Force Majeure Events a) Neither Party shall be responsible or liable for or deemed in breach hereof because of any delay or failure in the performance of its obligations hereunder (except for obligations to pay money due prior to occurrence of Force Majeure events under this Agreement) or failure to meet milestone dates due to any event or circumstance (a "Force Majeure Event") beyond the reasonable control of the Party experiencing such delay or failure, including the occurrence of any of the following:
i) acts of God;
ii) typhoons, floods, lightning, cyclone, hurricane, drought, famine, epidemic, plague or other natural calamities;
iii) acts of war (whether declared or undeclared), invasion or civil unrest;
iv) any requirement, action or omission to act pursuant to any judgment or order of any court or judicial authority in India (provided such requirement, action or omission to act is not due to the breach by the SPG or of any Law or any of their respective obligations under this Agreement);
v) inability despite complying with all legal requirements to obtain, renew or maintain required licenses or Legal Approvals;
vi) earthquakes, explosions, accidents, landslides; fire;
vii) expropriation and/or compulsory acquisition of the Project in whole or in part by Government Instrumentality;
viii) chemical or radioactive contamination or ionizing radiation; or
ix) damage to or breakdown of transmission facilities of GETCO/ DISCOMs;
x) Exceptionally adverse weather condition which are in excess of the statistical measure of the last hundred (100) years.
Termination for continuing Force Majeure Event Either Party may, by written notice to the other, terminate this Framework Agreement if a Force Majeure Event endures for a continuous period of more than one hundred and twenty (120) Working Days.
Duty to report Force Majeure Event 21.5.1 Upon occurrence of a Force Majeure Event, the Affected Party shall by notice report such occurrence to the other Party forthwith. Any notice pursuant hereto shall include full particulars of:
(a) the nature and extent of each Force Majeure Event which is the subject of any claim for relief under this Article 21 with evidence in support thereof;
(b) the estimated duration and the effect or probable effect which such Force Majeure Event is having or will have on the Affected Party’s performance of its obligations under this Agreement;
(c) the measures which the Affected Party is taking or proposes to take for alleviating the impact of such Force Majeure Event; and
(d) any other information relevant to the Affected Party’s claim.
21.5.2 The Affected Party shall not be entitled to any relief for or in respect of a Force Majeure Event unless it shall have notified the other Party of the occurrence of the Force Majeure Event as soon as reasonably practicable, and in any event no later than 10 (ten) days after the Affected Party knew, or ought reasonably to have known, of its occurrence, and shall have given particulars of the probable material effect that the Force Majeure Event is likely to have on the performance of its obligations under this Agreement.
21.5.3 For so long as the Affected Party continues to claim to be materially affected by such Force Majeure Event, it shall provide the other Party with regular (and not less than weekly) reports containing information as required by Clause 21.5.1, and such other information as the other Party may reasonably request the Affected Party to provide.
Reporting of Non-Force Majeure Events Each Party (the “Notifying Party”) shall notify the other Parties when the Notifying Party becomes aware of its inability to comply with the provisions of this Agreement for a reason other than a Force Majeure event. The Parties agree to cooperate with each other and provide necessary information regarding such inability to comply, including the date, duration, reason for the inability to comply, and corrective actions taken or planned to be taken with respect to such inability to comply. Notwithstanding the foregoing, notification, cooperation or information provided under this Article shall not entitle the Party receiving such notification to allege a cause for anticipatory breach of this Agreement.
Force Majeure If by reason of Force Majeure, either party hereto shall be rendered unable wholly or in part to carry out its obligations under this Agreement through no fault of its own then such party shall give notice and full particulars of Force Majeure in writing to the other party within a reasonable time after occurrence of the event or cause relied upon. Upon delivering such notice, the obligation of the affected party, so far as it is affected by such Force Majeure as described, shall be suspended during the continuance of the inability then claimed but for no longer period, and such party shall endeavor to remove or overcome such inability with all reasonable dispatch. In the event that Vendor’s obligations are suspended by reason of Force Majeure, all TIPS Sales accepted prior to the Force Majeure event shall be the legal responsibility of Vendor and the terms of the TIPS Sale Supplemental Agreement shall control Vendor’s failure to fulfill for a Force Majeure event.
Notification of Force Majeure Event 11.5.1 The Affected Party shall give notice to the other Party of any event of Force Majeure as soon as reasonably practicable, but not later than seven (7) days after the date on which such Party knew or should reasonably have known of the commencement of the event of Force Majeure. If an event of Force Majeure results in a breakdown of communications rendering it unreasonable to give notice within the applicable time limit specified herein, then the Party claiming Force Majeure shall give such notice as soon as reasonably practicable after reinstatement of communications, but not later than one (1) day after such reinstatement. Provided that, such notice shall be a pre-condition to the Affected Party’s entitlement to claim relief under this Agreement. Such notice shall include full particulars of the event of Force Majeure, its effects on the Party claiming relief and the remedial measures proposed. The Affected Party shall give the other Party regular reports on the progress of those remedial measures and such other information as the other Party may reasonably request about the Force Majeure.
11.5.2 The Affected Party shall give notice to the other Party of (i) the cessation of the relevant event of Force Majeure; and (ii) the cessation of the effects of such event of Force Majeure on the performance of its rights or obligations/ roles under this Agreement, as soon as practicable after becoming aware of each of these cessations.
Events of Force Majeure Neither Party shall be held liable or responsible to the other Party nor be deemed to be in default under, or in breach of any provision of, this Agreement for failure or delay in fulfilling or performing any obligation of this Agreement when such failure or delay is due to force majeure, and without the fault or negligence of the Party so failing or delaying. For purposes of this Agreement, force majeure is defined as causes beyond the control of the Party, including, without limitation, acts of God; acts, regulations, or laws of any government; war; civil commotion; destruction of production facilities or materials by fire, flood, earthquake, explosion or storm; labor disturbances; epidemic; and failure of public utilities or common carriers. In such event Medistem or Licensee, as the case may be, shall immediately notify the other Party of such inability and of the period for which such inability is expected to continue. The Party giving such notice shall thereupon be excused from such of its obligations under this Agreement as it is thereby disabled from performing for so long as it is so disabled and the 30 days thereafter. To the extent possible, each Party shall use reasonable efforts to minimize the duration of any force majeure.
Tenant’s Remedies Notwithstanding any other provision of this Lease, if any default hereunder by Landlord is not cured within the applicable cure period provided in Paragraph 20(c) or any other applicable cure period provided in this Lease (including any Mortgagee’s additional cure period), Tenant’s exclusive remedies shall be (i) an action for specific performance, or (ii) an action for actual damages. Notwithstanding any other provision of this Lease, the liability of Landlord to Tenant for any breach or default by Landlord under the terms of this Lease, or for any other matter related to this Lease or to the Premises or Project, shall be limited to Tenant’s actual direct, but not consequential, damages therefor, and any judgment against Landlord in connection therewith shall be recoverable only from the interest of Landlord in the Buildings. Tenant hereby waives any claim for damages for any disturbance, loss of business, nuisance, injury or inconvenience to or interference with Tenant’s business, any loss of occupancy or quiet enjoyment of the Premises, and any other loss arising from Landlord’s entry and acts pursuant to Paragraph 18 or otherwise with respect to any act, omission or breach of Landlord. Without limiting the preceding sentence, in no event shall Landlord be liable to Tenant for any consequential damages, including, without limitation, any losses arising from any interruption of Tenant’s business, or for lost profits, or for charges or expenses which continue but would have been earned if the business had gone on without interruption, or for any other loss, claim, cost, expense or damage which would be covered by a standard policy of business interruption insurance. Landlord, or if Landlord is a partnership its partners whether general or limited, or if Landlord is a corporation its directors, officers or shareholders, or if Landlord is a limited liability company its members or managers, shall never be personally liable for any such judgment. Any lien obtained to enforce such judgment and any levy of execution thereon shall be subject and subordinate to any Mortgage (excluding any Mortgage which was created as part of an effort to defraud creditors, i.e., a fraudulent conveyance); provided, however that any such judgment and any such levy of execution thereon shall not be subject or subordinated to any Mortgage that is created or recorded in the official records of the county in which the Project is located after the date of the judgment giving rise to such lien. Landlord’s interest in the Buildings shall include any insurance proceeds received by Landlord which are not controlled by any Mortgagee or other lender. Tenant hereby waives the benefit of any Laws granting it (A) the right to perform Landlord’s obligations, or (B) the right to terminate this Lease or withhold Rent on account of any Landlord default, including, without limitation, Sections 1932(1), 1941 and 1942 of the California Civil Code.
Force Majeure, Notice of Delay, and No Damages for Delay The Contractor will not be responsible for delay resulting from its failure to perform if neither the fault nor the negligence of the Contractor or its employees or agents contributed to the delay and the delay is due directly to acts of God, wars, acts of public enemies, strikes, fires, floods, or other similar cause wholly beyond the Contractor’s control, or for any of the foregoing that affect subcontractors or suppliers if no alternate source of supply is available to the Contractor. In case of any delay the Contractor believes is excusable, the Contractor will notify the Department or Customer in writing of the delay or potential delay and describe the cause of the delay either (1) within 10 days after the cause that creates or will create the delay first arose, if the Contractor could reasonably foresee that a delay could occur as a result, or (2) if delay is not reasonably foreseeable, within five days after the date the Contractor first had reason to believe that a delay could result. The foregoing will constitute the Contractor’s sole remedy or excuse with respect to delay. Providing notice in strict accordance with this paragraph is a condition precedent to such remedy. No claim for damages will be asserted by the Contractor. The Contractor will not be entitled to an increase in the Contract price or payment of any kind from the Department or Customer for direct, indirect, consequential, impact or other costs, expenses or damages, including but not limited to costs of acceleration or inefficiency, arising because of delay, disruption, interference, or hindrance from any cause whatsoever. If performance is suspended or delayed, in whole or in part, due to any of the causes described in this paragraph, after the causes have ceased to exist the Contractor will perform at no increased cost, unless the Department or Customer determines, in its sole discretion, that the delay will significantly impair the value of the Contract to the State of Florida or to Customers, in which case the Department or Customer may (1) accept allocated performance or deliveries from the Contractor, provided that the Contractor grants preferential treatment to Customers with respect to commodities or contractual services subjected to allocation, or (2) purchase from other sources (without recourse to and by the Contractor for the related costs and expenses) to replace all or part of the commodity or contractual services that are the subject of the delay, which purchases may be deducted from the Contract quantity, or (3) terminate the Contract in whole or in part.
Force Majeure Event 16.1 If a Force Majeure Event gives rise to a failure or delay in either party performing any obligation under this Agreement (other than any obligation to make a payment), that obligation will be suspended for the duration of the Force Majeure Event.
16.2 A party that becomes aware of a Force Majeure Event which gives rise to, or which is likely to give rise to, any failure or delay in that party performing any obligation under this Agreement, must:
(a) promptly notify the other; and
(b) inform the other of the period for which it is estimated that such failure or delay will continue.
16.3 A party whose performance of its obligations under this Agreement is affected by a Force Majeure Event must take reasonable steps to mitigate the effects of the Force Majeure Event.
