Notice to Contractor The Contractor is required to submit Certificates of Insurance acceptable to the State as evidence of insurance coverage requirements prior to commencing work under this Contract. Contractor shall not commence work under the contract until they have obtained all the insurance described below and the State has approved such insurance. Contractor shall maintain such insurance in force and effect throughout the term of this Contract, unless otherwise specified in this Contract The failure of the Contractor to provide a Certificate of Insurance, for the policies required under this Contract or renewals thereof, or failure of the insurance company to notify the State of the cancellation of policies required under this Contract shall not constitute a waiver by the State to the Contractor to provide such insurance. The State reserves the right to immediately terminate this Contract if the Contractor is not in compliance with the insurance requirements and retains all rights to pursue any legal remedies against the Contractor. All insurance policies must be open to inspection by the State, and copies of policies must be submitted to the State’s Authorized Representative upon written request.
Condition to Contract As a condition to this Agreement, Contractor shall execute the “Chapter 12B Declaration: Nondiscrimination in Contracts and Benefits” form (form HRC-12B-101) with supporting documentation and secure the approval of the form by the San Francisco Human Rights Commission.
Compensation to Contractor The terms related to the price of the goods and/or services to be provided under this Agreement and the terms of payment to the Contractor are described in more detail in Attachment “B” to this Agreement: Price and Payment Information.
Freedom to Contract The Executive represents that he is free to enter into this Agreement and carry out his obligations hereunder without any conflict with any prior agreements, and that he has not made and will not make any agreement in conflict with this Agreement.
Payment to Contractor The TOWN agrees to pay at the rates specified for SERVICES satisfactorily performed in accordance with this contract. Unless otherwise specified, the CONTRACTOR shall submit an itemized invoice to the TOWN by the end of the month during which SERVICES are performed. Payment will be processed promptly upon receipt and approval by the TOWN of the invoice.
Notice; Defense of Claims An indemnified party may make claims for indemnification hereunder by giving written notice thereof to the indemnifying party within the period in which indemnification claims can be made hereunder. If indemnification is sought for a claim or liability asserted by a third party, the indemnified party shall also give written notice thereof to the indemnifying party promptly after it receives notice of the claim or liability being asserted, but the failure to do so shall not relieve the indemnifying party from any liability except to the extent that it is prejudiced by the failure or delay in giving such notice. Such notice shall summarize the bases for the claim for indemnification and any claim or liability being asserted by a third party. Within 20 days after receiving such notice the indemnifying party shall give written notice to the indemnified party stating whether it disputes the claim for indemnification and whether it will defend against any third party claim or liability at its own cost and expense. If the indemnifying party fails to give notice that it disputes an indemnification claim within 20 days after receipt of notice thereof, it shall be deemed to have accepted and agreed to the claim, which shall become immediately due and payable. The indemnifying party shall be entitled to direct the defense against a third party claim or liability with counsel selected by it (subject to the consent of the indemnified party, which consent shall not be unreasonably withheld) as long as the indemnifying party is conducting a good faith and diligent defense. The indemnified party shall at all times have the right to fully participate in the defense of a third party claim or liability at its own expense directly or through counsel; provided, however, that if the named parties to the action or proceeding include both the indemnifying party and the indemnified party and the indemnified party is advised that representation of both parties by the same counsel would be inappropriate under applicable standards of professional conduct, the indemnified party may engage separate counsel at the expense of the indemnifying party. If no such notice of intent to dispute and defend a third party claim or liability is given by the indemnifying party, or if such good faith and diligent defense is not being or ceases to be conducted by the indemnifying party, the indemnified party shall have the right, at the expense of the indemnifying party, to undertake the defense of such claim or liability (with counsel selected by the indemnified party), and to compromise or settle it, exercising reasonable business judgment. If the third party claim or liability is one that by its nature cannot be defended solely by the indemnifying party, then the indemnified party shall make available such information and assistance as the indemnifying party may reasonably request and shall cooperate with the indemnifying party in such defense, at the expense of the indemnifying party.
Notice of Litigation, Right to Prosecute, Etc No Fund shall be liable for indemnification under this Section 5.03 unless a Person shall have promptly notified such Fund in writing of the commencement of any litigation or proceeding brought against such Person in respect of which indemnity may be sought under this Section 5.03. With respect to claims in such litigation or proceedings for which indemnity by a Fund may be sought and subject to applicable law and the ruling of any court of competent jurisdiction, such Fund shall be entitled to participate in any such litigation or proceeding and, after written notice from such Fund to any Person, such Fund may assume the defense of such litigation or proceeding with counsel of its choice at its own expense in respect of that portion of the litigation for which such Fund may be subject to an indemnification obligation; provided however, a Person shall be entitled to participate in (but not control) at its own cost and expense, the defense of any such litigation or proceeding if such Fund has not acknowledged in writing its obligation to indemnify the Person with respect to such litigation or proceeding. If such Fund is not permitted to participate or control such litigation or proceeding under applicable law or by a ruling of a court of competent jurisdiction, such Person shall reasonably prosecute such litigation or proceeding. A Person shall not consent to the entry of any judgment or enter into any settlement in any such litigation or proceeding without providing each applicable Fund with adequate notice of any such settlement or judgment, and without each such Fund's prior written consent. All Persons shall submit written evidence to each applicable Fund with respect to any cost or expense for which they are seeking indemnification in such form and detail as such Fund may reasonably request.
Authority to Contract Each Party represents and warrants that it has full right, power and authority to enter into and perform its obligations under this Agreement, and that the person signing this Agreement is duly authorized to enter into this Agreement on its behalf.
Parties to Contract Any contract of the character described in Sections 4.1 and 4.2 of this Article IV or in Article VII hereof may be entered into with any Person, although one or more of the Trustees, officers or employees of the Trust may be an officer, director, trustee, shareholder, or member of such other party to the contract, and no such contract shall be invalidated or rendered voidable by reason of the existence of any such relationship, nor shall any Person holding such relationship be liable merely by reason of such relationship for any loss or expense to the Trust under or by reason of said contract or accountable for any profit realized directly or indirectly therefrom, provided that the contract when entered into was reasonable and fair and not inconsistent with the provisions of this Article IV or the By-Laws. The same Person may be the other party to contracts entered into pursuant to Sections 4.1 and 4.2 above or Article VII, and any individual may be financially interested or otherwise affiliated with Persons who are parties to any or all of the contracts mentioned in this Section 4.3.
Waiver of Right to Appeal Provided the Judgment is consistent with the terms and conditions of this Agreement, specifically including the Class Counsel Fees Payment and Class Counsel Litigation Expenses Payment reflected set forth in this Settlement, the Parties, their respective counsel, and all Participating Class Members who did not object to the Settlement as provided in this Agreement, waive all rights to appeal from the Judgment, including all rights to post-judgment and appellate proceedings, the right to file motions to vacate judgment, motions for new trial, extraordinary writs, and appeals. The waiver of appeal does not include any waiver of the right to oppose such motions, writs or appeals. If an objector appeals the Judgment, the Parties’ obligations to perform under this Agreement will be suspended until such time as the appeal is finally resolved and the Judgment becomes final, except as to matters that do not affect the amount of the Net Settlement Amount.
