same, shall be applied in reduction of the outstanding Principal Balance under the Note pertaining to the Damaged Property. Notwithstanding anything to the contrary set forth above, if a particular Property (a "DAMAGED PROPERTY") shall be damaged or destroyed, in whole or in part, by fire or other casualty, Lender shall, in accordance with the provisions of this Section hereinafter set forth, make the net amount of all insurance proceeds received by Lender pursuant to the provisions of this Agreement as a result of such damage or destruction after deduction of its reasonable costs and expenses, if any, in collecting the same (hereinafter referred to as the "NET PROCEEDS") available for the repair and restoration of the Damaged Property, provided that (i) no default shall have occurred and shall be continuing under the Loan Documents, (ii) Borrower shall commence the repair and restoration of the Damaged Property, as nearly as possible to the condition the Damaged Property was in immediately prior to such fire or other casualty, with such alterations as may be approved by Lender, as soon as reasonably practicable, and shall diligently pursue the same to satisfactory completion, (iii) Lender shall be satisfied that any operating deficits which will be incurred with respect to the Damaged Property as a result of the occurrence of any such fire or other casualty will be covered out of the Net Proceeds or by Borrower out-of-pocket or with the proceeds, if any, of business interruption or rental interruption insurance, (iv) Lender shall be satisfied that, within a reasonable period of time, not to exceed one hundred eighty (180) days following the completion of such repair and restoration of the Damaged Property, the gross cash flow and the net cash flow of the Damaged Property will be restored to a level sufficient to cover all carrying costs and operating expenses of the Damaged Property, (v) Lender shall be satisfied that the repair and restoration of the Damaged Property will be completed on or before the earlier to occur of (w) ninety (90) days prior to the Maturity Date, or (x) the date on which the business interruption insurance covered by such Borrower shall expire, (vi) Lender shall be satisfied that all of the terms, covenants and provisions of this Agreement and the other Loan Documents will continue to be complied with during and subsequent to the completion of such repair and restoration and (vii) Borrower and ARC IV shall execute and deliver to Lender a completion guaranty in form and substance satisfactory to Lender pursuant to the provisions of which Borrower and ARC IV shall jointly and severally guaranty to Lender the lien-free completion of the repair and restoration of the Damaged Property in accordance with the provisions of this paragraph. The Net Proceeds shall be held by Lender in an interest-bearing account, and until disbursed in accordance with the provisions of this paragraph, shall constitute additional security for the payment of the Debt. The Net Proceeds together with interest earned thereon, shall be disbursed by Lender to, or as directed by, Borrower from time to time during the course of the repair and restoration of the Damaged Property, upon receipt of evidence satisfactory to Lender (which evidence shall in each instance and to the full extent required by Lender include receipted bills, invoices, lien waivers and a continuation and date down of title to the Damaged Property in form satisfactory to Lender and issued by the title company insuring the lien of the Mortgage encumbering such Property or another title company satisfactory to Lender) that (i) all materials installed and work and labor performed (except to the extent that they are to be paid for out of the requested disbursement) in connection with the repair and restoration of the Damaged Property have been paid for in full, and (ii) there exist no notice of pendency, stop order, notice of intention to file mechanic's or materialman's lien, mechanic's or materialman's lien or other lien or encumbrance of any nature whatsoever on the Damaged Property arising out of the repair and restoration of the Damaged Property which have not either been fully bonded to the satisfaction of Lender and discharged of record or in the alternative fully insured over to the satisfaction of Lender by the title company insuring the lien of the Mortgage encumbering the Damaged Property. The repair and restoration of the Damaged Property shall be done and completed by Borrower in an expeditious and diligent fashion and in compliance with all applicable governmental laws, rules and regulations (including, without limitation, all applicable Environmental Requirements), and all plans and specifications required in connection with the repair and restoration of the Damaged Property shall be subject to review and acceptance in all respects by Lender and by the Consultant. If Lender fails to respond within ten (10) Business Days following a request and submissions of plans and specifications for approval, such plans and specification shall be deemed approved by Lender. Upon the occurrence of an Event of Default, Lender shall have the use of such plan and specifications and all permits, licenses and approvals required or obtained in connection with the repair and restoration of the Damaged Property. The identity of the contractors, subcontractors and materialmen engaged in the repair and restoration of the Damaged Property, as well as the contracts under which they have been engaged, shall be identified to Lender and Consultant, if any. All costs and expenses incurred by Lender in connection with making the Net Proceeds available for the repair and restoration of the Damaged Property including, without limitation, reasonable counsel fees and reasonable fees of the Consultant, shall be paid by Borrower. In no event shall Lender be obligated to make disbursements of the Net Proceeds in excess of an amount equal to the costs actually incurred from time to time for work in place as part of the repair and restoration of the Damaged Property,
Loss or Destruction Upon receipt of evidence satisfactory to the Company of the loss, theft, destruction, or mutilation of this Warrant Certificate and, in the case of any such loss, theft or destruction, upon delivery of an indemnity agreement or bond satisfactory in form, substance and amount to the Company or, in the case of any such mutilation, upon surrender and cancellation of this Warrant Certificate, the Company at its expense will execute and deliver, in lieu thereof, a new Warrant Certificate of like tenor.
Expiration or Termination A. Owner shall have the right, upon thirty (30) days prior written notice to Operator, to terminate this Agreement in its entirety, upon or after the happening of one or more of the following events, if said event or events shall then be continuing:
(i) If Operator shall make a general assignment for the benefit of creditors; or
(ii) If Operator shall file a voluntary petition in bankruptcy or a petition seeking their reorganization or the readjustment of their indebtedness under the Federal Bankruptcy laws or under similar State laws; or
(iii) If an involuntary petition in bankruptcy shall be filed against Operator and Operator is thereafter adjudicated a bankruptcy thereunder; or
(iv) If Operator shall consent to the appointment of a receiver, trustee, or liquidator of all or substantially all of the property of Operator; or
(v) If Operator shall fail to pay the SASO Fee or other money payments required by this Agreement and such failure shall not be remedied within thirty (30) days following receipt by Operator of written demand from Owner; or
(vii) If Operator shall default in fulfilling any of the terms, covenants or conditions to be fulfilled by them hereunder and shall fail to commence with due diligence the remedying of said default within thirty (30) days following receipt by Operator of written demand from Owner to do so.
B. Operator shall have the right, after thirty (30) days written notice to Owner, to terminate or suspend this Agreement upon the happening of one or more of the following events, if said event or events shall then be continuing:
(i) The issuance by any court of competent jurisdiction of an injunction, order or decree preventing or restraining the use of the Airport for normal airport purposes or the use of any part thereof which may be used by Operator and which is necessary for Operator's operations of the Airport, which remains in force for a period of at least ninety (90) consecutive days.
(ii) If Owner shall default in fulfilling any of the terms, covenants or conditions to be fulfilled by it under this Agreement and shall fail to cure said default within thirty (30) days following receipt of written demand from Operator to do so; or
(iii) If all or a mutual part of the Airport or Airport facilities shall be destroyed by fire, explosion, earthquake, other casualty, or acts of God or the public enemy;
(iv) If the United States Government or any of its agencies shall occupy the Airport or any substantial part thereof to such an extent as to interfere materially with Operator’s operations, for a period of thirty
Destruction or Damage (a) If the Building or the Premises are totally destroyed by storm, fire, earthquake, or other casualty, or damaged to the extent that, in Landlord's reasonable opinion the damage cannot be restored within one hundred eighty (180) days of the date Landlord provides Tenant written notice of Landlord's reasonable estimate of the time necessary to restore the damage, or if the damage is not covered by standard "all risks" property insurance and as a result Landlord elects not to restore such damage, Landlord or Tenant shall have the right to terminate this Lease effective as of the date of such destruction or damage by written notice to the other on or before thirty (30) days following Landlord's notice described in the next sentence and Rent shall be accounted for as between Landlord and Tenant as of that date. Landlord shall provide Tenant with notice within forty-five (45) days following the date of the damage of the estimated time needed to restore, and whether the loss is covered by Landlord's insurance coverage (and if not, whether Landlord nevertheless elects to restore).
(b) If the Premises are damaged by any such casualty or casualties but neither party is entitled to or neither party elects to terminate this Lease as provided in subparagraph (a) above, this Lease shall remain in full force and effect, Landlord shall notify Tenant in writing within forty-five (45) days of the date of the damage that the damage will be restored (and will include Landlord's good faith estimate of the date the restoration will be complete), in which case Rent shall xxxxx as to any portion of the Premises which is not usable, and Landlord shall restore the Premises to substantially the same condition as before the damage occurred as soon as practicable, whereupon full Rent shall recommence.
Damage or Destruction Condemnation (a) In the event of partial damage or destruction of the Property of a type which can, under the circumstances, be expected in the reasonable judgment of Seller and Buyer to be restored or repaired at a cost of $500,000 or less, then, this Contract shall be consummated on the Closing Date at the Purchase Price, and unless such damage has been repaired by Seller prior to Closing, Seller shall assign to Buyer the casualty insurance proceeds payable to Seller and business interruption proceeds applicable to the period on and after the Closing Date payable to Seller (but only to the extent such business interruption proceeds are assignable to Buyer), less any amounts expended by Seller for partial restoration and with a credit to Buyer for the amount of any deductible and/or uninsured damage.
(b) In the event that the Property shall have been damaged by fire or casualty, the cost of repair or restoration of which would, in the reasonable judgment of Seller and Buyer, exceed the sum of $500,000, then unless Seller has previously repaired or restored the Property to its former condition, at Buyer’s election, Seller shall either (i) pay over or assign to Buyer, on delivery of the Deed all casualty insurance proceeds payable to Seller and business interruption proceeds applicable to the period on and after the Closing Date payable to Seller (but only to the extent such business interruption proceeds are assignable to Buyer), less any amounts reasonably expended by Seller for partial restoration, with a credit to Buyer for the amount of any deductible and/or uninsured damage, or (ii) direct Escrow Agent to return the Deposit to Buyer in which case, except for the Surviving Obligation, all other obligations of the parties hereto shall cease and this Contract shall terminate and be without further recourse or remedy to the parties hereto. Notwithstanding the foregoing, if Buyer elects to proceed with the transaction under clause (i) of this paragraph (b), in no event shall Seller be obligated to incur any out of pocket cost above $500,000 (whether attributable to a casualty being uninsured, underinsured or to any deductible).
(c) If all or part of the Property is taken by condemnation, eminent domain or by agreement in lieu thereof, or any proceeding to acquire, take or condemn all or part of the Property is threatened or commenced, Buyer may either terminate this Contract (in which event Buyer shall be entitled to a return of the Deposit and accrued interest thereon, if any, and, except for the Surviving Obligations, all other obligations of the parties hereto shall cease and this Contract shall terminate and be without further recourse or remedy to the parties hereto) or close title to the Property in accordance with the terms hereof, without reduction in the Purchase Price, together with an assignment of Seller's rights to any award paid or payable by or on behalf of the condemning authority. If Seller has received payments from the condemning authority and if Buyer elects to close title to the Property, Seller shall credit the amount of said payment against the Purchase Price at the Closing.
