Attorneys’ Fees; Expenses Xxxxxxxx agrees to pay upon demand all of Xxxxxx’s costs and expenses, including Xxxxxx’s attorneys’ fees and Xxxxxx’s legal expenses, incurred in connection with the enforcement of this Agreement. Lender may hire or pay someone else to help enforce this Agreement, and Borrower shall pay the costs and expenses of such enforcement. Costs and expenses include Xxxxxx’s attorneys’ fees and legal expenses whether or not there is a lawsuit, including attorneys’ fees and legal expenses for bankruptcy proceedings (including efforts to modify or vacate any automatic stay or injunction), appeals, and any anticipated post-judgment collection services. Borrower also shall pay all court costs and such additional fees as may be directed by the court.
Isolation Allowance Employees in the following Communities shall receive an Isolation Allowance of $74.00 per month. Alert Bay Xxxxx Lake Chetwynd Xxxxxx Creek Xxxxx Lake Fort Xxxxxx Fort St. Xxxxx Fort St. Xxxx Xxxxxx Lake Gold River Hazelton Houston Hudson Hope Kitimat XxXxxxx Xxxxxxxxx Nakusp New Denver Port Xxxxx Port Hardy Port XxXxxxx Pouce Coupe Prince Xxxxxx Xxxxx Charlotte Islands Xxxxxxxx Xxxxxxx Tahsis Terrace Tofino Tumbler Ridge Valemount Vanderhoof Waglisla
Construction Allowance (a) Landlord shall provide to Tenant a construction allowance not to exceed $135.00 per rentable square foot in the Relocation Premises (the “Construction Allowance”) to be applied toward the Total Construction Costs, as adjusted for any changes to the Tenant Work. If the Total Construction Costs are estimated to exceed the Construction Allowance by more than $5.00 per rentable square foot of the Relocation Premises, then no advance of the Construction Allowance shall be made by Landlord until Tenant has first paid to the contractor from its own funds (and provided reasonable evidence thereof to Landlord) the anticipated amount by which the projected Total Construction Costs exceed the amount of the Construction Allowance. Thereafter, Landlord shall pay to Tenant (or at Tenant’s request directly to Tenant’s general contractor) the Construction Allowance in multiple disbursements (but not more than once in any calendar month) following the receipt by Landlord of the following items: (i) a request for payment and sworn statements of Tenant and contractor, (ii) final or partial lien waivers, as the case may be, from all persons performing work or supplying or fabricating materials for the Tenant Work, fully executed, acknowledged and in recordable form, which waivers may be conditioned upon receipt of payment, (iii) the Architect’s certification that the Tenant Work for which reimbursement has been requested has been finally completed, including (with respect to the last application for payment only) any punch-list items, on the appropriate AIA form or another form approved by Landlord, and, (iv) with respect to the disbursement of the last 10% of the Construction Allowance, (1) the permanent certificate of occupancy issued for the Relocation Premises, if required by applicable law, (2) the record drawing in CAD format, PDF format and hard copy required by Section 5 above, and (3) an estoppel certificate confirming such factual matters as Landlord or Landlord’s Mortgagee may reasonably request (collectively, a “Completed Application for Payment”). Landlord shall pay the amount requested in the applicable Completed Application for Payment to Tenant within 30 days following Tenant’s submission of the Completed Application for Payment. If, however, the Completed Application for Payment is incomplete or incorrect, Landlord shall promptly notify Tenant of the same and Landlord’s payment of such request shall be deferred until 30 days following Landlord’s receipt of the corrected Completed Application for Payment. Notwithstanding anything to the contrary contained in this Exhibit, Landlord shall not be obligated to make any disbursement of the Construction Allowance during the pendency of any of the following: (1) Landlord has received written notice of any unpaid claims relating to any portion of the Tenant Work or materials in connection therewith covered by previously funded applications for payment, (2) there is an unbonded lien outstanding against the Building or the Relocation Premises or Tenant’s interest therein by reason of work done, or claimed to have been done, or materials supplied or specifically fabricated, claimed to have been supplied or specifically fabricated, to or for Tenant or the Relocation Premises, (3) the conditions to the advance of the Construction Allowance are not satisfied, or (4) Tenant is in Default under the Lease. (b) The Construction Allowance must be used on Tenant Work performed within the Relocation Premises and the Total Construction Costs and may not be used to pay for furniture, fixtures or equipment or as rent abatement, HOWEVER, notwithstanding the foregoing, provided Tenant is not in Default, Tenant may use a portion of the Construction Allowance, not to exceed an amount equal to $35.00 per rentable square foot of the Relocation Premises, to pay for furniture, fixtures or equipment, moving costs, cabling costs, and other soft costs associated with the Relocation Premises. Should Tenant elect to use a portion of the Construction Allowance to pay for such soft costs, at Landlord’s request Tenant shall execute and deliver a letter to Landlord confirming the exact amount of the Construction Allowance used to pay for such soft costs. Should Tenant elect to use a portion of the Construction Allowance to pay for such costs, Tenant shall provide Landlord with a written request that includes copies of paid invoices or receipts for reimbursement of such costs, and Landlord shall reimburse Tenant for such amounts within 30 days of receipt of Tenant’s request. Tenant shall provide lien waivers as appropriate. No portion of the Construction Allowance may be used as a credit against Rent due under the Lease. (c) The Construction Allowance must be used (i.e. work performed and invoices submitted to Landlord) by June 30, 2020, or the Construction Allowance shall be deemed forfeited with no further obligation by Landlord with respect thereto. (d) If Landlord defaults in Landlord’s obligation to pay the Construction Allowance pursuant to Section 9 of this Exhibit B-1, or any portion thereof, within five (5) days after the date the same is due, then Tenant shall have the right to give Landlord a second written notice (“Offset Exercise Notice”) requesting payment of such unpaid amounts and notifying Landlord that Tenant intends to offset against rent if not paid. In the event that Landlord fails to contest in good faith or fully pay such amounts within ten (10) business days after such Offset Exercise Notice is received by Landlord, then provided no Default exists Tenant may withhold and offset such unpaid sums from and against 25% of Base Rent next due until paid.
Disbursement of the Tenant Improvement Allowance Except as otherwise set forth in this Work Letter, the Tenant Improvement Allowance shall be disbursed by Landlord (each of which disbursements shall be made pursuant to Landlord’s disbursement process, which disbursement process shall require the Architect to make field verifications and written certifications as required by Landlord in connection with Landlord’s disbursements to Contractor (as defined below)) only for the following items and costs (collectively the “Tenant Improvement Allowance Items”): (a) Payment of (i) the fees of the Architect and the Engineers (as defined below), (ii) charges for Landlord’s construction consultant and Building engineer, and (iii) the fees incurred by, and the cost of documents and materials supplied by, Landlord and Landlord’s consultants in connection with the preparation and review of the Construction Drawings (as defined below); (b) The payment of plan check, permit and license fees relating to construction of the Tenant Improvements; (c) The cost of construction of the Tenant Improvements, including, without limitation, any cost of after-hours freight elevator usage; (d) The cost of any changes in the Base, Shell, and Core when such changes are required by the Construction Drawings, such cost to include all direct architectural and/or engineering fees and expenses incurred in connection therewith; (e) The cost of any changes to the Construction Drawings or Tenant Improvements required by applicable laws and building codes (collectively, “Code”); (f) Sales and use taxes; and (g) All other costs to be expended by Landlord in connection with the construction of the Tenant Improvements. In no event shall the Tenant Improvement Allowance Items include any costs of procuring or installing in the Premises any trade fixtures, equipment, furniture, furniture partitions or systems, furnishings, telephone, telecommunications, data and security wiring, cabling and equipment, or other personal property (“Personal Property”) to be used in the Premises by Tenant, and the cost of such Personal Property shall be paid by Tenant.
Excess Costs If the Permitted Costs exceeds the Finish Allowance, then Tenant shall pay all such excess costs (“Excess Costs”), provided, however, Landlord will, prior to the commencement of construction of Tenant’s Improvements, advise Tenant of the sum of the Contract Sum and the Construction Management Fee (the “Cost Estimate”). Tenant shall have five (5) business days from and after the receipt of such advice within which to approve or disapprove the Contract Sum and Cost Estimate. If Tenant fails to approve same by the expiration of the fifth such business day, then Tenant shall be deemed to have approved the Proposed Contract Sum and Cost Estimate. If Tenant disapproves the Contract Sum and Cost Estimate within such five (5) business day period, then Tenant shall either reduce the scope of Tenant’s Improvements such that the Contract Sum and Construction Management Fee do not exceed the Finish Allowance or, at Tenant’s option, Landlord shall obtain two (2) additional bids, provided that each day beyond such five (5) business day period and until the rebid is accepted by Tenant shall constitute a Tenant Delay hereunder. The foregoing process shall continue until a Contract Sum and Cost Estimate are accepted or deemed accepted by Tenant. Landlord and Tenant must approve (or be deemed to have approved) the Contract Sum for the construction of Tenant’s Improvements in writing prior to the commencement of construction.
Attorneys’ Fees; Costs Should litigation be necessary to enforce any terms or provisions of this Agreement, then each party shall bear its own litigation and collection expenses, witness fees, court costs and attorney’s fees.
Start-Up Costs The Government of Ontario will provide:
Tenant Improvement Allowance Items Except as otherwise set forth in this Tenant Work Letter, the Tenant Improvement Allowance shall be disbursed by Landlord only for the following items and costs (collectively, the “Tenant Improvement Allowance Items”): 2.2.1.1 Payment of the fees of the “Architect” and the “Engineers,” as those terms are defined in Section 3.1 of this Tenant Work Letter, the costs of Tenant’s project manager (if any) and payment of the fees incurred by, and the cost of documents and materials supplied by, Landlord and Landlord’s consultants in connection with the preparation and review of the “Construction Drawings,” as that term is defined in Section 3.1 of this Tenant Work Letter; 2.2.1.2 The payment of plan check, permit and license fees relating to construction of the Tenant Improvements; 2.2.1.3 The cost of construction of the Tenant Improvements, including, without limitation, contractors’ fees and general conditions, testing and inspection costs, costs of utilities, trash removal, parking and hoists, and the costs of after-hours freight elevator usage. 2.2.1.4 The cost of any changes in the Base, Shell and Core work when such changes are required by the Construction Drawings (including if such changes are due to the fact that such work is prepared on an unoccupied basis), such cost to include all direct architectural and/or engineering fees and expenses incurred in connection therewith; 2.2.1.5 The cost of any changes to the Construction Drawings or Tenant Improvements required by applicable laws and building codes (collectively, “Code”); 2.2.1.6 Sales and use taxes; 2.2.1.7 The “Coordination Fee,” as that term is defined in Section 4.2.2.2 of this Tenant Work Letter; and 2.2.1.8 All other costs to be expended by Landlord in connection with the construction of the Tenant Improvements.
Tenant’s Costs Within 60 days after the Commencement Date, and within 60 days after the beginning of each calendar year, Landlord shall give Tenant a written estimate, for such calendar year, of Tenant’s share of the cost of utilities, if not separately metered, taxes and insurance provided by Landlord (“Tenant Costs”). Tenant shall pay such estimated amount to Landlord in equal monthly installments, in advance. Within 90 days after the end of each calendar year, Landlord shall furnish to Tenant a statement showing in reasonable detail the costs incurred by Landlord for the operation and maintenance of the Premises during such year (the “Annual Statement”), and Tenant shall pay to Landlord Tenant’s proportionate share of the cost incurred in excess of the payments made by Tenant within 10 days of receipt of such statement. In the event that the payments made by Tenant for the operation and maintenance of the Premises exceed Tenant’s share of the cost of same, such amount shall be credited by Landlord to the Rent or other charges next due and owing, provided that, if the Lease term has expired, Landlord shall accompany said statement with the amount due Tenant. Tenant shall have the right, by giving written notice thereof to Landlord within sixty (60) days after Tenant’s receipt of each Annual Statement, to contest all or any item comprising Tenant Costs and in connection therewith audit Landlord’s books and records relating to Tenant Cost covered by the Annual Statement. Landlord shall promptly provide Tenant with copies of all bills and records supporting the Tenant Costs or any particular item of Tenant Costs specified by Tenant in writing. If Tenant fails to deliver a notice of audit/contest to Landlord within the aforesaid sixty (60) day period, Tenant shall be deemed to have accepted the Annual Statement for the applicable calendar year.
Line Outage Costs Notwithstanding anything in the NYISO OATT to the contrary, the Connecting Transmission Owner may propose to recover line outage costs associated with the installation of Connecting Transmission Owner’s Attachment Facilities or System Upgrade Facilities or System Deliverability Upgrades on a case-by-case basis.
