Functionality Customer is entitled to additional functionality previously purchased or bundled with the software if available in the version or update released on or after the start date of the Agreement. Customer acknowledges that certain functionality in current and previous software versions may not be available in future upgrades. Added functionality may require additional paid services (clinical and technical) to configure and support.
Product ACCEPTANCE Unless otherwise provided by mutual agreement of the Authorized User and the Contractor, Authorized User(s) shall have thirty (30) days from the date of delivery to accept hardware products and sixty (60) days from the date of delivery to accept all other Product. Where the Contractor is responsible for installation, acceptance shall be from completion of installation. Failure to provide notice of acceptance or rejection or a deficiency statement to the Contractor by the end of the period provided for under this clause constitutes acceptance by the Authorized User(s) as of the expiration of that period. The License Term shall be extended by the time periods allowed for trial use, testing and acceptance unless the Commissioner or Authorized User agrees to accept the Product at completion of trial use. Unless otherwise provided by mutual agreement of the Authorized User and the Contractor, Authorized User shall have the option to run testing on the Product prior to acceptance, such tests and data sets to be specified by User. Where using its own data or tests, Authorized User must have the tests or representative set of data available upon delivery. This demonstration will take the form of a documented installation test, capable of observation by the Authorized User, and shall be made part of the Contractor’s standard documentation. The test data shall remain accessible to the Authorized User after completion of the test. In the event that the documented installation test cannot be completed successfully within the specified acceptance period, and the Contractor or Product is responsible for the delay, Authorized User shall have the option to cancel the order in whole or in part, or to extend the testing period for an additional thirty (30) day increment. Authorized User shall notify Contractor of acceptance upon successful completion of the documented installation test. Such cancellation shall not give rise to any cause of action against the Authorized User for damages, loss of profits, expenses, or other remuneration of any kind. If the Authorized User elects to provide a deficiency statement specifying how the Product fails to meet the specifications within the testing period, Contractor shall have thirty (30) days to correct the deficiency, and the Authorized User shall have an additional sixty (60) days to evaluate the Product as provided herein. If the Product does not meet the specifications at the end of the extended testing period, Authorized User, upon prior written notice to Contractor, may then reject the Product and return all defective Product to Contractor, and Contractor shall refund any monies paid by the Authorized User to Contractor therefor. Costs and liabilities associated with a failure of the Product to perform in accordance with the functionality tests or product specifications during the acceptance period shall be borne fully by Contractor to the extent that said costs or liabilities shall not have been caused by negligent or willful acts or omissions of the Authorized User’s agents or employees. Said costs shall be limited to the amounts set forth in the Limitation of Liability Clause for any liability for costs incurred at the direction or recommendation of Contractor.
SHOP DRAWINGS, PRODUCT DATA AND SAMPLES 4.12.1 Shop Drawings are drawings, diagrams, schedules and other, data specially prepared for the Work by the Contractor or any Subcontractor, manufacturer, supplier or distributor to illustrate some portion of the Work. 4.12.2 Product Data are illustrations, standard schedules, performance charts, instructions, brochures, diagrams and other information furnished by the Contractor to illustrate a material, product or system for some portion of the Work. 4.12.3 Samples are physical examples which illustrate materials, equipment or workmanship and establish standards by which the Work will be judged. 4.12.4 The Contractor shall review, approve and submit, with reasonable promptness and in such sequence as to cause no delay in the Work or in the work of the State or any separate contractor, all Shop Drawings, Product Data and Samples required by the Contract Documents. 4.12.5 By approving and submitting Shop Drawings, Product Data and Samples, the Contractor represents that he / she has determined and verified all materials, field measurements, and field construction criteria related thereto, or will do so, and that he / she has checked and coordinated the information contained within such submittals with the requirements of the Work and of the Contract Documents. 4.12.6 The Contractor shall not be relieved of responsibility for any deviation from the requirements of the Contract Documents by the Architect's approval of Shop Drawings, Product Data or Samples under Subparagraph 2.2.7 of these General Conditions unless the Contractor has specifically informed the Architect and the State in writing of such deviation at the time of sub- mission and the Architect and the State has given written approval to the specific deviation. The Contractor shall not be relieved from responsibility for errors or omissions in the Shop Drawings, Product Data or Samples by the Architect's approval thereof. 4.12.7 The Contractor shall direct specific attention, in writing or on resubmitted Shop Drawings, Product Data or Samples, to revisions other than those requested by the Architect on previous submittals. 4.12.8 No portion of the Work requiring submission of a Shop Drawing, Product Data or Sample shall be commenced until the submittal has been approved by the Architect as provided in Subparagraph 2.2.7 of these General Conditions. All such portions of the Work shall be in accordance with approved submittals.
API If the Software offers integration capabilities via an API, your use of the API may be subject to additional costs or Sage specific policies and terms and conditions (which shall prevail in relation to your use of the API). You may not access or use the API in any way that could cause damage to us or the Software, or in contravention of any applicable laws. We reserve the right in our sole discretion, to: (i) update any API from time to time; (ii) place limitations around your use of any API; and (iii) deny you access to any API in the event of misuse by you or to otherwise protect our legitimate interests.
Contract Database Metadata Elements Title: Great Neck Union Free School District and Great Neck Paraprofessionals Association (2011) Employer Name: Great Neck Union Free School District Union: Great Neck Paraprofessionals Association Local: Effective Date: 07/01/2011 Expiration Date: 06/30/2015 PERB ID Number: 5132 Unit Size: Number of Pages: 28 For additional research information and assistance, please visit the Research page of the Catherwood website - xxxx://xxx.xxx.xxxxxxx.xxx/library/research/ For additional information on the ILR School - xxxx://xxx.xxx.xxxxxxx.xxx/ ARTICLE# TITLE PAGE# Preamble 2 Article 1 Association Rights 2 Article 2 Board-Administration-Association Relationship and Procedures 4 Article 3 Exchange of Proposals 6 Article 4 Professionals Duties and Responsibilities of Paraprofessionals 7 Article 5 Work Assignments 8 Article 6 Annual Appointment 10 Article 7 Selection and Promotion 10 Article 8 Evaluations and Standards 11 Article 9 Procedures for Termination of Employment 11 Article 10 Conferences 12 Article 11 Human Resource File 12 Article 12 Professional Growth 13 Article 13 Sick Leave 14 Article 14 Personal Leave 16 Article 15 Other Leaves 17 Article 16 Grievance Procedures 18 Article 17 Legal Assistance 19 Article 18 Conformity to Law 19 Article 19 Health Insurance 20 Article 20 Retirement Plan 20 Article 21 Salary Schedule 21 Article 22 Seniority Policy 23 Article 23 Compensation for Financial Loss 24 Article 24 Duration of Agreement 25 Appendix A Determination of Negotiating Unit 25 Appendix B Payroll Deduction Authorization 26 Appendix C Bus Aides 26 Appendix D Salary Schedules 27
ODUF Packing Specifications 6.3.1 A pack will contain a minimum of one message record or a maximum of 99,999 message records plus a pack header record and a pack trailer record. One transmission can contain a maximum of 99 packs and a minimum of one pack.
RE-WEIGHING PRODUCT Deliveries are subject to re- weighing at the point of destination by the Authorized User. If shrinkage occurs which exceeds that normally allowable in the trade, the Authorized User shall have the option to require delivery of the difference in quantity or to reduce the payment accordingly. Such option shall be exercised in writing by the Authorized User.
Compatibility 1. Any unresolved issue arising from a mutual agreement procedure case otherwise within the scope of the arbitration process provided for in this Article and Articles 25A to 25G shall not be submitted to arbitration if the issue falls within the scope of a case with respect to which an arbitration panel or similar body has previously been set up in accordance with a bilateral or multilateral convention that provides for mandatory binding arbitration of unresolved issues arising from a mutual agreement procedure case. 2. Nothing in this Article and Articles 25A to 25G shall affect the fulfilment of wider obligations with respect to the arbitration of unresolved issues arising in the context of a mutual agreement procedure resulting from other conventions to which the Contracting States are or will become parties.”.
Product Testing No later than [**] prior to a scheduled Delivery ARIAD US shall send to ARIAD SWISSCO the Delivery Documents for review. Following such review, unless within [**] of receipt of the Delivery Documents ARIAD SWISSCO gives written notice of rejection of the Product to be delivered, stating the reasons for such rejection, the Delivery shall proceed, and both Parties shall organize the same. Upon arrival at ARIAD SWISSCO nominated site it shall visually inspect the shipment of the Product to identify any damage to the external packaging. ARIAD SWISSCO may reject any shipment (or portion thereof) of the Product that is damaged by providing to ARIAD US reasonable evidence of damage within [**] after Delivery of such Product. If ARIAD SWISSCO does not so reject any shipment (or portion thereof) of the Product within [**] of Delivery of such Product, ARIAD SWISSCO shall be deemed to have accepted such shipment of the Product; provided, however, that in the case of the Product having any Latent Defect, ARIAD SWISSCO shall notify ARIAD US promptly once it becomes aware that a Product contains a Latent Defect and subsequently may reject such Product by giving written notice to ARIAD US of ARIAD SWISSCO’s rejection of such Product and shipping a representative sample of such Product or other evidence of Non-Conformance to ARIAD US within [**] after becoming aware of such Latent Defect, which notice shall include a description of the Latent Defect.
Technical Specifications The Technical Specifications furnished on the CD are intended to establish the standards for quality, performance and technical requirements for all labor, workmanship, material, methods and equipment necessary to complete the Work. When specifications and drawings are provided or referenced by the County, these are to be considered part of the Scope of Work, and to be specifically documented in the Detailed Scope of Work. For convenience, the County supplied specifications, if any, and the Technical Specifications furnished on the CD.
