Nonwaiver of Rights No waiver of default by either party of any of the terms, covenants, and conditions hereof to be performed, kept, and observed by the other party shall be construed as, or shall operate as, a waiver of any subsequent default of any of the terms, covenants, or conditions herein contained, to be performed, kept, and observed by the other party.
Waiver of Rights No right conferred on either party under this Contract shall be deemed waived, and no breach of this Contract excused, unless such waiver is in writing and signed by the party claimed to have waived such right. Neither the State’s review, approval or acceptance of, nor payment for, the services required under this Contract shall be construed to operate as a waiver of any rights under this Contract or of any cause of action arising out of the performance of this Contract, and the Contractor shall be and remain liable to the State in accordance with applicable law for all damages to the State caused by the Contractor’s negligent performance of any of the services furnished under this Contract.
No Waiver of Sovereign Immunity Nothing in the Contract will be construed as a waiver of the System Agency’s or the State’s sovereign immunity. This Contract shall not constitute or be construed as a waiver of any of the privileges, rights, defenses, remedies, or immunities available to the System Agency or the State of Texas. The failure to enforce, or any delay in the enforcement, of any privileges, rights, defenses, remedies, or immunities available to the System Agency or the State of Texas under the Contract or under applicable law shall not constitute a waiver of such privileges, rights, defenses, remedies, or immunities or be considered as a basis for estoppel. System Agency does not waive any privileges, rights, defenses, or immunities available to System Agency by entering into the Contract or by its conduct prior to or subsequent to entering into the Contract.
Waiver of Steps The parties may mutually agree to waive any step of the grievance procedure.
Waiver of Sovereign Immunity Each Loan Party that is incorporated outside the United States, in respect of itself, its Subsidiaries, its process agents, and its properties and revenues, hereby irrevocably agrees that, to the extent that such Loan Party or its respective Subsidiaries or any of its or its respective Subsidiaries’ properties has or may hereafter acquire any right of immunity, whether characterized as sovereign immunity or otherwise, from any legal proceedings, whether in the United States or elsewhere, to enforce or collect upon the Loans or any Loan Document or any other liability or obligation of such Loan Party or any of their respective Subsidiaries related to or arising from the transactions contemplated by any of the Loan Documents, including, without limitation, immunity from suit, immunity from service of process, immunity from jurisdiction or judgment of any court or tribunal, immunity from execution of a judgment, and immunity of any of its property from attachment prior to any entry of judgment, or from attachment in aid of execution upon a judgment, such Loan Party, for itself and on behalf of its Subsidiaries, hereby expressly waives, to the fullest extent permissible under applicable law, any such immunity, and agrees not to assert any such right or claim in any such proceeding, whether in the United States or elsewhere. Without limiting the generality of the foregoing, each Loan Party further agrees that the waivers set forth in this Section 10.25 shall have the fullest extent permitted under the Foreign Sovereign Immunities Act of 1976 of the United States and are intended to be irrevocable for purposes of such Act.
Buyer’s Rights and Remedies If at any time an Event of Default with respect to Seller has occurred and is continuing, then, unless the Seller has paid in full all of its obligations that are then due, including those under Section 7.2(c) of this Agreement (“Obligations”), the Buyer may exercise one or more of the following rights and remedies: (i) all rights and remedies available to a Secured Party under applicable law with respect to posted Eligible Collateral held by the Buyer, (ii) the right to set-off any amounts payable by the Seller with respect to any Obligations against any posted Eligible Collateral or the Cash equivalent of any posted Eligible Collateral held by the Buyer, or (iii) the right to liquidate any posted Eligible Collateral held by the Buyer and to apply the proceeds of such liquidation of the posted Eligible Collateral to any amounts payable to the Buyer with respect to the Obligations in such order as the Buyer may elect. For purposes of this Paragraph 6, the Buyer may draw on the entire undrawn portion of any Letter of Credit. Cash proceeds that are not applied to the Obligations shall be maintained in accordance with the terms of this CSA. The Seller shall remain liable for amounts due and owing to the Secured Party that remain unpaid after the application, pursuant to this Paragraph 6, of Eligible Collateral to the Obligations.
Limited Waiver of Sovereign Immunity Ex Contractu Contractor acknowledges and agrees that Owner is an agency or instrumentality of the State of Georgia, and as such is entitled to the protection of sovereign immunity. As set forth in Article I, Section II, Paragraph IX of the 1983 Georgia Constitution, sovereign immunity is waived “as to any action ex contractu for the breach of any written contract.” Contractor specifically acknowledges the constitutional and contractual requirements that written changes, modifications, and waivers to this Contract must be specifically executed by the Owner as set forth in the Contract Documents. Accordingly, Contractor specifically acknowledges the constitutional prohibitions against claims against Owner based solely upon oral statement, course of conduct, customs of the trade, quasi-contract, quantum meruit, or O.C.G.A § 13-4-4 (mutual departure from contract terms).
No Waiver of Rights A failure or delay in exercising any right, power or privilege in respect of this Agreement will not be presumed to operate as a waiver, and a single or partial exercise of any right, power or privilege will not be presumed to preclude any subsequent or further exercise, of that right, power or privilege or the exercise of any other right, power or privilege.
No waiver of our rights (a) No failure on our part to exercise and no delay on our part in exercising any right or remedy under this agreement will operate as a waiver of such right or remedy, nor will any single or partial exercise of any right or remedy preclude any other or further exercise of such right or remedy or the exercise of any other right or remedy.
Owner’s Right to Suspend Work The Owner reserves the right, with or without the concurrence of the Design Professional, to suspend the Work at any time or from time to time at the Owner's sole discretion, upon giving Contractor five days advanced written notice thereof. If the Owner exercises this right and then resumes the Work covered hereby, Contractor shall be entitled upon timely claim to a Change Order for payment by Owner of any reasonable Actual Costs actually incurred by Contractor in connection with the suspension and resumption of the Work, as well as an extension in the time for performance of the Work to the extent Contractor is delayed by Owner's suspension, to include compensation based upon the rate for Time Dependent Overhead Costs. The Design Professional shall determine the time, which shall be binding upon both Owner and Contractor, as set forth in Section 3, Part 3.
