Lease Commencement Date The earlier to occur of (i) the date upon which Tenant first commences to conduct business in the Premises, and (ii) the later to occur of (A) November 1, 2018 and (B) the date upon which the Premises are Ready for Occupancy (as that term is defined in Section 5.1 of the Tenant Work Letter attached hereto as Exhibit B (the “Tenant Work Letter”)).
Final Completion 6.5.1 Final Completion of the Work shall be achieved within ninety (90) Days after the earlier of the actual date of Substantial Completion or the Scheduled Substantial Completion Date (the “Final Completion Date”).
Annual Operating Plan Manager shall implement the Operating Plan prepared by Owner. The Operating Plan shall constitute a standard to which Manager shall reasonably attempt to adhere in the operation of the Project; provided, however, as the Operating Plan is a budget, Manager makes no representation or warranty that the actual operations of the Project shall conform to such plan. Except in an emergency, Manager shall not expend funds in any fiscal year in excess of the budgeted line item amounts in the Operating Budget without Owner's prior written approval. In the event any Fiscal Year shall commence without an approved Operating Plan, until the Operating Plan for such Fiscal Year is approved, Manager shall be entitled to make expenditures for items specified in the approved Operating Plan for the past Fiscal Year, at a rate not in excess of the rate permitted under that prior Operating Plan (other than for utilities, taxes, insurance premiums and mortgage payments), without the prior consent of Owner.
Annual Operating Budget As soon as available but, in any event, within sixty (60) days prior to (i) the Cooperation Period Commencement Date in respect of the initial Plant to be completed and, thereafter, (ii) the commencement of each Fiscal Year, an annual operating budget (the "Annual Budget") (including budgeted statements of income and sources and uses of cash and balance sheets) prepared by the Borrower and accompanied by a statement of the chief financial officer of the Borrower to the effect that, the best of his or her knowledge, the budget is a reasonable estimate for the period covered thereby. The first Annual Budget shall cover the period from the Cooperation Period Commencement Date through the end of the Fiscal Year in which the Cooperation Period Commencement Date occurs, and, if such period consists of less than six (6) months, for the immediately succeeding Fiscal Year. Each Annual Budget shall contain complete, fair and accurate estimates (by principal components) of Sales Proceeds, Operating and Maintenance Costs and Debt Service for each Month covered by such Annual Budget based on the Borrower's best projections at such time. Unless otherwise consented to by Eximbank, the Annual Budget from year to year shall be based on the same format as the Base Case Forecast, including any amounts allocated for contingencies, and be maintained on the same basis and provide sufficient detail to permit a meaningful comparison. For each Annual Budget that is expected to cover any period occurring after the Disbursement Date, Eximbank (in consultation with the Independent Engineer) shall review such Annual Budget, and Eximbank's response shall not be unreasonably delayed. If Eximbank does not approve an Annual Budget, Eximbank shall notify the Borrower of the items which are disapproved and the reason for such disapproval. Until such Annual Budget is so approved, the Annual Budget most recently in effect shall continue to apply, except that any items of the then proposed Annual Budget that have been approved shall also be given effect. From time to time, but not more frequently than once per Quarter, the Borrower may propose amendments to an Annual Budget, and Eximbank (in consultation with the Independent Engineer) may reject such proposal within thirty (30) Business Days from the date the Borrower submits such proposal if in Eximbank's reasonable judgment such amendment is not reasonably necessary or advisable for operation of the Project and, if no such rejection is made, such amendments shall become effective. Not later than three (3) Business Days after the effective date of each Annual budget and of any amendment thereto, the Borrower shall provide a copy of the same to the Collateral Trustee.
General Compliance This Agreement is intended to comply with Section 409A or an exemption thereunder and shall be construed and administered in accordance with Section 409A. Notwithstanding any other provision of this Agreement, payments provided under this Agreement may only be made upon an event and in a manner that complies with Section 409A or an applicable exemption. Any payments under this Agreement that may be excluded from Section 409A either as separation pay due to an involuntary separation from service or as a short-term deferral shall be excluded from Section 409A to the maximum extent possible. For purposes of Section 409A, each installment payment provided under this Agreement shall be treated as a separate payment. Any payments to be made under this Agreement upon a termination of employment shall only be made upon a “separation from service” under Section 409A. Notwithstanding the foregoing, the Company makes no representations that the payments and benefits provided under this Agreement comply with Section 409A, and in no event shall the Company be liable for all or any portion of any taxes, penalties, interest, or other expenses that may be incurred by the Executive on account of non-compliance with Section 409A.
Substantial Completion The Tenant Improvements shall be deemed to be “Substantially Completed” on the date that (i) the Tenant Improvements are essentially and satisfactorily completed in accordance with the Final Plans to the extent that the Leased Premises may be occupied by Tenant for its Approved Use, subject only to completion of minor finishing, adjustment of equipment, and other minor construction aspects (“punch list items”) which do not, in the aggregate, cause interference (other than minor inconvenience) with the use and occupancy of the Leased Premises for the Approved Use, and (ii) a certificate of occupancy, whether conditional or final, has been issued by the proper governmental authority. Landlord shall give Tenant at least 30 days prior notice (written or oral) of Landlord’s reasonable estimate of the date of Substantial Completion of the Tenant Improvements. Tenant shall schedule with Landlord a mutually acceptable date, which will not be later than 3 business days after the date of Substantial Completion (but in no event earlier than the Landlord’s estimated date of Substantial Completion), for a walk-through inspection of the Leased Premises. In such walk-through, Landlord and Tenant will mutually and reasonably agree upon a punch list, and subject to Tenant Delay, Landlord will use reasonable efforts to cause such punch list work to be completed within 30 days after such walk-through. Landlord hereby warrants to Tenant, which warranty shall survive for one year following the date of Substantial Completion of the Tenant Improvements, that (a) the materials and equipment furnished by Landlord and Landlord’s contractors in the completion of the Tenant Improvements will be of good quality and new, and (b) such materials and equipment and the work of such contractors shall be free from defects not inherent in the quality required or permitted hereunder. This warranty shall exclude damages or defects caused by Tenant, its agents, employees or contractors, improper or insufficient maintenance, improper operation or normal wear and tear under normal usage. Landlord shall use diligent and good faith efforts to cause the Tenant Improvements for the Fifth Floor Premises to be Substantially Completed by November 1, 2018. Subject only to Force Majeure (as defined in §11 hereof) and Tenant Delay, and provided that Landlord, using good faith efforts, obtains all required construction permits for the Tenant Improvements (the “Construction Permits”) by not later than June 30, 2018, then in the event that Landlord fails to cause the Tenant Improvements for the Fifth Floor Premises to be Substantially Completed on or before December 1, 2018, (the “Fifth Floor Substantial Completion Date”), Tenant shall be entitled to a day-for-day credit of Base Rent due as of the Commencement Date, for each day after the Fifth Floor Substantial Completion Date that the Tenant Improvements for the Fifth Floor Premises are not Substantially Completed; provided, however, that, for every day of delay which results from a Tenant Delay or a Force Majeure, the Fifth Floor Substantial Completion Date shall be moved back on a day-for-day basis. Such day-for-day credit of Base Rent shall commence upon the Commencement Date and shall continue until applied in full; provided that at no time may Tenant offset more than 50% of the Base Rent amount due each month until such abatement has been completed. Landlord shall use diligent and good faith efforts to cause the Tenant Improvements for the Fourth Floor Premises to be Substantially Completed by February 1, 2019. Subject only to Force Majeure (as defined in §11 hereof) and Tenant Delay, and provided that Landlord, using good faith efforts, obtains all required construction permits for the Tenant Improvements (the “Construction Permits”) by not later than June 30, 2018, then in the event that Landlord fails to cause the Tenant Improvements for the Fourth Floor Premises to be Substantially Completed on or before March 1, 2019, (the “Fourth Floor Substantial Completion Date”), Tenant shall be entitled to a day-for-day credit of Base Rent due as of the Commencement Date, for each day after the Fourth Floor Substantial Completion Date that the Tenant Improvements for the Fourth Floor Premises are not Substantially Completed; provided, however, that, for every day of delay which results from a Tenant Delay or a Force Majeure, the Fourth Floor Substantial Completion Date shall be moved back on a day-for-day basis. Such day-for-day credit of Base Rent shall commence upon the June 1, 2019, and shall continue until applied in full; provided that at no time may Tenant offset more than 50% of the Base Rent amount due each month until such abatement has been completed. Subject only to Force Majeure and Tenant Delay, and provided that Landlord, using good faith efforts, obtains all required Construction Permits by not later than June 30, 2018, if the Tenant Improvements for the Leased Premises are not Substantially Completed on or before April 1, 2019 (“Outside Completion Date”), then Tenant shall have the one-time right by not later than 10 days after the Outside Completion Date to terminate this lease by delivering written notice to Landlord, which notice shall be hand delivered to 0000 Xxxx Xxxxx Xxxxx, Xxxxxxxx, Xxxx 00000, Attention: Xxxxxx X. Xxxxx, Xx., and upon hand delivery of such termination notice to said address, this lease shall be deemed null and void and the parties shall have no further rights or obligations hereunder, except those that specifically survive the expiration or earlier termination of this lease. Landlord and Tenant acknowledge and agree that Tenant’s damages as a result of Landlord’s failure to cause the Tenant Improvements for the Fifth Floor Premises to be Substantially Completed by not later than the Fifth Floor Substantial Completion Date or the Fourth Floor Premises to be Substantially Completed by not later than the Fourth Floor Substantial Completion Date are difficult to ascertain, that such amounts set forth above are a reasonable pre-estimate of Tenant’s probable loss as a result thereof and that such damages constitute reasonable liquidated damages for Tenant’s loss and not a penalty.
Central Time After all Parties have been notified, the provisions of paragraphs (b) and (c) of this Section 2.1 shall apply.”
Vesting Commencement Date Exercise Price per Share: Total Number of Shares: Type of Option: Non-Qualified Stock Option/Incentive Stock Option
ANNUITY COMMENCEMENT DATE The Valuation Date on which the Contract Value is withdrawn for payment of annuity benefits under the Annuity Payment Option selected.
Operational Control THE PARTIES EXPRESSLY AGREE THAT LESSEE SHALL AT ALL TIMES WHILE THE AIRCRAFT IS IN ITS POSSESSION DURING THE TERM MAINTAIN OPERATIONAL CONTROL OF THE AIRCRAFT, AND THAT THE INTENT OF THE PARTIES IS THAT THIS AGREEMENT CONSTITUTE A “DRY” OPERATING LEASE. Lessee shall exercise exclusive authority over initiating, conducting, or terminating any flight conducted pursuant to this Agreement, and the Flight Crew shall be under the exclusive command and control of Lessee in all phases of such flights.
