NOTICE OF LABOR DISPUTES (a) If the Contractor has knowledge that any actual or potential labor dispute is delaying or threatens to delay the timely performance of this Contract, the Contractor immediately shall give notice, including all relevant information, to the Authority.
(b) The Contractor agrees to insert the substance of this paragraph, including this subparagraph (b), in any Sub- contract under which a labor dispute may delay the timely performance of this Contract; except that each Subcontract shall provide that in the event its timely performance is delayed or threatened by delay by any actual or potential labor dispute, the Subcontractor shall immediately notify the next higher tier Subcontractor or the Contractor, as the case may be, of all relevant information concerning the dispute.
Notice of Potential Claims The Contractor shall not be entitled to additional compensation or to extension of time for (1) any act or failure to act by the County Project Manager or the County, or (2) the happening of any event or occurrence, unless the Contractor has given the County a written Notice of Potential Claim within ten (10) days of the commencement of the act, failure, or event giving rise to the claim, and before final payment by the County. The written Notice of Potential Claim shall set forth the reasons for which the Contractor believes additional compensation or extension of time is due, the nature of the cost involved, and insofar as possible, the amount of the potential claim. Contractor shall keep full and complete daily records of the work performed, labor and material used, and all costs and additional time claimed to be additional.
Labor Code Notice 2.6.1 All A-E and subcontractors must comply with the requirements of California Labor Code 1770 et seq. if the work performed is considered a “public works” under California Labor Code 1720 et seq. A-E is encouraged to contact the California Department of Industrial Relations for clarification if the A-E is unsure if some or any of the work performed under this CONTRACT qualifies as “public works”.
Notice of Legal Matter or Litigation Grantee will send notice to the Substance Use Disorder (SUD) email box, XxxxxxxxxXxxxx.Xxxxxxxxx@xxxx.xxxxx.xx.xx of any litigation or legal matter related to or affecting this Contract within seven (7) calendar days of becoming aware of the litigation or legal matter.
Notice of Events As soon as Guarantor obtains knowledge thereof, Guarantor shall give Guarantied Party written notice of any condition or event which has resulted in (a) a material adverse change in the financial condition of Guarantor or Company or (b) any Event of Default or Potential Event of Default.
Notice of Disputes Notice of the dispute will be submitted on the form provided in Appendix A and sent to the responding party, in order to provide an opportunity to respond. The Crown shall be provided with a copy.
a) Notice of the dispute shall include the following:
i. Any central provision of the collective agreement alleged to have been violated.
ii. The provision of any statute, regulation, policy, guideline, or directive at issue.
iii. A comprehensive statement of any relevant facts.
iv. The remedy requested.
Notice of Legal Actions The Contractor must notify the Department of any legal actions filed against it for a violation of any laws, rules, codes, ordinances or licensing requirements within 30 days of the action being filed. The Contractor must notify the Department of any legal actions filed against it for a breach of a contract of similar size and scope to this Contract within 30 days of the action being filed. Failure to notify the Department of a legal action within 30 days of the action will be grounds for termination for cause of the Contract.
Notice of Actions Tenant will notify Landlord of any of the following actions affecting Landlord, Tenant or the Premises or the Project that result from or in any way relate to Tenant’s use of the Premises or the Project immediately after receiving notice of the same: (i) any enforcement, cleanup, removal or other governmental or regulatory action instituted, completed or threatened under any Hazardous Materials Law; (ii) any claim made or threatened by any person relating to damage, contribution, liability, cost recovery, compensation, loss or injury resulting from or claimed to result from any Hazardous Material; and (iii) any reports made by any person, including Tenant, to any environmental agency relating to any Hazardous Material, including any complaints, notices, warnings or asserted violations. Tenant will also deliver to Landlord, as promptly as possible and in any event within five (5) business days after Tenant first receives or sends the same, copies of all claims, reports, complaints, notices, warnings or asserted violations relating in any way to the Premises or the Project or Tenant’s use of the Premises or the Project. Upon Landlord’s written request, Tenant will promptly deliver to Landlord documentation acceptable to Landlord reflecting the legal and proper disposal of all Hazardous Materials removed or to be removed from the Premises. All such documentation will list Tenant or its agent as a responsible party and the generator of such Hazardous Materials and will not attribute responsibility for any such Hazardous Materials to Landlord or Landlord’s property manager.
Notice of Arbitration If a Person asserts that there exists a Dispute, then such Person (the “Disputing Person”) will give each other Person involved in such Dispute a written notice setting forth the nature of the asserted Dispute. If all such Persons do not resolve any such asserted Dispute prior to the 10th business day after such notice is given, then any of them may commence arbitration pursuant to this Paragraph 19 by giving each other Person involved in such Dispute a written notice to that effect (an “Arbitration Notice”), setting forth any matters which are required to be set forth therein in accordance with the AAA Rules.
Notice of Complaints Each Seller shall promptly notify the applicable Purchaser upon becoming aware of any complaint concerning any Serviced Appointment made by any party to the Serviced Corporate Trust Contracts, any Securityholder, any Credit Enhancement Provider or any rating agency.
