Forecasts and Purchase Orders (a) Following Regulatory Approval of one of the Initial Products during the term of this Agreement, Reliant shall provide to ASL no later than the first day of the first month of each calendar quarter a non-binding good faith estimate (“Quarterly Forecast”) by quarter of Reliant’s requirements for the Active Ingredient for the calendar quarter and the succeeding three (3) calendar quarters. Reliant will be obligated to purchase 75% of the quantities of API forecasted for the first two (2) succeeding calendar quarters of each Quarterly Forecast. Within (30) days of Regulatory Approval, Reliant shall provide an initial forecast (“Initial Forecast”) for the four calendar quarters following Regulatory Approval.
(b) Reliant shall place binding purchase orders for Active Ingredient by written or electronic purchase order (or by any other means agreed to by the parties) to ASL, which shall be placed at least ninety (90) days prior to desired date of delivery.
(c) ASL shall be obligated to supply Active Ingredient as ordered by Reliant. To the extent purchase orders in any calendar month exceed One Hundred Fifty percent (150%) of the Quarterly Forecast for the relevant quarter, ASL shall use its best efforts to supply 125% of the quantity ordered.
(d) ASL shall maintain minimum inventory levels equal to the binding portion of the then current Quarterly Forecast. The Active Ingredient shall be shipped C.I.F. Duty Unpaid to a Designated Facility or other location agreed by the parties. Active Ingredient shall be shipped upon completion of production in temperature-controlled vehicles in accordance with the specifications including light protecting containers and the Quality Agreement in order to maintain the quality of the Active Ingredient. Carriers selected by ASL must be commercially reputable, able to track shipments and fully insured with adequate coverage to replace the value of the goods shipped. Title and risk of loss pass on delivery to the Designated Facility.
(e) All shipments of Active Ingredient shall be accompanied by a packing slip and a certificate of analysis which describes the Active Ingredient, states the purchase order number, confirms that the Active Ingredient conforms in all ways with the Specifications, the Process Description and was manufactured in accordance with GMP and all other requirements of the Act. To the extent of any conflict or inconsistency between this Agreement and any purchase order, purchase order release, confirmation, acceptance or any similar document, the terms of this Agreement shall govern.
(f) Reliant shall notify ASL of any short-shipment claims within thirty (30) days of receipt of a shipment of Active Ingredient.
(g) ASL shall not be obligated to accept any returns of Active Ingredient other than as a result of such Active Ingredient failing to meet the Specifications in accordance with Section 2.9(a), was not manufactured in accordance with GMP, or does not otherwise comply with the manufacturing, storage and/or transportation requirements of the Act.
Minimum Shipping Requirements for TIPS Sales Vendor shall ship, deliver, or provide ordered goods and services within a commercially reasonable time after acceptance of the order. If a delay in delivery is anticipated, Vendor shall notify the TIPS Member as to why delivery is delayed and provide an updated estimated time for completion. The TIPS Member may cancel the order if the delay is not commercially acceptable or not consistent with the Supplemental Agreement applicable to the order.
Particular Methods of Procurement of Goods Works and Services (other than Consultants’ Services)
Penalties for non-conformity of production 9.1. The approval granted in respect of a vehicle type pursuant to this Regulation may be withdrawn if the requirements set forth above are not met.
9.2. If a Contracting Party to the Agreement applying this Regulation withdraws an approval it has previously granted, it shall forthwith so notify the other Contracting Parties applying this Regulation, by means of a communication form conforming to the model in Annex 1 to this Regulation.
Project Delivery Order Procedures The TIPS Member having approved and signed an interlocal agreement, or other TIPS Membership document, may make a request of the awarded vendor under this Agreement when the TIPS Member has services that need to be undertaken. Notification may occur via phone, the web, email, fax, or in person. Upon notification of a pending request, the awarded vendor shall make contact with the TIPS Member as soon as possible, but must make contact with the TIPS Member within two working days. Scheduling of projects (if applicable) may be accomplished when the TIPS Member issues a Purchase Order and/or an Agreement or Contract that will serve as “the notice to proceed” as agreed by the Vendor and the TIPS Member. The period for the delivery order will include the mobilization, materials purchase, installation and delivery, design, weather, and site cleanup and inspection. No additional claims may be made for delays as a result of these items. When the tasks have been completed the awarded vendor shall notify the client and have the TIPS Member or a designated representative of the TIPS Member inspect the work for acceptance under the scope and terms in the Purchase Order and/or Agreement or Contract. The TIPS Member will issue in writing any corrective actions that are required. Upon completion of these items, the TIPS Member will issue a completion notice and final payment will be issued per the contractual requirements of the project with the TIPS Member. Any Construction contract prepared by the TIPS Member’s Legal Counsel may alter the terms of this subsection, “Scheduling of Projects”.
Delivery Schedule The Goods specified in the List of Goods are required to be delivered within the acceptable time range (after the earliest and before the final date, both dates inclusive) specified in Section V, Schedule of Requirements. No credit will be given to deliveries before the earliest date, and Tenders offering delivery after the final date shall be treated as non-responsive. Within this acceptable period, an adjustment of [insert the adjustment factor], will be added, for evaluation purposes only, to the Tender price of Tenders offering deliveries later than the “Earliest Delivery Date” specified in Section V, Schedule of Requirements.
Purchase Order Requirements Customers shall use a Request for Quote per section 287.056(2), Florida Statutes, when making purchases off of this State Term Contract. Customers shall issue Request for Quotes to at least 25 vendors approved to provide IT Staff Augmentation services in accordance with section 287.0591(5), Florida Statutes. Customers shall order services from the Request for Quote via a Purchase Order with the Customers’ selected Contractor. The terms of the Purchase Order shall not conflict with the terms and conditions established by this Contract. In accepting a Purchase Order, the Contractor recognizes its responsibility for all tasks and deliverables contained therein, warrants that it has fully informed itself of all relevant factors affecting accomplishment of the tasks and deliverables and agrees to be fully accountable for the performance thereof.
DELIVERY: FOB DESTINATION, INSIDE DELIVERY, FREIGHT PAID Whenever possible, contractors should give the ordering entities 3 working days prior notice of any deliveries and/or installations. Furniture contractors will not be responsible for the removal/moving of existing furnishings unless requested by the ordering entity. Contractors should verify site readiness prior to delivery. All deliveries will be made during normal working hours unless otherwise arranged with the ordering entity. Contractor will communicate any scheduling delays and/or changes immediately. Agencies will not be responsible for any freight damage, concealed or otherwise.
PURCHASE ORDERS AND INVOICING All invoices shall at a minimum, include the items listed below and any additional information identified in the Authorized User RFQ and resulting Authorized User Agreement: Contract Number; Contractor/Reseller Name; NYS Vendor ID; Manufacturer Part Number (SKU); Product Name; Product Description; Quantity; NYS Net Price for each Product; Specific designation of special price(s) which may be better than the NYS Net Contract Price; and Invoice Total.
Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.
