RETURNS, CLAIMS, REFUNDS The customer shall immediately upon receipt of goods supplied fully inspect such goods and satisfy itself that the goods are correct. If the customer is unsatisfied, the customer must immediately contact the Company and communicate all details of such dissatisfaction. Unless the above procedure is followed the Company is entitled to assume that the goods supplied are correct and no returns claims for refunds will be permitted or made.
LIENS, CLAIMS AND ENCUMBRANCES The Contractor warrants and represents that all materials, equipment or services delivered herein are free and clear of all liens, claims, or encumbrances of any kind.
Indemnification Claims (a) In the event that any of the Parties are entitled, or seek to assert rights, to indemnification under this Article VI, the Party or Parties seeking indemnification (the “Indemnified Parties”) shall give written notification to the other Party or Parties (the “Indemnifying Parties”) of the commencement of any suit or proceeding relating to a third party claim for which indemnification pursuant to this Article VI may be sought. Such notification shall be given within 20 Business Days after receipt by the Indemnified Parties of notice of such suit or proceeding, and shall describe in reasonable detail (to the extent known by the Indemnified Parties) the facts constituting the basis for such suit or proceeding and the amount of the claimed damages; provided, however, that no delay on the part of the Indemnified Parties in notifying the Indemnifying Parties shall relieve the Indemnifying Parties of any liability or obligation hereunder except to the extent of any damage or liability caused by or arising out of such failure. Within 20 days after delivery of such notification, the Indemnifying Parties may, upon written notice thereof to the Indemnified Parties seeking indemnification, assume control of the defense of such suit or proceeding with counsel reasonably satisfactory to the Indemnified Party seeking indemnification; provided that the Indemnifying Parties may not assume control of the defense of a suit or proceeding involving criminal liability or in which equitable relief is sought against the Indemnified Party seeking indemnification. If the Indemnifying Parties do not so assume control of such defense, the Indemnified Parties seeking indemnification shall control such defense. The Party not controlling such defense (the “Non-Controlling Party”) may participate therein at its own expense; provided that if the Indemnifying Parties assumes control of such defense and the Indemnified Parties seeking indemnification reasonably concludes that the Indemnifying Parties and the Indemnified Parties seeking indemnification have conflicting interests or different defenses available with respect to such suit or proceeding, the reasonable fees and expenses of counsel to the Indemnified Parties shall be considered “Damages” for purposes of this Agreement. The Party or Parties controlling such defense (the “Controlling Party”) shall keep the Non-Controlling Party advised of the status of such suit or proceeding and the defense thereof and shall consider in good faith recommendations made by the Non-Controlling Party with respect thereto. The Non-Controlling Party shall furnish the Controlling Party with such information as it may have with respect to such suit or proceeding (including copies of any summons, complaint or other pleading which may have been served on such party and any written claim, demand, invoice, billing or other document evidencing or asserting the same) and shall otherwise cooperate with and assist the Controlling Party as reasonably needed in the defense of such suit or proceeding at the sole cost and expense of the Indemnifying Parties under Section 6.1 or 6.2, which cost and expense shall be considered “Damages” for purposes of this Agreement. The Indemnifying Parties shall not agree to any settlement of, or the entry of any judgment arising from, any such suit or proceeding without the prior written consent of the Indemnified Parties, which shall not be unreasonably withheld or delayed; provided that the consent of the Indemnified Parties shall not be required if the Indemnifying Parties agrees in writing to pay any amounts payable pursuant to such settlement or judgment and such settlement or judgment includes a complete release of the Indemnified Parties from further liability and has no other materially adverse effect on the Indemnified Parties. The Indemnified Parties shall not agree to any settlement of, or the entry of any judgment arising from, any such suit or proceeding without the prior written consent of the Indemnifying Parties, which shall not be unreasonably withheld or delayed.
Liability Calculation Method Per Claim Unless subject to a fixed dollar copayment, the calculation of Member liability on claims for Out-of-Area Covered Health Care Services processed through the BlueCard Program will be based on the lower of the provider’s billed charges or the negotiated price made available to Blue Shield by the Host Blue. Host Blues determine a negotiated price, which is reflected in the terms of each Host Blue’s health care provider contracts. The negotiated price made available to Blue Shield by the Host Blue may be represented by one of the following:
Product Warranty Claims When we receive a valid warranty claim for an HP hardware or software product, HP will either repair the relevant defect or replace the product. If HP is unable to complete the repair or replace the product within a reasonable time, Customer will be entitled to a full refund upon the prompt return of the product to HP (if hardware) or upon written confirmation by Customer that the relevant software product has been destroyed or permanently disabled. HP will pay for shipment of repaired or replaced products to Customer and Customer will be responsible for return shipment of the product to HP.
Warranty Claims This Contractual Warranty is provided by Xxxxxxxxx Electric and covers defects in workmanship and materials in your Product. This warranty period lasts from the date of purchase at the point of sale to you, the original end user, unless otherwise agreed in writing (the "Warranty Period"). This Contractual Warranty is transferable to subsequent owners but only for the unexpired portion of the Warranty Period.
Accountholder’s Indemnification Obligation You understand and agree that you are required to indemnify us and hold us harmless against any and all claims, actions, damages, liabilities, costs and expenses, including reasonable attorneys’ fees and expenses, arising out of your use of the Services and/or breach of this Agreement. You understand and agree that this paragraph shall survive termination of this Agreement.
Indemnification for Certain Claims The Party providing services hereunder, its affiliates and its parent company, shall be indemnified, defended and held harmless by the Party receiving services hereunder against any claim, loss or damage arising from the receiving company’s use of the services provided under this Agreement pertaining to (1) claims for libel, slander or invasion of privacy arising from the content of the receiving company’s own communications, or (2) any claim, loss or damage claimed by the End User of the Party receiving services arising from such company’s use or reliance on the providing company’s services, actions, duties, or obligations arising out of this Agreement.
PRIORITY HIRING CONSIDERATIONS If this Contract includes services in excess of $200,000, the Contractor shall give priority consideration in filling vacancies in positions funded by the Contract to qualified recipients of aid under Welfare and Institutions Code Section 11200 in accordance with Pub. Contract Code §10353.
Submitting False Claims The full text of San Francisco Administrative Code Chapter 21, Section 21.35, including the enforcement and penalty provisions, is incorporated into this Agreement. Pursuant to San Francisco Administrative Code §21.35, any contractor or subcontractor who submits a false claim shall be liable to the City for the statutory penalties set forth in that section. A contractor or subcontractor will be deemed to have submitted a false claim to the City if the contractor or subcontractor: (a) knowingly presents or causes to be presented to an officer or employee of the City a false claim or request for payment or approval;
