CONTRACTOR'S RESPONSIBILITY 1.1. The Basic Services to be performed by CONTRACTOR hereunder is the Citywide Landscape Maintenance.
1.2. The CONTRACTOR agrees to obtain and maintain throughout the period of this Agreement all such licenses as are required to do business in the State of Florida, the City of Naples, and in Xxxxxxx County, Florida, including, but not limited to, all licenses required by the respective state boards and other governmental agencies responsible for regulating and licensing the professional services to be provided and performed by the CONTRACTOR pursuant to this Agreement.
1.3. The CONTRACTOR agrees that, when the services to be provided hereunder relate to a professional service which, under Florida Statutes, requires a license, certificate of authorization or other form of legal entitlement to practice such services, it shall employ and/or retain only qualified personnel to provide such services.
1.4. CONTRACTOR agrees to employ and designate, in writing, within five (5) calendar days after receiving its Notice to Proceed, a qualified licensed professional to serve as the CONTRACTOR's project manager (hereinafter referred to as the "Project Manager"). The Project Manager shall be authorized and responsible to act on behalf of the CONTRACTOR with respect to directing, coordinating and administering all aspects of the services to be provided and performed under this Agreement.
1.5. The CONTRACTOR has represented to the OWNER that it has expertise in the type of professional services that will be required for the Project. The CONTRACTOR agrees that all services to be provided by CONTRACTOR pursuant to this Agreement shall be subject to the OWNER's review and approval and shall be in accordance with the generally accepted standards of professional practice in the State of Florida, as well as in accordance with all published laws, statutes, ordinances, codes, rules, regulations and requirements of any governmental agencies which regulate or have jurisdiction over the Project or the services to be provided and performed by CONTRACTOR hereunder. In the event of any conflicts in these requirements, the CONTRACTOR shall notify the OWNER of such conflict and utilize its best professional judgment to advise OWNER regarding resolution of the conflict.
1.6. CONTRACTOR agrees not to divulge, furnish or make available to any third person, firm or organization, without OWNER's prior written consent, or unless incident to the proper performance of the CONTRACTOR's obligations hereunder, or in the course of judicial or legislative proceedings where such information has been properly subpoenaed, any non-public information concerning the services to be rendered by CONTRACTOR hereunder, and CONTRACTOR shall require all of its employees, agents, subconsultants and subcontractors to comply with the provisions of this paragraph.
Construction Responsibilities The party named in Article 1, Responsible Parties, under AGREEMENT is responsible for the following:
A. Advertise for construction bids, issue bid proposals, receive and tabulate the bids, and award and administer the contract for construction of the Project. Administration of the contract includes the responsibility for construction engineering and for issuance of any change orders, supplemental agreements, amendments, or additional work orders that may become necessary subsequent to the award of the construction contract. In order to ensure federal funding eligibility, projects must be authorized by the State prior to advertising for construction.
B. If the State is the responsible party, the State will use its approved contract letting and award procedures to let and award the construction contract.
C. If the Local Government is the responsible party, the Local Government shall submit its contract letting and award procedures to the State for review and approval prior to letting.
D. If the Local Government is the responsible party, the State must concur with the low bidder selection before the Local Government can enter into a contract with the vendor.
E. If the Local Government is the responsible party, the State must review and approve change orders.
F. Upon completion of the Project, the party responsible for constructing the Project will issue and sign a “Notification of Completion” acknowledging the Project’s construction completion and submit certification(s) sealed by a professional engineer(s) licensed in the State of Texas.
G. For federally funded contracts, the parties to this Agreement will comply with federal construction requirements cited in 23 CFR Part 635 and with requirements cited in 23 CFR Part 633, and shall include the latest version of Form “FHWA-1273” in the contract bidding documents. If force account work will be performed, a finding of cost effectiveness shall be made in compliance with 23 CFR 635, Subpart B.
Engineers Responsibility The Engineer shall be responsible for the accuracy of its work and shall promptly make necessary revisions or corrections resulting from its errors, omissions, or negligent acts without compensation. The Engineer will not be relieved of the responsibility for subsequent correction of any such errors or omissions or for clarification of any ambiguities until after the construction phase of the project has been completed.
Contractor’s Responsibilities Unless stated specifically to the contrary in the tender with full supporting explanations, the contractor will be deemed to have concurred as a practical manufacturer with the design and layout of the works as being sufficient to ensure reliability and safety in operation, freedom from undue stresses and satisfactory performance in all other essentials as a working material.
Supplier’s Responsibilities 14.1 The Supplier shall supply all the Goods and Related Services included in the Scope of Supply in accordance with GCC Clause 12, and the Delivery and Completion Schedule, as per GCC Clause 13.
Owner’s Responsibility Proper preventative maintenance of the exterior and interior of the vehicle is the responsibility of the owner. See the owner’s manual(s) for proper care instructions. Defects or damage as a result of improper care or maintenance are not covered by this warranty agreement.
OWNER’S RESPONSIBILITIES 2.1. The Owner shall designate in writing a project coordinator to act as OWNER's representative with respect to the services to be rendered under this Agreement (hereinafter referred to as the "Project Coordinator"). The Project Coordinator shall have authority to transmit instructions, receive information, interpret and define OWNER's policies and decisions with respect to CONTRACTOR's services for the Project. However, the Project Coordinator is not authorized to issue any verbal or written orders or instructions to the CONTRACTOR that would have the effect, or be interpreted to have the effect, of modifying or changing in any way whatever:
(a) The scope of services to be provided and performed by the CONTRACTOR hereunder;
(b) The time the CONTRACTOR is obligated to commence and complete all such services; or
(c) The amount of compensation the OWNER is obligated or committed to pay the CONTRACTOR.
2.2. The Project Coordinator shall:
(a) Review and make appropriate recommendations on all requests submitted by the CONTRACTOR for payment for services and work provided and performed in accordance with this Agreement;
(b) Arrange for access to and make all provisions for CONTRACTOR to enter the Project site to perform the services to be provided by CONTRACTOR under this Agreement; and
(c) Provide notice to CONTRACTOR of any deficiencies or defects discovered by the OWNER with respect to the services to be rendered by CONTRACTOR hereunder.
2.3. CONTRACTOR acknowledges that access to the Project Site, to be arranged by OWNER for CONTRACTOR, may be provided during times that are not the normal business hours of the CONTRACTOR.
3.1. Services to be rendered by CONTRACTOR shall be commenced subsequent to the execution of this Agreement upon written Notice to Proceed from OWNER for all or any designated portion of the Project and shall be performed and completed by September 30, 2005. Based on the mutual agreement of both parties, this contract may be renewed a maximum of two one-year periods thereafter.
3.2. Should CONTRACTOR be obstructed or delayed in the prosecution or completion of its services as a result of unforeseeable causes beyond the control of CONTRACTOR, and not due to its own fault or neglect, including but not restricted to acts of God or of public enemy, acts of government or of the OWNER, fires, floods, epidemics, quarantine regulations, strikes or lock-outs, then CONTRACTOR shall notify OWNER in writing within five (5) working days after commencement of such delay, stating the cause or causes thereof, or be deemed to have waived any right which CONTRACTOR may have had to request a time extension.
3.3. No interruption, interference, inefficiency, suspension or delay in the commencement or progress of CONTRACTOR's services from any cause whatsoever, including those for which OWNER may be responsible in whole or in part, shall relieve CONTRACTOR of its duty to perform or give rise to any right to damages or additional compensation from OWNER. XXXXXXXXXX's sole remedy against OWNER will be the right to seek an extension of time to its schedule. This paragraph shall expressly apply to claims for early completion, as well as claims based on late completion. Provided, however, if through no fault or neglect of the CONTRACTOR, the services to be provided hereunder have not been completed within 18 months of the date hereof, the CONTRACTOR's compensation may be equitably adjusted, with respect to those services that have not yet been performed, to reflect the incremental increase in costs experienced by CONTRACTOR after expiration of said 18 month period.
3.4. Should the CONTRACTOR fail to commence, provide, perform or complete any of the services to be provided hereunder in a timely and reasonable manner, in addition to any other rights or remedies available to the OWNER hereunder, the OWNER at its sole discretion and option may withhold any and all payments due and owing to the CONTRACTOR until such time as the CONTRACTOR resumes performance of its obligations hereunder in such a manner so as to reasonably establish to the OWNER's satisfaction that the CONTRACTOR's performance is or will shortly be back on schedule.
Specific Responsibilities Without limiting the responsibilities of the Manager, the Manager will:
1. Maintain office facilities (which may be in the offices of the Manager or a corporate affiliate but shall be in such location as the Trust reasonably determines).
2. Furnish statistical and research data, clerical services and stationery and office supplies.
3. Compile data for, prepare for execution by the Fund and file all the Fund’s federal and state tax returns and required tax filings other than those required by this Agreement to be made by the Fund’s custodian and transfer agent.
4. Prepare compliance filings pursuant to state securities laws with the advice of the Trust’s counsel.
5. Prepare the Trust’s Annual and Semi-Annual Reports to Shareholders and amendments to its Registration Statements (on Form N-1A or any replacement therefor).
6. Compile data for, prepare and file timely Notices to the SEC required pursuant to Rule 24f-2 under the 1940 Act.
7. Determine the daily pricing of the portfolio securities and computation of the net asset value and the net income of Fund in accordance with the Prospectus, resolutions of the Trust’s Board of Trustees, and the procedures set forth in EXHIBIT A: NET ASSET VALUE CALCULATIONS.
8. Keep and maintain the financial accounts and records of the Fund and provide the Trust with certain reports, as needed or requested by the Fund.
9. Provide officers for the Trust as requested by the Trust’s Board of Trustees.
10. Perform fund accounting services for the Fund as set forth in EXHIBIT B: FUND ACCOUNTING FUNCTIONS.
11. Generally assist in all aspects of the operations of the Fund.
Cost Responsibility for Interconnection Facilities and Distribution Upgrades 4.1 Interconnection Facilities 4.2 Distribution Upgrades
COUNTY’S RESPONSIBILITIES A. A County program liaison will monitor the submission of all correspondence required in this Agreement, including, but not limited to:
1. Quarterly Treatment Reports;
2. Financial reports such as annual budgets, cost allocation plans, and cost reports;
3. Incident reports;
4. Outcome data;
5. Monthly XXXXX Reports
6. Other requested reports
B. A County program liaison may visit Contractor during the contract term. The visits shall be for the purpose of reviewing any aspect of Contractor’s program operations. The visit may include, but is not limited to:
1. Review all pertinent participant records.
2. Conduct appropriate interviews/discussions with participants served by Contractor.
3. Review and monitor all correspondence and reports submitted by Contractor related to Contractor’s services provided under this Agreement.
4. Meet with appropriate program management and operations staff.
5. Conduct site visit(s) to Contractor’s program(s) at least once during the term of the Agreement to review all aspects of program operations. Site visit(s) may include a review of Contractor’s programmatic and fiscal documentation related to required reports on services specified in the Exhibits.
a. Provide a written site review report documenting areas of compliance and any necessary corrective action(s) required.
6. A County program liaison may attend an organized activity of a selected component or selected components of Contractor’s program(s) at least once during the contract term.
C. AODS will conduct periodic mandatory treatment provider meetings with representatives of all contracted service providers and appropriate staff.
D. Provide ongoing technical assistance as needed.
E. AODS shall act as intermediary on behalf of each contracted alcohol and drug service provider in the submission of the California Outcomes Measurement System (CalOMS) data submissions to the State of California.
I. GENERAL ADMINISTRATIVE REQUIREMENTS
A. Attend each of the following meetings:
1. Contractor shall attend periodic mandatory meetings; and
2. Drug and Alcohol Information System for You (DAISY) User Group meeting.
3. Other meetings as required by the County
B. Contractor shall acknowledge the San Mateo County Alcohol and Other Drug Services (AODS) and/or the County of San Mateo as a funding source on newly developed promotional materials.
C. Subcontracting requirements:
1. Pursuant to paragraph 12 of the body of this Agreement, Contractor may subcontract for provision of services described in this Agreement with written approval of the Director of the Human Services Agency or her designee. If Contractor subcontracts for any services under this Agreement, Contractor will guarantee that any and all subcontractors have and maintain the same level of insurance coverage required of the Contractor under this Agreement. Contractor and County will be listed as additional insured on all applicable insurance of subcontractor.
