Selection of Subcontractors, Procurement of Materials and Leasing of Equipment The contractor shall not discriminate on the grounds of race, color, religion, sex, national origin, age or disability in the selection and retention of subcontractors, including procurement of materials and leases of equipment. The contractor shall take all necessary and reasonable steps to ensure nondiscrimination in the administration of this contract.
a. The contractor shall notify all potential subcontractors and suppliers and lessors of their EEO obligations under this contract.
b. The contractor will use good faith efforts to ensure subcontractor compliance with their EEO obligations.
Procedure for Third Party Claims The obligations and liabilities of each Party with respect to Third-Party Claims shall be subject to the following terms and conditions:
(i) Promptly upon receiving a written notice of a Third-Party Claim, the Indemnifying Party may elect, at its sole option, to undertake the defense thereof by outside counsel of its own choosing, which outside counsel shall be reasonably satisfactory to the Indemnified Party, by sending written notice of its election to the Indemnified Party; provided however, that if, in the Indemnified Party’s and the Indemnifying Party’s reasonable judgment, a conflict of interest exists between the Indemnified Party and the Indemnifying Party with respect to such Third-Party Claim, or if the Indemnifying Party elects not to defend or otherwise does not promptly defend such Third-Party Claim, such Indemnified Party shall be entitled to undertake the defense of, and to compromise or settle, such Third-Party Claim on behalf, for the account, and at the risk of the Indemnifying Party, to the extent that the Indemnifying Party is determined to be obligated to indemnify the Indemnified Party under this Agreement with respect to such Third-Party Claim. The written notice of the Third-Party Claim shall contain all material information known to the Indemnified Party with respect to such Third-Party Claim and shall include copies of materials submitted to Indemnified Party by the Third-Party with respect to such Third-Party Claim.
(ii) If the Indemnifying Party elects to undertake and diligently pursue the defense of a Third-Party Claim hereunder, the Indemnifying Party shall control all aspects of the defense and settlement of such Third-Party Claim and may settle, compromise or enter into a judgment with respect to such Third-Party Claim; provided that the Indemnifying Party shall not enter into any such settlement, compromise or judgment without the prior written consent of the Indemnified Party if such settlement, compromise or judgment would result in the imposition of any non-monetary liability or obligation on the Indemnified Party. If the Indemnifying Party assumes control of the defense under this Article 9, the Indemnified Party shall fully cooperate with the Indemnifying Party in connection therewith and may employ, at any time, a separate outside counsel to represent it; provided however, that the Indemnified Party shall be solely responsible for the costs and expenses of any such separate outside counsel. If the Indemnified Party undertakes the defense of a Third-Party Claim hereunder, the Indemnified Party shall not settle, compromise, or enter into any judgment with respect to such Third-Party Claim for which it is seeking or shall seek indemnification hereunder without the prior written consent of Indemnifying Party, which written consent shall not be unreasonably withheld, conditioned or delayed.
(iii) The Indemnified Party shall provide the Indemnifying Party with access to all reasonably requested records and documents of the Indemnified Party relating to any Third-Party Claim, other than documents for which the Indemnified Party has claimed or shall claim a legal privilege.
CERTIFICATION OF NO ASBESTOS CONTAINING MATERIALS OR WORK 8.1 The Contractor shall be responsible for ensuring that no asbestos containing materials or work is included within the scope of the Work. The Contractor shall take whatever measures it deems necessary to insure that all employees, suppliers, fabricators, material men, subcontractors, or their assigns, comply with this requirement.
8.2 The Contractor shall ensure that Texas Department of Health licensed individuals, consultants or companies are used for any required asbestos work including asbestos inspection, asbestos abatement plans/specifications, asbestos abatement, asbestos project management and third-party asbestos monitoring.
Presentation of Potential Target Businesses The Company shall cause each of the Initial Shareholders to agree that, in order to minimize potential conflicts of interest which may arise from multiple affiliations, the Initial Shareholders will present to the Company for its consideration, prior to presentation to any other person or company, any suitable opportunity to acquire an operating business, until the earlier of the consummation by the Company of a Business Combination or the liquidation of the Company, subject to any pre-existing fiduciary obligations the Initial Shareholders might have.
Convicted, Discriminatory, Antitrust Violator, and Suspended Vendor Lists In accordance with sections 287.133, 287.134, and 287.137, F.S., the Contractor is hereby informed of the provisions of sections 287.133(2)(a), 287.134(2)(a), and 287.137(2)(a), F.S. For purposes of this Contract, a person or affiliate who is on the Convicted Vendor List, the Discriminatory Vendor List, or the Antitrust Violator Vendor List may not perform work as a contractor, supplier, subcontractor, or consultant under the Contract. The Contractor must notify the Department if it or any of its suppliers, subcontractors, or consultants have been placed on the Convicted Vendor List, the Discriminatory Vendor List, or the Antitrust Violator Vendor List during the term of the Contract. In accordance with section 287.1351, F.S., a vendor placed on the Suspended Vendor List may not enter into or renew a contract to provide any goods or services to an agency after its placement on the Suspended Vendor List. A firm or individual placed on the Suspended Vendor List pursuant to section 287.1351, F.S., the Convicted Vendor List pursuant to section 287.133, F.S., the Antitrust Violator Vendor List pursuant to section 287.137, F.S., or the Discriminatory Vendor List pursuant to section 287.134, F.S., is immediately disqualified from Contract eligibility.
Technical Feasibility of String While ICANN has encouraged and will continue to encourage universal acceptance of all top-‐level domain strings across the Internet, certain top-‐level domain strings may encounter difficulty in acceptance by ISPs and webhosters and/or validation by web applications. Registry Operator shall be responsible for ensuring to its satisfaction the technical feasibility of the TLD string prior to entering into this Agreement.
Vendor Logo (Supplemental Vendor Information Only) No response Optional. If Vendor desires that their logo be displayed on their public TIPS profile for TIPS and TIPS Member viewing, Vendor may upload that logo at this location. These supplemental documents shall not be considered part of the TIPS Contract. Rather, they are Vendor Supplemental Information for marketing and informational purposes only. Some participating public entities are required to seek Disadvantaged/Minority/Women Business & Federal HUBZone ("D/M/WBE/Federal HUBZone") vendors. Does Vendor certify that their entity is a D/M/WBE/Federal HUBZone vendor? If you respond "Yes," you must upload current certification proof in the appropriate "Response Attachments" location. NO Some participating public entities are required to seek Historically Underutilized Business (HUB) vendors as defined by the Texas Comptroller of Public Accounts Statewide HUB Program. Does Vendor certify that their entity is a HUB vendor? If you respond "Yes," you must upload current certification proof in the appropriate "Response Attachments" location. No Can the Vendor provide its proposed goods and services to all 50 US States? Yes
Procedures for Third Party Claims In the case of any claim for indemnification arising from a claim of a third-party other than an Infringement Claim subject to Section 13.3 above (a “Third-Party Claim”), a party seeking indemnification hereunder (each an “Indemnified Party”) shall give prompt written notice, following such Indemnified Party’s receipt of such claim or demand, to the party from which indemnity is sought (each an “Indemnifying Party”) of any claim or demand of which such Indemnified Party has knowledge and as to which it may request indemnification hereunder; provided, however, that failure to give such notice will not affect such Indemnified Party’s rights hereunder unless, and then solely to the extent that, the rights of the Indemnifying Parties from whom indemnity is sought are prejudiced as a result of such failure. The Indemnifying Party shall have the right (and if it elects to exercise such right, shall do so within twenty (20) days after receiving such notice from the Indemnified Party) to defend and to direct the defense against any such claim or demand, in its name or in the name of the Indemnified Party, as the case may be, at the expense of the Indemnifying Party, and with counsel selected by the Indemnifying Party; provided, that the Indemnifying Party shall be entitled to assume control of the defense of such action only if the Indemnifying Party acknowledges in writing its indemnity obligations and assumes and holds the Indemnified Party harmless from and against all Losses resulting from such Third-Party Claim; and provided further that the Indemnifying Party shall not be entitled to assume control of such defense if (i) the Indemnifying Party shall not have notified the Indemnified Party of its exercise of its right to defend such Third-Party claim within such twenty (20) day period; (ii) such claim or demand seeks an injunction or other equitable relief against the Indemnified Party, (iii) the Indemnified Party shall have reasonably concluded that (x) there is a conflict of interest between the Indemnified Party and the Indemnifying Party in the conduct of the defense of such claim or demand or (y) the Indemnified Party has one or more defenses not available to the Indemnifying Party, (iv) such claim relates to or arises in connection with any criminal proceeding, action, indictment, allegation or investigation, or (v) the appropriate court rules that the Indemnifying Party failed or is failing to vigorously prosecute or defend such Third-Party Claim. Notwithstanding anything in this Agreement to the contrary, the Indemnified Party shall, at the expense of the Indemnifying Party, cooperate with the Indemnifying Party, and keep the Indemnifying Party fully informed, in the defense of such claim or demand. The Indemnified Party shall have the right to participate in the defense of any claim or demand with counsel employed at its own expense; provided, however, that, in the case of any claim or demand described in clause (i) or (ii) of the second preceding sentence or as to which the Indemnifying Party shall not in fact have employed counsel to assume the defense of such claim or demand, the reasonable fees and disbursements of such counsel shall be at the expense of the Indemnifying Party. The Indemnifying Party shall have no indemnification obligations with respect to any such claim or demand which shall be settled by the Indemnified Party without the prior written consent of the Indemnifying Party, which consent shall not be unreasonably withheld, delayed or conditioned. The Indemnifying Party shall not settle any such claim without the prior written consent of the Indemnified Party (which consent shall not be unreasonably withheld, delayed or conditioned if such settlement is accompanied by a document releasing the Indemnified Party from all liability with respect to the matter in controversy that is binding, valid and enforceable against all applicable Parties). Notwithstanding the foregoing, if the Indemnified Party fails to object to the settlement within five (5) Business Days of receipt of a written notice from the Indemnifying Party containing the terms and condition of such settlement, the Indemnified Party shall be deemed to have consented to the settlement.
Standard of Care; Uncontrollable Events; Limitation of Liability SMC shall use reasonable professional diligence to ensure the accuracy of all services performed under this Agreement, but shall not be liable to the Company for any action taken or omitted by SMC in the absence of bad faith, willful misfeasance, negligence or reckless disregard by it of its obligations and duties. The duties of SMC shall be confined to those expressly set forth herein, and no implied duties are assumed by or may be asserted against SMC hereunder. SMC shall maintain adequate and reliable computer and other equipment necessary or appropriate to carry out its obligations under this Agreement. Upon the Company's reasonable request, SMC shall provide supplemental information concerning the aspects of its disaster recovery and business continuity plan that are relevant to the services provided hereunder. Notwithstanding the foregoing or any other provision of this Agreement, SMC assumes no responsibility hereunder, and shall not be liable for, any damage, loss of data, delay or any other loss whatsoever caused by events beyond its reasonable control. Events beyond SMC's reasonable control include, without limitation, force majeure events. Force majeure events include natural disasters, actions or decrees of governmental bodies, and communication lines failures that are not the fault of either party. In the event of force majeure, computer or other equipment failures or other events beyond its reasonable control, SMC shall follow applicable procedures in its disaster recovery and business continuity plan and use all commercially reasonable efforts to minimize any service interruption. SMC shall provide the Company, at such times as the Company may reasonably require, copies of reports rendered by independent public accountants on the internal controls and procedures of SMC relating to the services provided by SMC under this Agreement. Notwithstanding anything in this Agreement to the contrary, in no event shall SMC, its affiliates or any of its or their directors, officers, employees, agents or subcontractors be liable for exemplary, punitive, special, incidental, indirect or consequential damages, or lost profits, each of which is hereby excluded by agreement of the parties regardless of whether such damages were foreseeable or whether either party or any entity has been advised of the possibility of such damages.
Notice of Loss; Third Party Claims (a) An Indemnified Party shall give the Indemnifying Party notice of any matter that an Indemnified Party has determined has given or could give rise to a right of indemnification under this Agreement, within thirty (30) days of such determination, stating the amount of the Loss, if known, and method of computation thereof, and containing a reference to the provisions of this Agreement in respect of which such right of indemnification is claimed or arises.
(b) If an Indemnified Party shall receive notice of any Action, audit, demand or assessment (each, a “Third Party Claim”) against it or which may give rise to a claim for a Loss under this Article VIII, within thirty (30) days of the receipt of such notice, the Indemnified Party shall give the Indemnifying Party notice of such Third Party Claim; provided, however, that the failure to provide such notice shall not release the Indemnifying Party from any of its obligations under this Article VIII except to the extent that the Indemnifying Party is materially prejudiced by such failure and shall not relieve the Indemnifying Party from any other obligation or liability that it may have to any Indemnified Party otherwise than under this Article VIII. If the Indemnifying Party acknowledges in writing its obligation to indemnify the Indemnified Party hereunder against any Losses that may result from such Third Party Claim, then the Indemnifying Party shall be entitled to assume and control the defense of such Third Party Claim at its expense and through counsel of its choice if it gives notice of its intention to do so to the Indemnified Party within five (5) days of the receipt of notice from the Indemnified Party of such Third Party Claim; provided, however, that if there exists or is reasonably likely to exist a conflict of interest that would make it inappropriate in the judgment of the Indemnified Party in its sole and absolute discretion for the same counsel to represent both the Indemnified Party and the Indemnifying Party, then the Indemnified Party shall be entitled to retain its own counsel in each jurisdiction for which the Indemnified Party determines counsel is required, at the expense of the Indemnifying Party. In the event that the Indemnifying Party exercises the right to undertake any such defense against any such Third Party Claim as provided above, the Indemnified Party shall cooperate with the Indemnifying Party in such defense and make available to the Indemnifying Party, at the Indemnifying Party’s expense, all witnesses, pertinent records, materials and information in the Indemnified Party’s possession or under the Indemnified Party’s control relating thereto as is reasonably required by the Indemnifying Party. Similarly, in the event the Indemnified Party is, directly or indirectly, conducting the defense against any such Third Party Claim, the Indemnifying Party shall cooperate with the Indemnified Party in such defense and make available to the Indemnified Party, at the Indemnifying Party’s expense, all such witnesses, records, materials and information in the Indemnifying Party’s possession or under the Indemnifying Party’s control relating thereto as is reasonably required by the Indemnified Party. No such Third Party Claim may be settled by the Indemnifying Party without the prior written consent of the Indemnified Party.
