General Conditions Costs Contractor is entitled to receive payment for the actual cost of the allowable General Conditions items incurred after receipt of a Notice to Proceed with Construction from Owner through Substantial Completion of the Project, plus 30 calendar days. Contractor is not entitled to reimbursement for General Conditions Costs incurred before receipt of the Notice to Proceed. General Conditions Costs incurred after Substantial Completion, plus 30 calendar days, must be approved in advance by Owner. Allowable General Conditions items are identified below and in Exhibit “D” attached to this Agreement. These items shall be included in the General Conditions Cost amount shown as a line item in the Guaranteed Maximum Price Proposal and as detailed on the Schedule of Values. Items not specifically included below or in Exhibit “D” will not be allowed as General Condition Costs.
Payments and Completion Payments may be withheld because of (1) defective work not remedied; (2) failure of contractor to make proper payments to subcontractors, workers, or suppliers; (3) persistent failure to carry out work in acceptance with this Agreement or these general conditions, or (4) legal claims. Final payment will be due after complete release of any and all liens arising out of the contract or submission of receipts or other evidence of payment covering all subcontractors or suppliers who could file such a lien. The contractor agrees to indemnify the Owner against such liens and will refund all monies including costs and reasonable attorney’s fees paid by the owner in discharging the liens. A 10 percent holdback is required by the lender to assure the work has been properly completed and there are no liens against the property.
FINAL COMPLETION AND FINAL PAYMENT 9.9.1 Upon receipt of written notice that the Work is ready for final inspection and acceptance and upon receipt of a final Application for Payment, the Architect will promptly make such
9.9.2 Neither the final payment nor the remaining retained percentage shall become due until the Contractor submits to the Architect (1) an affidavit that all payrolls, bills for materials and equipment, and other indebtedness connected with the Work for which the State or its property might in any way be responsible, have been paid or otherwise satisfied; (2) consent of surety, if any, to final payment; (3) Other data establishing payment or satisfaction of all such obligations, including, but not limited to, receipts, releases, or other supporting documentation. and (4) final waivers of liens arising out of the Contract, to the extent and in such form as may be designated by the State. If any Subcontractor refuses to furnish a release or waiver required by the State, the Contractor may furnish a bond satisfactory to the State to indemnify him against any such lien. If any such lien remains unsatisfied after all payments are made, the Contractor shall refund to the State all moneys that the latter may be compelled to pay in discharging such lien, including all costs and reasonable attorneys' fees.
9.9.3 If, after Substantial Completion of the Work, final completion thereof is materially delayed through no fault of the Contractor or by the issuance of Change Orders affecting final completion, and the Architect so confirms, the State shall, upon application by the Contractor and certification by the Architect, and without terminating the Contract, make payment of the balance due for that portion of the Work fully completed and accepted. If the remaining balance for Work not fully completed or corrected is less than the retainage stipulated in the Contract Documents, and if bonds have been furnished as required by the Contract Documents, the written consent of the surety to the payment of the balance due for that portion of the Work fully completed and accepted shall be submitted by the Contractor to the Architect prior to certification of such payment. Such payment shall be made under the terms and conditions governing final payment, except that it shall not constitute a waiver of claims.
9.9.4 The making of final payment shall constitute a waiver of all claims by the State except those arising from:
(a) unsettled liens,
(b) faulty or defective Work appearing after Substantial Completion,
(c) failure of the Work to comply with the requirements of the Contract Documents, or
(d) terms of any special warranties required by the Contract Documents.
9.9.5 The acceptance of final payment shall constitute a waiver of all claims by the Contractor except those previously made in writing and identified by the Contractor as unsettled at the time of the final Application for Payment.
Reconciliation and Final Payment Seller and Buyer shall reasonably cooperate after Closing to make a final determination of the allocations and prorations required under this Contract within one hundred eighty (180) days after the Closing Date. Upon the final reconciliation of the allocations and prorations under this Section, the party which owes the other party any sums hereunder shall pay such party such sums within ten (10) days after the reconciliation of such sums. The obligations to calculate such prorations, make such reconciliations and pay any such sums shall survive the Closing.
How to Obtain Warranty Service The Warranty Holder must inspect the Flooring for Manufacturing Defects caused by improper milling, grading, staining, and coating, and report any such defects to Cali Bamboo, prior to installation of the Flooring. To obtain warranty service, the Warranty Holder must contact Cali Bamboo’s Customer Experience Department: xxxxxxxxxxxxxxx@xxxxxxxxxx.xxx/ 000- 000-0000. Warranty claims must be received within 30 calendar days after the Warranty Holder identifies the Manufacturing Defect or other basis for a warranty claim. To be covered under this Cali Bamboo limited warranty, the Warranty Holder must provide documentation of sales order and proof that the Flooring was properly installed in accordance with the Installation Guide (defined below). Cali Bamboo reserves the right to retain a certified and independent National Wood Flooring Association inspector (“NWFA Inspector”) to verify the Warranty Holder’s warranty claims. The determination of the NWFA Inspector regarding the warranty claim is not binding on either Cali Bamboo or on the Warranty Holder. A determination that does not verify the warranty claim shall not affect the Warranty Holder’s right to submit its claim to arbitration in accordance with the terms of the Arbitration Agreement (as defined in Cali Bamboo’s Terms and Conditions of Purchase). The performance of the inspection, however, if requested by Xxxx Xxxxxx and assuming that Xxxx Xxxxxx advances the full cost of the inspection as described above, is a requirement for the Warranty Holder to submit a warranty claim to arbitration under the Arbitration Agreement. For specific instructions on how to obtain warranty service for defective Flooring, visit the Cali Bamboo website xxxxx://xxx.xxxxxxxxxx.xxx/flooring-warranty/. This limited warranty covers Flooring that is both (i) installed with strict adherence to Cali Bamboo’s Odyssey Engineered flooring installation guide found online at xxxxx://xxx.xxxxxxxxxx.xxx/flooring-installation/ (the “Installation Guide”) and
Authorization of Overtime All overtime work must be authorized by the employee's immediate Manager.
Notifications of Outages and Maintenance In the event that a Registry Operator plans maintenance, it will provide notice to the ICANN emergency operations department, at least, twenty-‐four (24) hours ahead of that maintenance. ICANN’s emergency operations department will note planned maintenance times, and suspend Emergency Escalation services for the monitored services during the expected maintenance outage period. If Registry Operator declares an outage, as per its contractual obligations with ICANN, on services under a service level agreement and performance requirements, it will notify the ICANN emergency operations department. During that declared outage, ICANN’s emergency operations department will note and suspend emergency escalation services for the monitored services involved.
Authorization and Application of Overtime An employee who is required to work overtime shall be entitled to overtime compensation when the overtime worked is authorized in advance.
Governing Law; Submission to Process EXCEPT TO THE EXTENT THAT THE LAW OF ANOTHER JURISDICTION IS EXPRESSLY ELECTED IN A TRANSACTION DOCUMENT, THIS AGREEMENT AND THE OTHER TRANSACTION DOCUMENTS, SHALL BE GOVERNED BY AND CONSTRUED IN ACCORDANCE WITH THE INTERNAL LAWS OF THE STATE OF NEW YORK, WITHOUT REGARD TO PRINCIPLES OF CONFLICTS OF LAW. EACH OF BIONOVA AND SAVIA HEREBY IRREVOCABLY SUBMITS ITSELF AND EACH OTHER RELATED PERSON TO THE NON-EXCLUSIVE JURISDICTION OF THE STATE AND FEDERAL COURTS SITTING IN THE STATE OF NEW YORK AND THE COUNTY OF NEW YORK AND AGREES AND CONSENTS THAT SERVICE OF PROCESS MAY BE MADE UPON IT OR ANY OF ITS SUBSIDIARIES IN ANY LEGAL PROCEEDING RELATING TO THE TRANSACTION DOCUMENTS BY ANY MEANS ALLOWED UNDER NEW YORK OR FEDERAL LAW. EACH OF BIONOVA AND SAVIA IRREVOCABLY WAIVES, TO THE FULLEST EXTENT PERMITTED BY APPLICABLE LAW, ANY OBJECTION THAT IT MAY NOW OR HEREAFTER HAVE TO THE LAYING OF THE VENUE OF ANY SUCH PROCEEDING BROUGHT IN SUCH A COURT AND ANY CLAIM THAT ANY SUCH PROCEEDING BROUGHT IN SUCH A COURT HAS BEEN BROUGHT IN AN INCONVENIENT FORUM.
Examination of Implementation 1. Without prejudice to the procedures set out in Article 188 (Compensation), once the period of time set out in paragraph 3 of Article 186 (Implementation of the Report) has expired, and there is disagreement between the disputing Parties as to the existence or consistency of the measures taken to comply with the Panel report, such dispute shall be referred to the original Panel wherever possible. If not possible, the procedure pursuant to Article 179 (Panel Selection) shall be followed to appoint a new Panel, in which event the periods set out thereof shall be reduced by half (22).
2. This Panel shall issue its report on the matter within 60 days after the date of the referral of the matter to it. When the Panel considers that it cannot provide its report within this timeframe, it shall inform the Parties in writing of the reasons for the delay together with an estimate of the period within which it will submit its report. Any delay shall not exceed a further period of 30 days unless the Parties otherwise agree.
