Orders and Forecasting Eighteen Month Supply Delivery Sample Clauses

Open Split View

Download

Share

Cite

Orders and Forecasting Eighteen Month Supply Delivery 

Sample 1Sample 2

Save

Copy

Related to Orders and Forecasting Eighteen Month Supply Delivery

• DELIVERY: FOB DESTINATION, INSIDE DELIVERY, FREIGHT PAID Whenever possible, contractors should give the ordering entities 3 working days prior notice of any deliveries and/or installations. Furniture contractors will not be responsible for the removal/moving of existing furnishings unless requested by the ordering entity. Contractors should verify site readiness prior to delivery. All deliveries will be made during normal working hours unless otherwise arranged with the ordering entity. Contractor will communicate any scheduling delays and/or changes immediately. Agencies will not be responsible for any freight damage, concealed or otherwise.

• Rolling Forecast (i) On or before the fifteenth (15th) calendar day of each month during the Term (as defined in Section 6.1 herein), Buyer shall provide Seller with an updated eighteen (18) month forecast of the Products to be manufactured and supplied (each a “Forecast”) for the eighteen (18) month period beginning on the first day of the following calendar month. The first two months of each Forecast will restate the balance of the Firm Order period of the prior Forecast, and the first three (3) months of the Forecast shall constitute the new Firm Order period for which Buyer is obligated to purchase and take delivery of the forecasted Product, and the supply required for the last month of such new Firm Order period shall not be more than one (1) full Standard Manufacturing Batch from the quantity specified for such month in the previous Forecast (or Initial Forecast, as the case may be). Except as provided in Section 2.2(a), Purchase Orders setting forth Buyer’s monthly Product requirements will be issued for the last month of each Firm Order period no later than the fifteenth calendar day of the first month of each Firm Order period, and such Purchase Order will be in agreement with the Firm Order period of the Forecast. If a Purchase Order for any month is not submitted by such deadline, Buyer shall be deemed to have submitted a Purchase Order for such month for the amount of Product set forth in Buyer’s Forecast for such month. (ii) The remainder of the Forecast shall set forth Buyer’s best estimate of its Product production and supply requirements for the remainder of the Forecast period. Each portion of such Forecast that is not deemed to be a Firm Order shall not be deemed to create a binding obligation on Buyer to purchase and take delivery of Products nor a binding obligation of Seller to deliver Products, except as otherwise provided in Section 2.2(f). (iii) Forecast and Purchase Orders shall be in full Standard Manufacturing Batches. If a Product has multiple SKUs, then the composite of the forecasted SKU must equate to the Standard Manufacturing Batch. One Purchase Order shall be issued for each full Standard Manufacturing Batch of Product and contain the required information set forth in Section 2.2(e) hereof.

• Rolling Forecasts No later than ten (10) days of the Commencement Date, the Client shall provide Patheon with a written non-binding 18 month forecast of the volume of the Drug Product that the Client then anticipates will be required to be produced and delivered to the Client during each month of that 18 month period. Such forecast will be updated by the Client monthly on a rolling 18 month basis and updated forthwith upon the Client determining that the volumes contemplated in the most recent of such forecasts has changed by more than 20%. The most recent 18 month forecast shall prevail.

• Forecasts and Purchase Orders (a) Following Regulatory Approval of one of the Initial Products during the term of this Agreement, Reliant shall provide to ASL no later than the first day of the first month of each calendar quarter a non-binding good faith estimate (“Quarterly Forecast”) by quarter of Reliant’s requirements for the Active Ingredient for the calendar quarter and the succeeding three (3) calendar quarters. Reliant will be obligated to purchase 75% of the quantities of API forecasted for the first two (2) succeeding calendar quarters of each Quarterly Forecast. Within (30) days of Regulatory Approval, Reliant shall provide an initial forecast (“Initial Forecast”) for the four calendar quarters following Regulatory Approval. (b) Reliant shall place binding purchase orders for Active Ingredient by written or electronic purchase order (or by any other means agreed to by the parties) to ASL, which shall be placed at least ninety (90) days prior to desired date of delivery. (c) ASL shall be obligated to supply Active Ingredient as ordered by Reliant. To the extent purchase orders in any calendar month exceed One Hundred Fifty percent (150%) of the Quarterly Forecast for the relevant quarter, ASL shall use its best efforts to supply 125% of the quantity ordered. (d) ASL shall maintain minimum inventory levels equal to the binding portion of the then current Quarterly Forecast. The Active Ingredient shall be shipped C.I.F. Duty Unpaid to a Designated Facility or other location agreed by the parties. Active Ingredient shall be shipped upon completion of production in temperature-controlled vehicles in accordance with the specifications including light protecting containers and the Quality Agreement in order to maintain the quality of the Active Ingredient. Carriers selected by ASL must be commercially reputable, able to track shipments and fully insured with adequate coverage to replace the value of the goods shipped. Title and risk of loss pass on delivery to the Designated Facility. (e) All shipments of Active Ingredient shall be accompanied by a packing slip and a certificate of analysis which describes the Active Ingredient, states the purchase order number, confirms that the Active Ingredient conforms in all ways with the Specifications, the Process Description and was manufactured in accordance with GMP and all other requirements of the Act. To the extent of any conflict or inconsistency between this Agreement and any purchase order, purchase order release, confirmation, acceptance or any similar document, the terms of this Agreement shall govern. (f) Reliant shall notify ASL of any short-shipment claims within thirty (30) days of receipt of a shipment of Active Ingredient. (g) ASL shall not be obligated to accept any returns of Active Ingredient other than as a result of such Active Ingredient failing to meet the Specifications in accordance with Section 2.9(a), was not manufactured in accordance with GMP, or does not otherwise comply with the manufacturing, storage and/or transportation requirements of the Act.

• Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.

• Minimum Shipping Requirements for TIPS Sales Vendor shall ship, deliver, or provide ordered goods and services within a commercially reasonable time after acceptance of the order. If a delay in delivery is anticipated, Vendor shall notify the TIPS Member as to why delivery is delayed and provide an updated estimated time for completion. The TIPS Member may cancel the order if the delay is not commercially acceptable or not consistent with the Supplemental Agreement applicable to the order.

• Bidder Supplied Samples The Commissioner reserves the right to request from the Bidder/Contractor a representative sample(s) of the Product offered at any time prior to or after award of a contract. Unless otherwise instructed, samples shall be furnished within the time specified in the request. Untimely submission of a sample may constitute grounds for rejection of Bid or cancellation of the Contract. Samples must be submitted free of charge and be accompanied by the Bidder’s name and address, any descriptive literature relating to the Product and a statement indicating how and where the sample is to be returned. Where applicable, samples must be properly labeled with the appropriate Bid or Contract reference. A sample may be held by the Commissioner during the entire term of the Contract and for a reasonable period thereafter for comparison with deliveries. At the conclusion of the holding period the sample, where feasible, will be returned as instructed by the Bidder, at the Bidder’s expense and risk. Where the Bidder has failed to fully instruct the Commissioner as to the return of the sample (i.e., mode and place of return, etc.) or refuses to bear the cost of its return, the sample shall become the sole property of the receiving entity at the conclusion of the holding period.

• Project Delivery Order Procedures The TIPS Member having approved and signed an interlocal agreement, or other TIPS Membership document, may make a request of the awarded vendor under this Agreement when the TIPS Member has services that need to be undertaken. Notification may occur via phone, the web, email, fax, or in person. Upon notification of a pending request, the awarded vendor shall make contact with the TIPS Member as soon as possible, but must make contact with the TIPS Member within two working days. Scheduling of projects (if applicable) may be accomplished when the TIPS Member issues a Purchase Order and/or an Agreement or Contract that will serve as “the notice to proceed” as agreed by the Vendor and the TIPS Member. The period for the delivery order will include the mobilization, materials purchase, installation and delivery, design, weather, and site cleanup and inspection. No additional claims may be made for delays as a result of these items. When the tasks have been completed the awarded vendor shall notify the client and have the TIPS Member or a designated representative of the TIPS Member inspect the work for acceptance under the scope and terms in the Purchase Order and/or Agreement or Contract. The TIPS Member will issue in writing any corrective actions that are required. Upon completion of these items, the TIPS Member will issue a completion notice and final payment will be issued per the contractual requirements of the project with the TIPS Member. Any Construction contract prepared by the TIPS Member’s Legal Counsel may alter the terms of this subsection, “Scheduling of Projects”.

• Forecast Customer shall provide Flextronics, on a monthly basis, a rolling [***] forecast indicating Customer’s monthly Product requirements. The first [***] of the forecast will constitute Customer’s written purchase order for all Work to be completed within the first [***] period. Such purchase orders will be issued in accordance with Section 3.2 below.

• Purchase Order and Sales Contact Email Please enter a valid email address that will definitely reach the Purchase Order and Sales Contact. xxxxxxx.xxxxxxxxx@xxxxx.xxx Numbers only, no symbols or spaces (Ex. 8668398477). The system will auto-populate your entry with commas once submitted which is appropriate and expected (Ex. 8,668,398,477). 6122484264 Company Website (Format - xxx.xxxxxxx.xxx) xxxxx://xxx.xxxxx.xxx/ You must confirm that you are responding to this solicitation under your legal entity name. Go now to your Supplier Profile in this eBid System and confirm that your profile reflects your "Legal Name" as it is listed on your W9. In this question, please identify all of your entity's assumed names and D/B/A's. Please note that you will be identified publicly by the Legal Name under which you respond to this solicitation unless you organize otherwise with TIPS after award. Midwest Mechanical Solutions Primary Address 0000 Xxxxx Xxxx Primary Address City Golden Valley Primary Address State (2 Digit Abbreviation) Minnesota Primary Address Zip 55427 Please list all search words and phrases to be included in the TIPS database related to your entity. Do not list words which are not associated with the bid category/scope (See bid title for general scope). This will help users find you through the TIPS website search function. You may include product names, manufacturers, specialized services, and other words associated with the scope of this solicitation. MMS, Midwest Mechanical Solutions, HVAC Does Vendor's parent company or majority owner: