Construction of the Project Highway (i) The Contractor shall construct the Project Highway as specified in Schedule- B and Schedule-C, and in conformity with the Specifications and Standards set forth in Schedule-D. The Contractor shall be responsible for the correct positioning of all parts of the Works, and shall rectify any error in the positions, levels, dimensions or alignment of the Works. The [650th (six hundred and fiftieth) day] from the Appointed Date shall be the scheduled completion date (the “Scheduled Completion Date”) and the Contractor agrees and undertakes that the construction shall be completed on or before the Scheduled Completion Date, including any extension thereof.
(ii) The Contractor shall construct the Project Highway in accordance with the Project Completion Schedule set forth in Schedule-J. In the event that the Contractor fails to achieve any Project Milestone or the Scheduled Completion Date within a period of 30 (thirty) days from the date set forth in Schedule-J, unless such failure has occurred due to Force Majeure or for reasons solely attributable to the Authority, it shall pay Damages to the Authority of a sum calculated at the rate of 0.05% (zero point zero five percent) of the Contract Price for delay of each day reckoned from the date specified in Schedule –J and until such Project Milestone is achieved or the Project Highway is completed; provided that if the period for any or all Project Milestones or the Scheduled Completion Date is extended in accordance with the provisions of this Agreement, the dates set forth in Schedule-J shall be deemed to be modified accordingly and the provisions of this Agreement shall apply as if Schedule-J has been amended as above; provided further that in the event the Project Highway is completed within or before the Scheduled Completion Date including any Time Extension, applicable for that work or section, the Damages paid under this Clause 10.3 (ii) shall be refunded by the Authority to the Contractor, but without any interest thereon. The Parties agree that for determining achievement or delays in completion of the Project Milestones or the Project on the due date, the works affected due to delay in providing the site for which time extension has been granted beyond the Scheduled Completion Date will be excluded. For example on the due date to achieve the Project Milestone-I (i.e., Stage Payments of 10% (ten percent) of Contract Price on 180th (one hundred and eighty) day from the Appointed Date), if 5% (five percent) of the project length corresponding to the Project Milestone-I is not handed over or lately handed over resulting in the extension of completion of this 5% (five percent) length beyond Scheduled Completion Date, Stage Payment of 10% X 0.95 = 9.5% only is to be achieved by 180th (one hundred and eighty) day. For the avoidance of doubt, it is agreed that recovery of Damages under this Clause 10.3 (ii) shall be without prejudice to the rights of the Authority under this Agreement including the right of Termination thereof. The Parties further agree that Time Extension hereunder shall only be reckoned for and in respect of the affected Works as specified in Clause 10.5 (ii).
(iii) The Authority shall notify the Contractor of its decision to impose Damages in pursuance with the provisions of this Clause 10.3. Provided that no deduction on account of Damages shall be effected by the Authority without notifying the Contractor of its decision to impose the Damages, and taking into consideration the representation, if any, made by the Contractor within 20 (twenty) days of such notice. The Parties expressly agree that the total amount of Damages under Clause 10.3 (ii) shall not exceed 10% (ten percent) of the Contract Price. If the damages exceed 10% (ten percent) of the Contract Price, the Contractor shall be deemed to be in default of this agreement having no cure and the Authority shall be entitled to terminate this Agreement by issuing a Termination Notice in accordance with the provisions of Clause 23.1 (ii).
(iv) In the event that the Contractor fails to achieve the Project Completion within a period of 90 (ninety) days from the Schedule Completion Date set forth in Schedule-J, unless such failure has occurred due to Force Majeure or for reasons solely attributable to the Authority, the contractor shall be deemed to be ineligible for bidding any future projects of the Authority, both as the sole party or as one of the parties of Joint Venture/ Consortium during the period from Scheduled Completion Date to issuance of Completion Certificate. This restriction is applicable if the contract value of the delayed project is not less than Rs. 300 Crore.
Development of the Project 4.1 TSP's obligations in development of the Project:
a. for procuring and maintaining in full force and effect all Consents, Clearances and Permits, required in accordance with Law for development of the Project;
b. for financing, constructing, owning and commissioning each of the Element of the Project for the scope of work set out in Schedule 1 of this Agreement in accordance with:
i. the Electricity Act and the Rules made thereof;
ii. the Grid Code;
iii. the CEA Regulations applicable, and as amended from time to time, for Transmission Lines and sub-stations: • the Central Electricity Authority (Technical Standards for Connectivity to the Grid) Regulations, 2007; • Central Electricity Authority (Technical Standards for construction of Electrical Plants and Electric Lines) Regulation, 2010; • Central Electricity Authority (Grid Standard) Regulations, 2010; • Central Electricity Authority (Safety requirements for construction, operation and maintenance of Electrical Plants and Electrical Lines) Regulation, 2011; • Central Electricity Authority (Measures relating to Safety and Electricity Supply) Regulation, 2010; • Central Electricity Authority (Technical Standards for Communication System in Power System Operation) Regulations, 2020.
iv. Safety/ security Guidelines laid down by the Government;
v. Prudent Utility Practices, relevant Indian Standards and the Law; not later than the Scheduled COD as per Schedule 2 of this Agreement;
c. for entering into a Connection Agreement with the concerned parties in accordance with the Grid Code.
d. for owning the Project throughout the term of this Agreement free and clear of any encumbrances except those expressly permitted under Article 15 of this Agreement;
e. to co-ordinate and liaise with concerned agencies and provide on a timely basis relevant information with regard to the specifications of the Project that may be required for interconnecting the Project with the Interconnection Facilities;
f. for providing all assistance to the Arbitrators as they may require for the performance of their duties and responsibilities;
g. to provide to the Nodal Agency and CEA, on a monthly basis, progress reports with regard to the Project and its execution (in accordance with prescribed form) to enable the CEA to monitor and co-ordinate the development of the Project matching with the Interconnection Facilities;
h. to comply with Ministry of Power order no. 25-11/6/2018 – PG dated 02.07.2020 as well as other Guidelines issued by Govt. of India pertaining to this;
i. to procure the products associated with the Transmission System as per provisions of Public Procurement (Preference to Make in India) orders issued by Ministry of Power vide orders No. 11/5/2018 - Coord. dated 28.07.2020 for transmission sector, as amended from time to time read with Department for Promotion of Industry and Internal Trade (DPIIT) orders in this regard (Procuring Entity as defined in above orders shall deemed to have included Selected Bidder and/ or TSP). Also, to comply with Department of Expenditure, Ministry of Finance vide Order (Public Procurement No 1) bearing File No. 6/18/2019- PPD dated 23.07.2020, Order (Public Procurement No 2) bearing File No. 6/18/2019-PPD dated 23.07.2020 and Order (Public Procurement No. 3) bearing File No. 6/18/2019-PPD, dated 24.07.2020, as amended from time to time, regarding public procurement from a bidder of a country, which shares land border with India;
j. to submit to Nodal Agency information in the prescribed format [To be devised by Nodal Agency] for ensuring compliance to Article 4.1 i) above.
k. to comply with all its obligations undertaken in this Agreement.
4.2 Roles of the Nodal Agency in implementation of the Project:
4.2.1 Subject to the terms and conditions of this Agreement, the Nodal Agency shall be the holder and administrator of this Agreement and shall inter alia:
a. appoint an Independent Engineer within 90 days of the Effective Date
b. provide letters of recommendation to the concerned Indian Governmental Instrumentality, as may be requested by the TSP from time to time, for obtaining the Consents, Clearances and Permits required for the Project;
c. coordinate among TSP and upstream/downstream entities in respect of Interconnection Facilities; and
d. monitor the implementation of the Agreement and take appropriate action for breach thereof including revocation of guarantees, cancellation of Agreement, blacklisting etc
e. provide all assistance to the Arbitrators as required for the performance of their duties and responsibilities; and
f. perform any other responsibility (ies) as specified in this Agreement.
Development of the Property Except as modified by this Agreement, the Development and the Property will be developed in accordance with all applicable local, state, and federal regulations, including but not limited to the City’s ordinances and the zoning regulations applicable to the Property, and such amendments to City ordinances and regulations that that may be applied to the Development and the Property under Chapter 245, Texas Local Government Code, and good engineering practices (the “Applicable Regulations”). If there is a conflict between the Applicable Regulations and the Development Standards, the Development Standards shall control.
CONSTRUCTION OF THE PROJECT/ APARTMENT The Allottee has seen the proposed layout plan, specifications, amenities and facilities of the [Apartment/Plot] and accepted the floor plan, payment plan and the specifications, amenities and facilities [annexed along with this Agreement] which has been approved by the competent authority, as represented by the Promoter. The Promoter shall develop the Project in accordance with the said layout plans, floor plans and specifications, amenities and facilities. Subject to the terms in this Agreement, the Promoter undertakes to strictly abide by such plans approved by the competent Authorities and shall also strictly abide by the bye-laws, FAR and density norms and provisions prescribed by the [Please insert the relevant State laws]and shall not have an option to make any variation /alteration / modification in such plans, other than in the manner provided under the Act, and breach of this term by the Promoter shall constitute a material breach of the Agreement.
Management of the Partnership (a) Except as otherwise expressly provided in this Agreement, the General Partner shall have full, complete and exclusive discretion to manage and control the business of the Partnership for the purposes herein stated, and shall make all decisions affecting the business and assets of the Partnership. Subject to the restrictions specifically contained in this Agreement, the powers of the General Partner shall include, without limitation, the authority to take the following actions on behalf of the Partnership:
(i) to acquire, purchase, own, operate, lease and dispose of any real property and any other property or assets including, but not limited to notes and mortgages, that the General Partner determines are necessary or appropriate or in the best interests of the business of the Partnership;
(ii) to construct buildings and make other improvements on the properties owned or leased by the Partnership;
(iii) to authorize, issue, sell, redeem or otherwise purchase any Partnership Interests or any securities (including secured and unsecured debt obligations of the Partnership, debt obligations of the Partnership convertible into any class or series of Partnership Interests, or options, rights, warrants or appreciation rights relating to any Partnership Interests) of the Partnership;
(iv) to borrow or lend money for the Partnership, issue or receive evidences of indebtedness in connection therewith, refinance, increase the amount of, modify, amend or change the terms of, or extend the time for the payment of, any such indebtedness, and secure such indebtedness by mortgage, deed of trust, pledge or other lien on the Partnership’s assets;
(v) to pay, either directly or by reimbursement, for all Administrative Expenses to third parties or to the General Partner or its Affiliates as set forth in this Agreement;
(vi) to guarantee or become a co-maker of indebtedness of the General Partner or any Subsidiary thereof, refinance, increase the amount of, modify, amend or change the terms of, or extend the time for the payment of, any such guarantee or indebtedness, and secure such guarantee or indebtedness by mortgage, deed of trust, pledge or other lien on the Partnership’s assets;
(vii) to use assets of the Partnership (including, without limitation, cash on hand) for any purpose consistent with this Agreement, including, without limitation, payment, either directly or by reimbursement, of all Administrative Expenses of the General Partner, the Partnership or any Subsidiary of either, to third parties or to the General Partner as set forth in this Agreement;
(viii) to lease all or any portion of any of the Partnership’s assets, whether or not the terms of such leases extend beyond the termination date of the Partnership and whether or not any portion of the Partnership’s assets so leased are to be occupied by the lessee, or, in turn, subleased in whole or in part to others, for such consideration and on such terms as the General Partner may determine;
(ix) to prosecute, defend, arbitrate, or compromise any and all claims or liabilities in favor of or against the Partnership, on such terms and in such manner as the General Partner may reasonably determine, and similarly to prosecute, settle or defend litigation with respect to the Partners, the Partnership, or the Partnership’s assets;
(x) to file applications, communicate, and otherwise deal with any and all governmental agencies having jurisdiction over, or in any way affecting, the Partnership’s assets or any other aspect of the Partnership business;
(xi) to make or revoke any election permitted or required of the Partnership by any taxing authority;
(xii) to maintain such insurance coverage for public liability, fire and casualty, and any and all other insurance for the protection of the Partnership, for the conservation of Partnership assets, or for any other purpose convenient or beneficial to the Partnership, in such amounts and such types, as it shall determine from time to time;
(xiii) to determine whether or not to apply any insurance proceeds for any property to the restoration of such property or to distribute the same;
(xiv) to establish one or more divisions of the Partnership, to hire and dismiss employees of the Partnership or any division of the Partnership, and to retain legal counsel, accountants, consultants, real estate brokers, and such other persons, as the General Partner may deem necessary or appropriate in connection with the Partnership business and to pay therefor such reasonable remuneration as the General Partner may deem reasonable and proper;
(xv) to retain other services of any kind or nature in connection with the Partnership business, and to pay therefor such remuneration as the General Partner may deem reasonable and proper;
(xvi) to negotiate and conclude agreements on behalf of the Partnership with respect to any of the rights, powers and authority conferred upon the General Partner;
(xvii) to maintain accurate accounting records and to file promptly all federal, state and local income tax returns on behalf of the Partnership;
(xviii) to distribute Partnership cash or other Partnership assets in accordance with this Agreement;
(xix) to form or acquire an interest in, and contribute property to, any further limited or general partnerships, limited liability companies, joint ventures or other relationships that it deems desirable (including, without limitation, the acquisition of interests in, and the contributions of property to, its Subsidiaries and any other Person in which it has an equity interest from time to time);
(xx) to establish Partnership reserves for working capital, capital expenditures, contingent liabilities, or any other valid Partnership purpose;
(xxi) to merge, consolidate or combine the Partnership with or into another Person;
(xxii) to do any and all acts and things necessary or prudent to ensure that the Partnership will not be classified as a “publicly traded partnership” for purposes of Section 7704 of the Code; and
(xxiii) to take such other action, execute, acknowledge, swear to or deliver such other documents and instruments, and perform any and all other acts that the General Partner deems necessary or appropriate for the formation, continuation and conduct of the business and affairs of the Partnership (including, without limitation, all actions consistent with allowing the General Partner at all times to qualify as a REIT unless the General Partner voluntarily terminates its REIT status) and to possess and enjoy all of the rights and powers of a general partner as provided by the Act.
(b) Except as otherwise provided herein, to the extent the duties of the General Partner require expenditures of funds to be paid to third parties, the General Partner shall not have any obligations hereunder except to the extent that partnership funds are reasonably available to it for the performance of such duties, and nothing herein contained shall be deemed to authorize or require the General Partner, in its capacity as such, to expend its individual funds for payment to third parties or to undertake any individual liability or obligation on behalf of the Partnership.
Completion of Concrete Pours and Emergency Work (a) Except as provided in this sub-clause an Employee shall nor work or be required to work in the rain.
(b) Employees shall not be required to start a concrete pour in Inclement Weather.
(c) Where a concrete pour has been commenced prior to the commencement of a period of Inclement Weather Employees may be required to complete such concrete pour to a practical stage and for such work shall be paid at the rate of double time calculated to the next hour, and in the case of wet weather shall be provided with adequate wet weather gear.
(d) If an Employee’s clothes become wet as a result of working in the rain during a concrete pour the Employee shall, unless the Employee has a change of dry working clothes available, be allowed to go home without loss of pay.
(e) The provisions of clauses 32.7(c) and 32.7(d) hereof shall also apply in the case of emergency work where the Employees concerned and their delegates agree that the work is of an emergency nature and can start and/or proceed.
Completion of the Project The Participating County acknowledges it is obligated to undertake and complete the design and construction of the Project in compliance with all of the applicable terms and conditions of the Project Documents and the Participating County agrees to use its best efforts to cause the completion of design and construction of the Project in compliance with the applicable terms and conditions of such documents. The Participating County agrees to complete the Project in accordance with this Agreement and consistent with the scope, cost and schedule established by the Board and attached hereto in Exhibit A, as such scope, cost and schedule may be modified with the approval of Finance and the recognition of the Board.
Construction of the Project The Allottee has seen the proposed layout plan, specifications, amenities and facilities of the Apartment/ Plot and accepted the floor plan, payment plan and the specification, amenities and facilities annexed along with this Agreement which has been approved by the competent authority, as represented by the Promoter. The Promoter shall develop the Project in accordance with the said layout plans, floor plans and specifications, amenities and facilities. Subject to the terms in this Agreement, the Promoter undertakes to strictly abide by such plans approved by the competent authorities and shall also strictly abide by the bye-laws, FAR, and density norms and provisions prescribed by the relevant building bye-laws and shall not have an option to make any variation/ alteration/ modification in such plans, other than in the manner provided under the Act, and breach of this term by the Promoter shall constitute a material breach of this Agreement.
MAINTENANCE OF THE SAID BUILDING / APARTMENT / PROJECT The Promoter shall be responsible to provide and maintain essential services in the Project till the taking over of the maintenance of the project by the association of the allottees. The cost of such maintenance has been included in the Total Price of the [Apartment/Plot].
Withdrawal of General Partner (a) The General Partner may not Withdraw (other than as a result of an Involuntary Withdrawal) without the Consent of the Special Limited Partner. Withdrawal shall be conditioned upon the agreement of the Special Limited Partner to be admitted as a successor General Partner, or if the Special Limited Partner declines to be admitted as a successor General Partner then on the agreement of one or more Persons who satisfy the requirements of Section 13.5 of this Agreement to be admitted as successor General Partner(s).
(b) Each General Partner shall indemnify and hold harmless the Partnership and all Partners from its Withdrawal in violation of Section 13.1(a) hereof. Each General Partner shall be liable for damages to the Partnership resulting from its Withdrawal in violation of Section 13.1(a).
